6B(3) - Laserfiche WebLink

Home Browse Search

15. Providing Construction Phase services beyond the original date for completion and readiness for final payment of Contractor. 16.Providing assistance in responding to the presence of any Constituent of Concern at the Site,in compliance with current Laws and Regulations. 17.Preparing Record Drawings showing appropriate record information based on Project annotated record documents received from Contractor, and furnishing such Record Drawings to Owner. 18. Preparation of operation and maintenance manuals. 19. Preparing to serve or serving as a consultant or witness for Owner in any litigation, arbitration,or other dispute resolution process related to the Project. 20.Providing more extensive services required to enable Engineer to issue notices or certifications requested by Owner. • 21.Assistance in connection with the adjusting of Project equipment and systems. 22.Assistance to Owner in training Owner's staff to operate and maintain Project equipment and systems. 23.Assistance to Owner. in developing procedures for (a) control of the operation and maintenance of Project equipment and systems,and(b)related record-keeping. 24. Overtime work requiring higher than regular rates. 25. Other services performed or furnished by Engineer not otherwise provided for in this Agreement. A2.02 Additional Services Not Requiring Owner's Written Authorization A. Engineer shall advise Owner in advance that Engineer is will immediately commence to perform or furnish the Additional Services of the types listed below. For such Additional Services, Engineer need not request or obtain specific advance written authorization from Owner. Engineer shall cease performing or furnishing such Additional Services upon receipt of written notice from Owner. 1. Services in connection with work change directives and change orders to reflect changes requested by Owner. 2. Services in making revisions to Drawings and Specifications occasioned by the acceptance of substitute materials or equipment other than"or-equal"items; services after the award of the Construction Contract in evaluating and determining the acceptability of a proposed "or equal" or substitution which is found to be inappropriate for the Project; evaluation and determination of an excessive number of proposed "or equals" or substitutions, whether proposed before or after award of the Construction Contract. Page 8 (Exhibit A—Engineer's Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright©2008 National Society of Professional Engineers for EJCDC. All rights reserved.