Laserfiche WebLink
Laws and Regulations enacted subsequent to the Effective Date or are due to any other <br />causes beyond Engineer's control. <br />3. Services resulting from Owner's request to evaluate additional Study and Report Phase <br />alternative solutions beyond those identified under Basic Services. <br />4. Services required as a result of Owner's providing incomplete or incorrect Project <br />information to Engineer. <br />5. Undertaking investigations and studies including, but not limited to, detailed consideration <br />of operations, maintenance, and overhead expenses; the preparation of financial feasibility <br />and cash flow studies, rate schedules, and appraisals; assistance in obtaining financing for <br />the Project; evaluating processes available for licensing, and assisting Owner in obtaining <br />process licensing; detailed quantity surveys of materials, equipment, and labor; and audits or <br />inventories required in connection with construction performed by Owner. <br />6. Furnishing services of Consultants for other than Basic Services. <br />7. Preparing for, coordinating with, participating in and responding to structured independent <br />review processes, including, but not limited to, construction management, cost estimating, <br />project peer review, value engineering, and constructibility review requested by Owner; and <br />performing or furnishing services required to revise studies, reports, Drawings, <br />Specifications, or other Bidding Documents as a result of such review processes. <br />S. Preparing additional Bidding Documents or Contract Documents for alternate bids or prices <br />requested by Owner for the Work or a portion thereof. <br />9. Assistance in connection with Bid protests, rebidding, or renegotiating contracts for <br />construction, materials, equipment, or services. <br />10. Providing construction surveys and staking to enable Contractor to perform its work, and <br />any type of property surveys or related engineering services needed for the transfer of <br />interests in real property; and providing other special field surveys. <br />11. Providing Construction Phase services beyond the original date for completion and <br />readiness for final payment of Contractor. <br />12. Preparing to serve or serving as a consultant or witness for Owner in any litigation, <br />arbitration, or other dispute resolution process related to the Project. <br />25. Other services performed or furnished by Engineer not otherwise provided for in this <br />Agreement. <br />A2.02 Additional Services Not Requiring avner's Written Authorization <br />A. Engineer shall advise Owner in advance that Engineer will inunediately commence to perform or <br />furnish the Additional Services of the types listed below. For such Additional Services, Engineer <br />Page 7 <br />(Exhibit A — Engineer's Services) <br />EJCDC E-500 Agreement Behveen Owner and Engineer for Professional Services <br />Copyright O 2008 National Society of Professional Engineers for EJCDC. All rights reserved. <br />