|
Architect's evaluation of the Work as provided in Section 3.6.2 and on the data comprising; the Contractor's
<br />Application for Payment, that, to the best of the ,architect's knowledge, information and belief, the Work has
<br />progressed to the point indicated, the quality of the 'Work is in accordance with the Contract Documents, and that the
<br />Contractor is entitled to payment in the amount certified. The foregoing representations are subject to (I) an
<br />evaluation of the Work for conformance with the Contract Documents upon Substantial Completion, (2) results of
<br />subsequent tests and inspections, (3) correction of Minor deviations from the Contract Documents prior to
<br />completion, and (4) specific qualifications expressed by the Architect.
<br />§ 3.6.3.2 The issuance of a Certificate for Payment shall not be a representation that the Architect has ( I ) made
<br />exhaustive or continuous on -site inspections to check the duality or quantity of the Work, (2) reviewed construction
<br />means, methods, techniques, sequences or procedures, (3) reviewed copies ofrequisitions received from
<br />Subcontractors and suppliers and other data requested by the Owner to substantiate the Contractor's right to
<br />payment, or (4) ascertained how or for what purpose the Contractor has used money previously paid on account of
<br />the Contract SLIM.
<br />§ 16.3.3 The Architect :shall maintain a record of the Applications and Certificates for payment.
<br />§ 3.6.4 Submittals
<br />§ 3. AI The Architect shall review the Contractor's submittal schedule and shall not unreasonably delay or withhold.
<br />approval of the schedule, The Architect's action in reviewing submittals shall be taken in accordance with the
<br />approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while
<br />allowing sufficient time, in the Architect's professional judgment, to permit adequate review.
<br />§ 3.6.4.2 The Architect shall review and approve, or take other appropriate action upon, the Contractor's submittals
<br />such as Shop Drawings, Product Data and Samples, but only for the limited purpose of checking for conformance
<br />with information given and the design concept expressed in the Contract Documents. Review of such submittals is
<br />not for the purpose of determining the accuracy and completeness of other information such as dimensions,
<br />quantities, and installation or performance of equipment or systems, which are the Contractor's responsibility. The
<br />Architect's review shall not constitute approval of safety precautions or construction means, methods, techniques,
<br />sequences or procedures. The Architect's approval of a specific item shall not indicate approval of an assembly of
<br />which the item is a component,
<br />§ 3.6.4.3 If the Contract Documents specifically require the Contractor to provide professional design services or
<br />certifications by a design professional related to systems, materials, or equipment, the Architect shall specify the
<br />appropriate performance and design criteria that such services must satisfy. The Architect shall review and take
<br />appropriate action on Shop Drawings and other submittals related to the Work designed or certified by the
<br />Contractor's design professional, provided the submittals bear such professional's seal and signature when
<br />submitted to the Architect. The Architect's review shall be for the limited purpose of checking for conformance with
<br />information given and the design concept expressed in the Contract Documents. The Architect shall be entitled to
<br />rely upon, and shall not be responsible for, the adequacy and accuracy of the services, certifications, and approvals
<br />performed or provided by such design professionals,
<br />§ 3.6.4.4 Subject to Section 4.2, the Architect shall review and respond to requests for information about the Contract
<br />Documents. The Architect shall set forth, in the Contract Documents, the requirements for requests for information.
<br />Requests for information shall include, at a minimum, a detailed written statement that indicates the specific
<br />Drawings or Specifications in need of clarification and the nature of the clarification requested. The Architect's
<br />response to such requests shall be made in writing, within any time limits agreed upon, or otherwise with reasonable
<br />promptness. If appropriate, the Architect shall prepare and issue supplemental Drawings and Specifications in
<br />response to the requests for information.
<br />§ 3.6.4.5 The Architect shall maintain a record of submittals and copies of submittals supplied by the Contractor in
<br />accordance with the requirements of the Contract Documents.
<br />§ 3.6.5 Changes in the Work
<br />§ 3.6.5.1 The Architect may order minor changes in the Work that are consistent with the intent of the Contract
<br />Documents and do not involve an adjustment in the Contract Sum or an extension of the Contract Time. Subject to
<br />AIA Document B1101 T" — 2017. Copyright@ 1974, 1978, 1987, 1997, 2,0�07 and 2017 by The American Institute of Architects. All rights reserved. WAIIR VII"1' .
<br />Init. err t" U . , p, g r ationel Tteatlm s. Unau ffiorized reproduction o di%tiithuaituoiru of this AM""" Document, I �
<br />w aura .ontuon of it, nrna ua.rruflt'in waves irc ry w�u 9��1t�. 1 do cnmc inure muffs )�or.uuruen is protected ac tM
<br />rd 0 7 u��wsn9 1vrt�w�rt c�m'udrqurual p.baarturNtuas, and urrs4l tre Ipuuxsurrurttrrtt to the nnsr4rtuuuwai exrvurrrt poawo&atms uuai4eur 4huu tawrlr. 1"his
<br />document was produced by ABA software at 12:W45 on 01116/2018 under Order No. 2731703659 which expires on 01116/2019, and is not for resale.
<br />User Notes: (3139ADAIC)
<br />
|