|
WARRANTY:
<br />MANUFACTURERS' LIMITED WARRANTY ON ALL EQUIPMENT, PARTS AND MATERIALS.
<br />A. LABOR AND MATERIALS: Horton Ambulance shall furnish Me Ambulance listed as specified, with the price and delivery quoted herein, are
<br />based on materials which were in our inventory and in the inventory of our suppliers M the time of this proposal and are subject to prior sale.
<br />Delivery quotes are contingent on timely confirmation from Customer. Any variations to material listed will result in a cost change.
<br />Change Order Fees may apply
<br />B. ARBITRATION: If any controversy or dispute arises under, out of, or in relation many of Me provisions hereof Mach cannot be settled by
<br />Me partieswithin 15 days after Me same shall arse, such controversy or dispute shall be submitted for arbitration in Me State of Ohio in
<br />accordance with the rules of Me American Arbitration Association. Such arbitrators) in accordance War such rules shall
<br />determine any dispute or controversy submitted to arbitration in accordance with the previsions of the section.
<br />The ar atuator(s) may award any relief which he or she shall deem proper in Me circumstances, without regard to the relief which
<br />would otherwise be available to any party hereto in a court of law or equity including, without limitation, an award of money damages, specific
<br />performance, Injunctive relief and/or declaratory relief. The award and finings of Me arbitratcrs shall be conclusive and binding upon all the
<br />parties heron, whe r., or not all parties hereto participate in Me arbitration proceeding, and judgment upon Me eward may be entered in any
<br />court of competent jurisdiction upon the application of any parry.
<br />Any party may inhale an arbitration proceeding hereunder, all casts of which (including filing fees, fees payable to arbitrators, court
<br />mpodem' fees, transcript costs and counsel fees) shall be recovered by Me prevailing party. No parry hereto shall commence any arbitration
<br />proceeding hereunder other than in good faith, or take any action other than in good faith wblch requires another party hereto to commence
<br />such stretch hearing and, in the event any party is determined in arbitration to have so acted other Man in good faith, he or it shall bear all
<br />costs of the such proceeding.
<br />C. REPRESENTATION OF SOLVENCY Buyer represents net buyer is solvent and has assets sufficient to meet all of its financial obligations,
<br />and that it is current on all of its financial obligations. Buyer further represents Mal it can and will meet all hs financial obligations to seller on
<br />time. Buyer understands seller relies on this promise and Mat any breach is material and substantial and to the essence of the contract.
<br />D. FORCE MAJEURE: Seller shall not be responsible for tlelay, nondelivery, failure to complete installation or construction, or default in
<br />shipment or other performance, in whole or in part if occasioned by strike, war, riot, or revolutions, or for any delay in transportation due to
<br />demands or embargoes of the United States government or any other government, or nondelivery or delays through fire, floods, droughts,
<br />accidents, insurrections, lockouts, breakdown of machinery, commandeering of vessels caning goads, or for lass or damage in transit, or
<br />detention of or delay in vessels resulting directly or indirectly from acts of God, perils of Me sea, stoppage of labor, shortage of carriers, or
<br />refusal of any necessary license of government restrictions considered as'Yorce majeure" or any other unavoidable cause other than sellers
<br />own negligence. In no case shall seller be responsible after delivery of goods in good order or conditioning to Me carver or carvers at Me point
<br />of shipment
<br />E. CUSTOM ORDERS: Buyer understands Mat a custom-0rdered vehicle Is specific to Buyers needs. Any deposit received fora mstom order
<br />is non-refundable ance Engineering has begun, material has been purchased or the vehicle begins production.
<br />YOU MAY CONSIDER THE PRICE QUOTED FIRM FOR WRITTEN ACCEPTANCE WITHIN 30 DAYS OF THE DATE OF OUR PROPOSAL.
<br />Thank you for your interest in having Horton Ambulance provide you with our quotation for this
<br />purchase. If you have any questions or comments regarding this sales agreement please contact us.
<br />Sincerely,
<br />Robert Burgh
<br />Horton Ambulance
<br />ACCEPTANCE OF PROPOSAL:
<br />I have read, understand and agree to Me terms, conditions and specifications described herein and
<br />authorize Renegade Specialty Vehicies to go forward with this order.
<br />Signature of Customer Date
<br />
|