The URL can be used to link to this page

Home My WebLink AboutPSA - Design Services for Sidewalk & Crosswalk Angela & SR 23 Proj No 125-078- Christopher Burke ELIZABETH A. MARADIK JOSEPH R. MOLNAR GARY A. GILOT MURRAY L. MILLER BREANA N. MICOU CITY HALL 215 S. MARTIN LUTHER KING JR. BLVD., SUITE 400 SOUTH BEND, INDIANA 46601-1830 PHONE 574/ 235-9251 FAX 574/ 235-9171 CITY OF SOUTH BEND JAMES MUELLER, MAYOR BOARD OF PUBLIC WORKS December 9, 2025 Mr. Andy Gebhard Christopher B. Burke Engineering, LLC 220 W. Colfax Ave., Suite 700 South Bend, IN 46601 agebhard@cbbel-in.com RE: Professional Services Agreement Dear Mr. Gebhard: At its December 9, 2025 meeting, the Board of Public Works approved the above referenced agreement for the preliminary design services for sidewalk and crosswalk improvements near the corner of Angela Blvd. & State Rd. 23, Project No. 125-078 in the amount of $31,200. Enclosed please find a copy of the agreement for your records. If you have any further questions, please call this office at (574) 235-9251. Sincerely, /s/ Hillary Horvath Hillary Horvath, Clerk Enclosures HH EJCDC E-500 Standard Form of Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. AGREEMENT BETWEEN OWNER AND ENGINEER FOR PROFESSIONAL SERVICES Prepared by ENGINEERS JOINT CONTRACT DOCUMENTS COMMITTEE and Issued and Published Jointly by AMERICAN COUNCIL OF ENGINEERING COMPANIES ______________________ ASSOCIATED GENERAL CONTRACTORS OF AMERICA ______________________ AMERICAN SOCIETY OF CIVIL ENGINEERS _______________________ PROFESSIONAL ENGINEERS IN PRIVATE PRACTICE A Practice Division of the NATIONAL SOCIETY OF PROFESSIONAL ENGINEERS This document has important legal consequences; consultation with an attorney is encouraged with respect to its use or modification. This document should be adapted to the particular circumstances of the contemplated Project and the Controlling Laws and Regulations. EJCDC E-500 Standard Form of Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Copyright © 2008 National Society of Professional Engineers 1420 King Street, Alexandria, VA 22314-2794 (703) 684-2882 www.nspe.org American Council of Engineering Companies 1015 15th Street N.W., Washington, DC 20005 (202) 347-7474 www.acec.org American Society of Civil Engineers 1801 Alexander Bell Drive, Reston, VA 20191-4400 (800) 548-2723 www.asce.org Associated General Contractors of America 2300 Wilson Boulevard, Suite 400, Arlington, VA 22201-3308 (703) 548-3118 www.agc.org The copyright for this EJCDC document is owned jointly by the four EJCDC sponsoring organizations and held in trust for their benefit by NSPE. This Agreement has been prepared for use with the Standard General Conditions of the Construction Contract (EJCDC C-700, 2007 Edition). Their provisions are interrelated, and a change in one may necessitate a change in the other. For guidance on the completion and use of this Agreement, see EJCDC User’s Guide to the Owner-Engineer Agreement, EJCDC E-001, 2009 Edition. TABLE OF CONTENTS Page ARTICLE 1 – SERVICES OF ENGINEER .................................................................................................... 1 1.01 Scope ............................................................................................................................................. 1 ARTICLE 2 – OWNER’S RESPONSIBILITIES............................................................................................ 1 2.01 General .......................................................................................................................................... 1 ARTICLE 3 – SCHEDULE FOR RENDERING SERVICES ........................................................................ 2 3.01 Commencement ............................................................................................................................ 2 3.02 Time for Completion .................................................................................................................... 2 ARTICLE 4 – INVOICES AND PAYMENTS ............................................................................................... 2 4.01 Invoices ......................................................................................................................................... 2 4.02 Payments ....................................................................................................................................... 2 ARTICLE 5 – OPINIONS OF COST .............................................................................................................. 3 5.01 Opinions of Probable Construction Cost ..................................................................................... 3 5.02 Designing to Construction Cost Limit ......................................................................................... 3 5.03 Opinions of Total Project Costs ................................................................................................... 3 ARTICLE 6 – GENERAL CONSIDERATIONS ........................................................................................... 3 6.01 Standards of Performance ............................................................................................................ 3 6.02 Design Without Construction Phase Services ............................................................................. 5 6.03 Use of Documents ........................................................................................................................ 5 6.04 Insurance ....................................................................................................................................... 7 6.05 Suspension and Termination ........................................................................................................ 7 6.06 Controlling Law ............................................................................................................................ 9 6.07 Successors, Assigns, and Beneficiaries ........................................................................................ 9 6.08 Dispute Resolution........................................................................................................................ 9 6.09 Environmental Condition of Site................................................................................................ 10 6.10 Indemnification and Mutual Waiver .......................................................................................... 10 6.11 Miscellaneous Provisions ........................................................................................................... 11 ARTICLE 7 – DEFINITIONS ........................................................................................................................ 12 7.01 Defined Terms ............................................................................................................................ 12 ARTICLE 8 – EXHIBITS AND SPECIAL PROVISIONS .......................................................................... 15 8.01 Exhibits Included ........................................................................................................................ 15 8.02 Total Agreement ......................................................................................................................... 15 8.03 Designated Representatives ........................................................................................................ 16 8.04 Engineer's Certifications ............................................................................................................. 16 Page 1 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. AGREEMENT BETWEEN OWNER AND ENGINEER FOR PROFESSIONAL SERVICES Owner and Engineer further agree as follows: ARTICLE 1 – SERVICES OF ENGINEER 1.01 Scope A.Engineer shall provide, or cause to be provided, the services set forth herein and in Exhibit A. ARTICLE 2 – OWNER’S RESPONSIBILITIES 2.01 General A.Owner shall have the responsibilities set forth herein and in Exhibit B. B.Owner shall pay Engineer as set forth in Exhibit C. C.Owner shall be responsible for, and Engineer may rely upon, the accuracy and completeness of all requirements, programs, instructions, reports, data, and other information furnished by Owner to THIS IS AN AGREEMENT effective as of , (“Effective Date”) between Board of Public Works, City of South Bend, Indiana (“Owner”) and Christopher B. Buke Engineering, LLC (“Engineer”). Owner's Project, of which Engineer's services under this Agreement are a part, is generally identified as follows: Angela Boulevard Sidewalk Extension from Twyckenham Drive to SR 23 ("Project"). Engineer's services under this Agreement are generally identified as follows: Preliminary Design for sidewalk extension along Angela Blvd. Engineer’s subconsultant to provide topographic survey and verify R/W. Amendment required for Final Design, Bidding & Negotiation Phase, Construction Phase, etc. 2025December 9 Page 2 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Engineer pursuant to this Agreement. Engineer may use such requirements, programs, instructions, reports, data, and information in performing or furnishing services under this Agreement. ARTICLE 3 – SCHEDULE FOR RENDERING SERVICES 3.01 Commencement A. Engineer is authorized to begin rendering services as of the Effective Date. 3.02 Time for Completion A. Engineer shall complete its obligations within a reasonable time. Specific periods of time for rendering services are set forth or specific dates by which services are to be completed are provided in Exhibit A, and are hereby agreed to be reasonable. B. If, through no fault of Engineer, such periods of time or dates are changed, or the orderly and continuous progress of Engineer’s services is impaired, or Engineer’s services are delayed or suspended, then the time for completion of Engineer’s services, and the rates and amounts of Engineer’s compensation, shall be adjusted equitably. C. If Owner authorizes changes in the scope, extent, or character of the Project, then the time for completion of Engineer’s services, and the rates and amounts of Engineer’s compensation, shall be adjusted equitably. D. Owner shall make decisions and carry out its other responsibilities in a timely manner so as not to delay the Engineer’s performance of its services. E. If Engineer fails, through its own fault, to complete the performance required in this Agreement within the time set forth, as duly adjusted, then Owner shall be entitled, as its sole remedy, to the recovery of direct damages, if any, resulting from such failure. ARTICLE 4 – INVOICES AND PAYMENTS 4.01 Invoices A. Preparation and Submittal of Invoices: Engineer shall prepare invoices in accordance with its standard invoicing practices and the terms of Exhibit C. Engineer shall submit its invoices to Owner on a monthly basis. Invoices are due and payable within 35 days of receipt. 4.02 Payments A. Application to Interest and Principal: Payment will be credited first to any interest owed to Engineer and then to principal. B. Failure to Pay: If Owner fails to make any payment due Engineer for services and expenses within 30 days after receipt of Engineer’s invoice, then: 1. amounts due Engineer will be increased at the rate of 1.0% per month (or the maximum rate of interest permitted by law, if less) from said thirtieth day; and Page 3 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. 2. Engineer may, after giving seven days written notice to Owner, suspend services under this Agreement until Owner has paid in full all non-disputed amounts due for services, expenses, and other related charges. Owner waives any and all claims against Engineer for any such suspension. C. Disputed Invoices: If Owner contests an invoice, Owner shall promptly advise Engineer of the specific basis for doing so, may withhold only that portion so contested, and must pay the undisputed portion. D. Legislative Actions: If after the Effective Date any governmental entity takes a legislative action that imposes taxes, fees, or charges on Engineer’s services or compensation under this Agreement, then the Engineer may invoice such new taxes, fees, or charges as a Reimbursable Expense to which a factor of 1.0 shall be applied. Owner shall reimburse Engineer for the cost of such invoiced new taxes, fees, and charges; such reimbursement shall be in addition to the compensation to which Engineer is entitled under the terms of Exhibit C. ARTICLE 5 – OPINIONS OF COST 5.01 Opinions of Probable Construction Cost A. Engineer’s opinions of probable Construction Cost are to be made on the basis of Engineer’s experience and qualifications and represent Engineer’s best judgment as an experienced and qualified professional generally familiar with the construction industry. However, because Engineer has no control over the cost of labor, materials, equipment, or services furnished by others, or over contractors’ methods of determining prices, or over competitive bidding or market conditions, Engineer cannot and does not guarantee that proposals, bids, or actual Construction Cost will not vary from opinions of probable Construction Cost prepared by Engineer. If Owner requires greater assurance as to probable Construction Cost, Owner must employ an independent cost estimator as provided in Exhibit B. 5.02 Designing to Construction Cost Limit A. If a Construction Cost limit is established between Owner and Engineer, such Construction Cost limit and a statement of Engineer’s rights and responsibilities with respect thereto will be specifically set forth in Exhibit F, “Construction Cost Limit,” to this Agreement. 5.03 Opinions of Total Project Costs A. The services, if any, of Engineer with respect to Total Project Costs shall be limited to assisting the Owner in collating the various cost categories which comprise Total Project Costs. Engineer assumes no responsibility for the accuracy of any opinions of Total Project Costs. ARTICLE 6 – GENERAL CONSIDERATIONS 6.01 Standards of Performance A. Standard of Care: The standard of care for all professional engineering and related services performed or furnished by Engineer under this Agreement will be the care and skill ordinarily used by members of the subject profession practicing under similar circumstances at the same Page 4 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. time and in the same locality. Engineer makes no warranties, express or implied, under this Agreement or otherwise, in connection with Engineer’s services. B. Technical Accuracy: Owner shall not be responsible for discovering deficiencies in the technical accuracy of Engineer’s services. Engineer shall correct deficiencies in technical accuracy without additional compensation, unless such corrective action is directly attributable to deficiencies in Owner-furnished information. C. Consultants: Engineer may employ such Consultants as Engineer deems necessary to assist in the performance or furnishing of the services, subject to reasonable, timely, and substantive objections by Owner. D. Reliance on Others: Subject to the standard of care set forth in Paragraph 6.01.A, Engineer and its Consultants may use or rely upon design elements and information ordinarily or customarily furnished by others, including, but not limited to, specialty contractors, manufacturers, suppliers, and the publishers of technical standards. E. Compliance with Laws and Regulations, and Policies and Procedures: 1. Engineer and Owner shall comply with applicable Laws and regulations. 2. Prior to the Effective Date, Owner provided to Engineer in writing any and all policies and procedures of Owner applicable to Engineer's performance of services under this Agreement. provided to Engineer in writing. Engineer shall comply with such policies and procedures, subject to the standard of care set forth in Paragraph 6.01.A, and to the extent compliance is not inconsistent with professional practice requirements. 3. This Agreement is based on Laws and Regulations and Owner-provided written policies and procedures as of the Effective Date. Changes after the Effective Date to these Laws and Regulations, or to Owner-provided written policies and procedures, may be the basis for modifications to Owner’s responsibilities or to Engineer’s scope of services, times of performance, or compensation. F. Engineer shall not be required to sign any documents, no matter by whom requested, that would result in the Engineer having to certify, guarantee, or warrant the existence of conditions whose existence the Engineer cannot ascertain. Owner agrees not to make resolution of any dispute with the Engineer or payment of any amount due to the Engineer in any way contingent upon the Engineer signing any such documents. G. The general conditions for any construction contract documents prepared hereunder are to be the “Standard General Conditions of the Construction Contract” as prepared by the Engineers Joint Contract Documents Committee (EJCDC C-700, 2007 Edition) unless both parties mutually agree to use other general conditions by specific reference in Exhibit J. H. Engineer shall not at any time supervise, direct, control, or have authority over any contractor work, nor shall Engineer have authority over or be responsible for the means, methods, techniques, sequences, or procedures of construction selected or used by any contractor, or the safety precautions and programs incident thereto, for security or safety at the Site, nor for any Page 5 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. failure of a contractor to comply with Laws and Regulations applicable to such contractor’s furnishing and performing of its work. I. Engineer neither guarantees the performance of any Contractor nor assumes responsibility for any Contractor’s failure to furnish and perform the Work in accordance with the Contract Documents. J. Engineer shall not provide or have any responsibility for surety bonding or insurance-related advice, recommendations, counseling, or research, or enforcement of construction insurance or surety bonding requirements. K. Engineer shall not be responsible for the acts or omissions of any Contractor, Subcontractor, or Supplier, or of any of their agents or employees or of any other persons (except Engineer’s own agents, employees, and Consultants) at the Site or otherwise furnishing or performing any Work; or for any decision made regarding the Contract Documents, or any application, interpretation, or clarification, of the Contract Documents, other than those made by Engineer. L. While at the Site, Engineer's employees and representatives shall comply with the specific applicable requirements of Contractor's and Owner's safety programs of which Engineer has been informed in writing. 6.02 Design Without Construction Phase Services A. Engineer shall be responsible only for those Construction Phase services expressly required of Engineer in Exhibit A, Paragraph A1.05. With the exception of such expressly required services, Engineer shall have no design, Shop Drawing review, or other obligations during construction and Owner assumes all responsibility for the application and interpretation of the Contract Documents, review and response to Contractor claims, contract administration, processing Change Orders, revisions to the Contract Documents during construction, construction surety bonding and insurance requirements, construction observation and review, review of payment applications, and all other necessary Construction Phase engineering and professional services. Owner waives all claims against the Engineer that may be connected in any way to Construction Phase engineering or professional services except for those services that are expressly required of Engineer in Exhibit A, Paragraph A1.05. 6.03 Use of Documents A. The Owner acknowledges the Engineer’s construction documents, including all electronic files, as instruments of professional services. Nevertheless, the final construction documents, including all electronic files, prepared under this agreement shall become the property of the Owner upon completion of services and payment in full of all monies due to the Engineer. The Owner shall not reuse or make any modification to the construction documents without the prior written authorization of the Engineer. All Documents are instruments of service in respect to this Project, and Engineer shall retain an ownership and property interest therein (including the copyright and the right of reuse at the discretion of the Engineer) whether or not the Project is completed. Owner shall not rely in any way on any Document unless it is in printed form, signed or sealed by the Engineer or one of its Consultants. B. Either party to this Agreement may rely that data or information set forth on paper (also known as hard copies) that the party receives from the other party by mail, hand delivery, or facsimile, are Page 6 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. the items that the other party intended to send. Files in electronic media format of text, data, graphics, or other types that are furnished by one party to the other are furnished only for convenience, not reliance by the receiving party. Any conclusion or information obtained or derived from such electronic files will be at the user’s sole risk. If there is a discrepancy between the electronic files and the hard copies, the hard copies govern. If the parties agree to other electronic transmittal procedures, such are set forth in Exhibit J. C. Because data stored in electronic media format can deteriorate or be modified inadvertently or otherwise without authorization of the data’s creator, the party receiving electronic files agrees that it will perform acceptance tests or procedures within 60 days, after which the receiving party shall be deemed to have accepted the data thus transferred. Any transmittal errors detected within the 60-day acceptance period will be corrected by the party delivering the electronic files. D. When transferring documents in electronic media format, the transferring party makes no representations as to long-term compatibility, usability, or readability of such documents resulting from the use of software application packages, operating systems, or computer hardware differing from those used by the documents’ creator. E. Owner may make and retain copies of Documents for information and reference in connection with use on the Project by Owner. Engineer grants Owner a limited license to use the Documents on the Project, extensions of the Project, and for related uses of the Owner, subject to receipt by Engineer of full payment for all services relating to preparation of the Documents and subject to the following limitations: (1) Owner acknowledges that such Documents are not intended or represented to be suitable for use on the Project unless completed by Engineer, or for use or reuse by Owner or others on extensions of the Project, on any other project, or for any other use or purpose, without written verification or adaptation by Engineer; (2) any such use or reuse, or any modification of the Documents, without written verification, completion, or adaptation by Engineer, as appropriate for the specific purpose intended, will be at Owner’s sole risk and without liability or legal exposure to Engineer or to its officers, directors, members, partners, agents, employees, and Consultants; (3) Owner shall indemnify and hold harmless Engineer and its officers, directors, members, partners, agents, employees, and Consultants from all claims, damages, losses, and expenses, including attorneys’ fees, arising out of or resulting from any use, reuse, or modification of the Documents without written verification, completion, or adaptation by Engineer; and (4) such limited license to Owner shall not create any rights in third parties. F. If Engineer at Owner’s request verifies the suitability of the Documents, completes them, or adapts them for extensions of the Project or for any other purpose, then Owner shall compensate Engineer at rates or in an amount to be agreed upon by Owner and Engineer. G. At completion of any survey services and upon payment of monies due the Engineer for those services, the Engineer shall provide the owner with all survey data and drawings, upon which it will become the property of the Owner. H. At completion of any traffic study services and upon payment of monies due the Engineer for those services, the Engineer shall provide the owner with all data and models, upon which it will become the property of the Owner. Page 7 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. I. At completion of any geotechnical or material investigation services and upon payment of monies due the Engineer for those services, the Engineer shall provide the owner with all data, upon which it will become the property of the Owner. 6.04 Insurance A. Engineer shall procure and maintain insurance as set forth in Exhibit G, “Insurance.” Engineer shall cause Owner to be listed as an additional insured on any applicable general liability insurance policy carried by Engineer. B. Owner shall procure and maintain insurance as set forth in Exhibit G, “Insurance.” Owner shall cause Engineer and its Consultants to be listed as additional insureds on any general liability policies and as loss payees on any property insurance policies carried by Owner which are applicable to the Project. C. Owner shall require Contractor to purchase and maintain policies of insurance covering workers' compensation, general liability, property damage (other than to the Work itself), motor vehicle damage and injuries, and other insurance necessary to protect Owner's and Engineer's interests in the Project. Owner shall require Contractor to cause Engineer and its Consultants to be listed as additional insureds with respect to such liability and other insurance purchased and maintained by Contractor for the Project. D. Owner and Engineer shall each deliver to the Owner other certificates of insurance evidencing the coverages indicated in Exhibit G. Such certificates shall be furnished prior to commencement of Engineer’s services and at renewals thereafter during the life of the Agreement. E. All policies of property insurance relating to the Project shall contain provisions to the effect that Engineer’s and its Consultants’ interests are covered and that in the event of payment of any loss or damage the insurers will have no rights of recovery against Engineer or its Consultants, or any insureds, additional insureds, or loss payees thereunder. F. All policies of insurance shall contain a provision or endorsement that the coverage afforded will not be canceled or reduced in limits by endorsement, and that renewal will not be refused, until at least 30 days prior written notice has been given to Owner and Engineer and to each other additional insured (if any) to which a certificate of insurance has been issued. G. At any time, Owner may request that Engineer or its Consultants, at Owner’s sole expense, provide additional insurance coverage, increased limits, or revised deductibles that are more protective than those specified in Exhibit G. If so requested by Owner, and if commercially available, Engineer shall obtain and shall require its Consultants to obtain such additional insurance coverage, different limits, or revised deductibles for such periods of time as requested by Owner, and Exhibit G will be supplemented to incorporate these requirements. 6.05 Suspension and Termination A. Suspension: 1. By Owner: Owner may suspend the Project for up to 90 days upon seven days written notice to Engineer. Page 8 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. 2. By Engineer: Engineer may, after giving seven days written notice to Owner, suspend services under this Agreement if Engineer's performance has been substantially delayed through no fault of Engineer. B. Termination: The obligation to provide further services under this Agreement may be terminated: 1. For cause, a. By either party upon 30 days written notice in the event of substantial failure by the other party to perform in accordance with the terms hereof through no fault of the terminating party. b. By Engineer: 1) upon seven days written notice if Owner demands that Engineer furnish or perform services contrary to Engineer’s responsibilities as a licensed professional; or 2) upon seven days written notice if the Engineer’s services for the Project are delayed or suspended for more than 90 days for reasons beyond Engineer’s control. 3) Engineer shall have no liability to Owner on account of such termination. c. Notwithstanding the foregoing, this Agreement will not terminate under Paragraph 6.05.B.1.a if the party receiving such notice begins, within seven days of receipt of such notice, to correct its substantial failure to perform and proceeds diligently to cure such failure within no more than 30 days of receipt thereof; provided, however, that if and to the extent such substantial failure cannot be reasonably cured within such 30 day period, and if such party has diligently attempted to cure the same and thereafter continues diligently to cure the same, then the cure period provided for herein shall extend up to, but in no case more than, 60 days after the date of receipt of the notice. 2. For convenience, a. By Owner effective upon Engineer’s receipt of notice from Owner. C. Effective Date of Termination: The terminating party under Paragraph 6.05.B may set the effective date of termination at a time up to 30 days later than otherwise provided to allow Engineer to demobilize personnel and equipment from the Site, to complete tasks whose value would otherwise be lost, to prepare notes as to the status of completed and uncompleted tasks, and to assemble Project materials in orderly files. D. Payments Upon Termination: 1. In the event of any termination under Paragraph 6.05, Engineer will be entitled to invoice Owner and to receive full payment for all services performed or furnished in accordance with Page 9 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. this Agreement and all Reimbursable Expenses incurred through the effective date of termination. Upon making such payment, Owner shall have the limited right to the use of Documents, at Owner’s sole risk, subject to the provisions of Paragraph 6.03.E. 2. In the event of termination by Owner for convenience or by Engineer for cause, Engineer shall be entitled, in addition to invoicing for those items identified in Paragraph 6.05.D.1, to invoice Owner and to payment of a reasonable amount for services and expenses directly attributable to termination, both before and after the effective date of termination, such as reassignment of personnel, costs of terminating contracts with Engineer’s Consultants, and other related close-out costs, using methods and rates for Additional Services as set forth in Exhibit C. 6.06 Controlling Law A. This Agreement is to be governed by the law of the state or jurisdiction in which the Project is located. 6.07 Successors, Assigns, and Beneficiaries A. Owner and Engineer are hereby bound and the successors, executors, administrators, and legal representatives of Owner and Engineer (and to the extent permitted by Paragraph 6.07.B the assigns of Owner and Engineer) are hereby bound to the other party to this Agreement and to the successors, executors, administrators and legal representatives (and said assigns) of such other party, in respect of all covenants, agreements, and obligations of this Agreement. B. Neither Owner nor Engineer may assign, sublet, or transfer any rights under or interest (including, but without limitation, moneys that are due or may become due) in this Agreement without the written consent of the other, except to the extent that any assignment, subletting, or transfer is mandated or restricted by law. Unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under this Agreement. C. Unless expressly provided otherwise in this Agreement: 1. Nothing in this Agreement shall be construed to create, impose, or give rise to any duty owed by Owner or Engineer to any Contractor, Subcontractor, Supplier, other individual or entity, or to any surety for or employee of any of them. 2. All duties and responsibilities undertaken pursuant to this Agreement will be for the sole and exclusive benefit of Owner and Engineer and not for the benefit of any other party. 3. Owner agrees that the substance of the provisions of this Paragraph 6.07.C shall appear in the Contract Documents. 6.08 Dispute Resolution A. Owner and Engineer agree to negotiate all disputes between them in good faith for a period of 30 days from the date of notice prior to invoking the procedures of Exhibit H or other provisions of this Agreement, or exercising their rights under law. Page 10 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. B. If the parties fail to resolve a dispute through negotiation under Paragraph 6.08.A, then either or both may invoke the procedures of Exhibit H. If Exhibit H is not included, or if no dispute resolution method is specified in Exhibit H, then the parties may exercise their rights under law. 6.09 Environmental Condition of Site A. Owner has disclosed to Engineer in writing the existence of all known and suspected Asbestos, PCBs, Petroleum, Hazardous Waste, Radioactive Material, hazardous substances, and other Constituents of Concern located at or near the Site, including type, quantity, and location. B. Owner represents to Engineer that to the best of its knowledge no Constituents of Concern, other than those disclosed in writing to Engineer, exist at the Site. C. If Engineer encounters or learns of an undisclosed Constituent of Concern at the Site, then Engineer shall notify (1) Owner and (2) appropriate governmental officials if Engineer reasonably concludes that doing so is required by applicable Laws or Regulations. D. It is acknowledged by both parties that Engineer’s scope of services does not include any services related to Constituents of Concern. If Engineer or any other party encounters an undisclosed Constituent of Concern, or if investigative or remedial action, or other professional services, are necessary with respect to disclosed or undisclosed Constituents of Concern, then Engineer may, at its option and without liability for consequential or any other damages, suspend performance of services on the portion of the Project affected thereby until Owner: (1) retains appropriate specialist consultants or contractors to identify and, as appropriate, abate, remediate, or remove the Constituents of Concern; and (2) warrants that the Site is in full compliance with applicable Laws and Regulations. E. If the presence at the Site of undisclosed Constituents of Concern adversely affects the performance of Engineer’s services under this Agreement, then the Engineer shall have the option of (1) accepting an equitable adjustment in its compensation or in the time of completion, or both; or (2) terminating this Agreement for cause on 30 days notice. F. Owner acknowledges that Engineer is performing professional services for Owner and that Engineer is not and shall not be required to become an "owner" “arranger,” “operator,” “generator,” or “transporter” of hazardous substances, as defined in the Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA), as amended, which are or may be encountered at or near the Site in connection with Engineer’s activities under this Agreement. 6.10 Indemnification and Mutual Waiver A. Indemnification by Engineer: To the fullest extent permitted by law, Engineer shall indemnify and hold harmless Owner, and Owner’s officers, directors, members, partners, agents, consultants, and employees from reasonable claims, costs, losses, and damages arising out of or relating to the Project, provided that any such claim, cost, loss, or damage is attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom, but only to the extent caused by any negligent act or omission of Engineer or Engineer’s officers, directors, members, partners, agents, Page 11 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. employees, or Consultants. This indemnification provision is subject to and limited by the provisions, if any, agreed to by Owner and Engineer in Exhibit I, “Limitations of Liability." B. Indemnification by Owner: Owner shall indemnify and hold harmless Engineer and its officers, directors, members, partners, agents, employees, and Consultants as required by Laws and Regulations and to the extent (if any) required in Exhibit I, Limitations of Liability. C. Environmental Indemnification: To the fullest extent permitted by law, Owner shall indemnify and hold harmless Engineer and its officers, directors, members, partners, agents, employees, and Consultants from and against any and all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys and other professionals, and all court, arbitration, or other dispute resolution costs) caused by, arising out of, relating to, or resulting from a Constituent of Concern at, on, or under the Site, provided that (1) any such claim, cost, loss, or damage is attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom, and (2) nothing in this paragraph shall obligate Owner to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence or willful misconduct. D. Percentage Share of Negligence: To the fullest extent permitted by law, a party’s total liability to the other party and anyone claiming by, through, or under the other party for any cost, loss, or damages caused in part by the negligence of the party and in part by the negligence of the other party or any other negligent entity or individual, shall not exceed the percentage share that the party’s negligence bears to the total negligence of Owner, Engineer, and all other negligent entities and individuals. E. Mutual Waiver: To the fullest extent permitted by law, Owner and Engineer waive against each other, and the other’s employees, officers, directors, members, agents, insurers, partners, and consultants, any and all claims for or entitlement to special, incidental, indirect, or consequential damages arising out of, resulting from, or in any way related to the Project. 6.11 Miscellaneous Provisions A. Notices: Any notice required under this Agreement will be in writing, addressed to the appropriate party at its address on the signature page and given personally, by facsimile, by registered or certified mail postage prepaid, or by a commercial courier service. All notices shall be effective upon the date of receipt. B. Survival: All express representations, waivers, indemnifications, and limitations of liability included in this Agreement will survive its completion or termination for any reason. C. Severability: Any provision or part of the Agreement held to be void or unenforceable under any Laws or Regulations shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon Owner and Engineer, which agree that the Agreement shall be reformed to replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provision. Page 12 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. D. Waiver: A party’s non-enforcement of any provision shall not constitute a waiver of that provision, nor shall it affect the enforceability of that provision or of the remainder of this Agreement. E. Accrual of Claims: To the fullest extent permitted by law, all causes of action arising under this Agreement shall be deemed to have accrued, and all statutory periods of limitation shall commence, no later than the date of Substantial Completion. ARTICLE 7 – DEFINITIONS 7.01 Defined Terms A. Wherever used in this Agreement (including the Exhibits hereto) terms (including the singular and plural forms) printed with initial capital letters have the meanings indicated in the text above, in the exhibits, or in the following provisions: 1. Additional Services – The services to be performed for or furnished to Owner by Engineer in accordance with Part 2 of Exhibit A of this Agreement. 2. Agreement – This written contract for professional services between Owner and Engineer, including all exhibits identified in Paragraph 8.01 and any duly executed amendments. 3. Asbestos – Any material that contains more than one percent asbestos and is friable or is releasing asbestos fibers into the air above current action levels established by the United States Occupational Safety and Health Administration. 4. Basic Services – The services to be performed for or furnished to Owner by Engineer in accordance with Part 1 of Exhibit A of this Agreement. 5. Construction Contract – The entire and integrated written agreement between Owner and Contractor concerning the Work. 6. Construction Cost – The cost to Owner of those portions of the entire Project designed or specified by Engineer. Construction Cost does not include costs of services of Engineer or other design professionals and consultants; cost of land or rights-of-way, or compensation for damages to properties; Owner’s costs for legal, accounting, insurance counseling or auditing services; interest or financing charges incurred in connection with the Project; or the cost of other services to be provided by others to Owner pursuant to Exhibit B of this Agreement. Construction Cost is one of the items comprising Total Project Costs. 7. Constituent of Concern – Any substance, product, waste, or other material of any nature whatsoever (including, but not limited to, Asbestos, Petroleum, Radioactive Material, and PCBs) which is or becomes listed, regulated, or addressed pursuant to (a) the Comprehensive Environmental Response, Compensation and Liability Act, 42 U.S.C. §§9601 et seq. (“CERCLA”); (b) the Hazardous Materials Transportation Act, 49 U.S.C. §§1801 et seq.; (c) the Resource Conservation and Recovery Act, 42 U.S.C. §§6901 et seq. (“RCRA”); (d) the Toxic Substances Control Act, 15 U.S.C. §§2601 et seq.; (e) the Clean Water Act, 33 U.S.C. §§1251 et seq.; (f) the Clean Air Act, 42 U.S.C. §§7401 et Page 13 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. seq.; and (g) any other federal, state, or local statute, law, rule, regulation, ordinance, resolution, code, order, or decree regulating, relating to, or imposing liability or standards of conduct concerning, any hazardous, toxic, or dangerous waste, substance, or material. 8. Consultants – Individuals or entities having a contract with Engineer to furnish services with respect to this Project as Engineer’s independent professional associates and consultants; subcontractors; or vendors. 9. Contract Documents – Those items so designated in the Construction Contract, including the Drawings, Specifications, construction agreement, and general and supplementary conditions. Only printed or hard copies of the items listed in the Construction Contract are Contract Documents. Approved Shop Drawings, other Contractor submittals, and the reports and drawings of subsurface and physical conditions are not Contract Documents. 10. Contractor – The entity or individual with which Owner has entered into a Construction Contract. 11. Documents – Data, reports, Drawings, Specifications, Record Drawings, and other deliverables, whether in printed or electronic media format, provided or furnished in appropriate phases by Engineer to Owner pursuant to this Agreement. 12. Drawings – That part of the Contract Documents prepared or approved by Engineer which graphically shows the scope, extent, and character of the Work to be performed by Contractor. Shop Drawings are not Drawings as so defined. 13. Effective Date – The date indicated in this Agreement on which it becomes effective, but if no such date is indicated, the date on which this Agreement is signed and delivered by the last of the parties to sign and deliver. 14. Engineer – The individual or entity named as such in this Agreement. 15. Hazardous Waste – The term Hazardous Waste shall have the meaning provided in Section 1004 of the Solid Waste Disposal Act (42 USC Section 6903) as amended from time to time. 16. Laws and Regulations; Laws or Regulations – Any and all applicable laws, rules, regulations, ordinances, codes, and orders of any and all governmental bodies, agencies, authorities, and courts having jurisdiction. 17. Owner – The individual or entity with which Engineer has entered into this Agreement and for which the Engineer's services are to be performed. Unless indicated otherwise, this is the same individual or entity that will enter into any Construction Contracts concerning the Project. 18. PCBs – Polychlorinated biphenyls. 19. Petroleum – Petroleum, including crude oil or any fraction thereof which is liquid at standard conditions of temperature and pressure (60 degrees Fahrenheit and 14.7 pounds per square inch absolute), such as oil, petroleum, fuel oil, oil sludge, oil refuse, gasoline, kerosene, and oil mixed with other non-hazardous waste and crude oils. Page 14 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. 20. Project – The total construction of which the Work to be performed under the Contract Documents may be the whole, or a part. 21. Radioactive Material – Source, special nuclear, or byproduct material as defined by the Atomic Energy Act of 1954 (42 USC Section 2011 et seq.) as amended from time to time. 22. Record Drawings – Drawings depicting the completed Project, prepared by Engineer as an Additional Service and based solely on Contractor's record copy of all Drawings, Specifications, addenda, change orders, work change directives, field orders, and written interpretations and clarifications, as delivered to Engineer and annotated by Contractor to show changes made during construction. 23. Reimbursable Expenses – The expenses incurred directly by Engineer in connection with the performing or furnishing of Basic and Additional Services for the Project. 24. Resident Project Representative – The authorized representative of Engineer assigned to assist Engineer at the Site during the Construction Phase. As used herein, the term Resident Project Representative or "RPR" includes any assistants or field staff of Resident Project Representative agreed to by Owner. The duties and responsibilities of the Resident Project Representative, if any, are as set forth in Exhibit D. 25. Samples – Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and which establish the standards by which such portion of the Work will be judged. 26. Shop Drawings – All drawings, diagrams, illustrations, schedules, and other data or information which are specifically prepared or assembled by or for Contractor and submitted by Contractor to illustrate some portion of the Work. 27. Site – Lands or areas to be indicated in the Contract Documents as being furnished by Owner upon which the Work is to be performed, including rights-of-way and easements for access thereto, and such other lands furnished by Owner which are designated for the use of Contractor. 28. Specifications – That part of the Contract Documents consisting of written technical descriptions of materials, equipment, systems, standards, and workmanship as applied to the Work and certain administrative details applicable thereto. 29. Subcontractor – An individual or entity having a direct contract with Contractor or with any other Subcontractor for the performance of a part of the Work at the Site. 30. Substantial Completion – The time at which the Work (or a specified part thereof) has progressed to the point where, in the opinion of Engineer, the Work (or a specified part thereof) is sufficiently complete, in accordance with the Contract Documents, so that the Work (or a specified part thereof) can be utilized for the purposes for which it is intended. The terms “substantially complete” and “substantially completed” as applied to all or part of the Work refer to Substantial Completion thereof. Page 15 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. 31. Supplier – A manufacturer, fabricator, supplier, distributor, materialman, or vendor having a direct contract with Contractor or with any Subcontractor to furnish materials or equipment to be incorporated in the Work by Contractor or Subcontractor. 32. Total Project Costs – The sum of the Construction Cost, allowances for contingencies, and the total costs of services of Engineer or other design professionals and consultants, together with such other Project-related costs that Owner furnishes for inclusion, including but not limited to cost of land, rights-of-way, compensation for damages to properties, Owner’s costs for legal, accounting, insurance counseling and auditing services, interest and financing charges incurred in connection with the Project, and the cost of other services to be provided by others to Owner pursuant to Exhibit B of this Agreement. 33. Work – The entire construction or the various separately identifiable parts thereof required to be provided under the Contract Documents. Work includes and is the result of performing or providing all labor, services, and documentation necessary to produce such construction, and furnishing, installing, and incorporating all materials and equipment into such construction, all as required by the Contract Documents. ARTICLE 8 – EXHIBITS AND SPECIAL PROVISIONS 8.01 Exhibits Included: A. Exhibit A, Engineer’s Services. B. Exhibit B, Owner’s Responsibilities. C. Exhibit C, Payments to Engineer for Services and Reimbursable Expenses. D. Exhibit D, Duties, Responsibilities and Limitations of Authority of Resident Project Representative. NOT INCLUDED E. Exhibit E, Notice of Acceptability of Work. NOT INCLUDED F. Exhibit F, Construction Cost Limit. NOT INCLUDED G. Exhibit G, Insurance. H. Exhibit H, Dispute Resolution. NOT INCLUDED I. Exhibit I, Limitations of Liability. J. Exhibit J, Special Provisions. NOT INCLUDED K. Exhibit K, Amendment to Owner-Engineer Agreement. NOT INCLUDED 8.02 Total Agreement: A. This Agreement, (together with the exhibits identified above) constitutes the entire agreement between Owner and Engineer and supersedes all prior written or oral understandings. This Page 16 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Agreement may only be amended, supplemented, modified, or canceled by a duly executed written instrument based on the format of Exhibit K to this Agreement. 8.03 Designated Representatives: A. With the execution of this Agreement, Engineer and Owner shall designate specific individuals to act as Engineer’s and Owner’s representatives with respect to the services to be performed or furnished by Engineer and responsibilities of Owner under this Agreement. Such an individual shall have authority to transmit instructions, receive information, and render decisions relative to the Project on behalf of the respective party whom the individual represents. 8.04 Engineer's Certifications: A. Engineer certifies that it has not engaged in corrupt, fraudulent, or coercive practices in competing for or in executing the Agreement. For the purposes of this Paragraph 8.04: 1. "corrupt practice" means the offering, giving, receiving, or soliciting of any thing of value likely to influence the action of a public official in the selection process or in the Agreement execution; 2. "fraudulent practice" means an intentional misrepresentation of facts made (a) to influence the selection process or the execution of the Agreement to the detriment of Owner, or (b) to deprive Owner of the benefits of free and open competition; 3. "coercive practice" means harming or threatening to harm, directly or indirectly, persons or their property to influence their participation in the selection process or affect the execution of the Agreement. Page 17 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. IN WITNESS WHEREOF, the parties hereto have executed this Agreement, the Effective Date of which is indicated on page 1. Owner: Engineer: City of South Bend, Indiana Christpher B. Burke Engineering, LLC By: By: Jon D. Stolz, PE Title: Buyer Title: Managing Vice President Date: November 26, 2025 Engineer License or Firm's Certificate No. 45-3940525 State of: Indiana Address for giving notices: Address for giving notices: 215 S Dr Martin Luther King Jr Blvd South Bend, Indiana 46601 220 W Colfax Avenue, Suite 700 South Bend, IN 46601 Designated Representative (Paragraph 8.03.A): Designated Representative (Paragraph 8.03.A): Abigail Magas, P.E. Andy Gebhard, PE Title: City Engineer Title: Assistant Director Northern Indiana Phone Number: (574) 235-9206 Phone Number: (574) 282-8001 Facsimile Number: (574) 235-9171 Facsimile Number: N/A E-Mail Address: amagas@southbendin.gov E-Mail Address: agebhard@cbbel-in.com December 9, 2025 Page 1 (Exhibit A – Engineer’s Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. This is EXHIBIT A, consisting of 12 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated , . Engineer’s Services Article 1 of the Agreement is supplemented to include the following agreement of the parties. Engineer shall provide Basic and Additional Services as set forth below. PART 1 – BASIC SERVICES A1.01 Study and Report Phase A. Engineer shall: 1. Consult with Owner to define and clarify Owner’s requirements for the Project and available data. 2. Advise Owner of any need for Owner to provide data or services of the types described in Exhibit B which are not part of Engineer’s Basic Services. 3. Identify, consult with, and analyze requirements of governmental authorities having jurisdiction to approve the portions of the Project designed or specified by Engineer, including but not limited to mitigating measures identified in the environmental assessment. 4. Identify and evaluate alternate solutions available to Owner and, after consultation with Owner, recommend to Owner those solutions which in Engineer’s judgment meet Owner’s requirements for the Project. 5. Prepare a report (the “Report”) which will, as appropriate, contain schematic layouts, sketches, and conceptual design criteria with appropriate exhibits to indicate the agreed-to requirements, considerations involved, and those alternate solutions available to Owner which Engineer recommends. For each recommended solution Eng 6. ineer will provide the following, which will be separately itemized: opinion of probable Construction Cost; proposed allowances for contingencies; the estimated total costs of design 7. , professional, and related services to be provided by Engineer and its Consultants; and, on the basis of information furnished by Owner, a summary of allowances for other items and services included within the definition of Total Project Costs. 8. Perform or provide the following additional Study and Report Phase tasks or deliverables: N/A 9. Furnish review copies of the Report and any other deliverables to Owner within calendar days of the Effective Date and review it with Owner. Within 14 calendar days of receipt, Owner shall submit to Engineer any comments regarding the Report and any other deliverables. Page 2 (Exhibit A – Engineer’s Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. 10. Revise the Report and any other deliverables in response to Owner’s comments, as appropriate, and furnish copies of the revised Report and any other deliverables to the Owner within calendar days of receipt of Owner’s comments. B. Engineer’s services under the Study and Report Phase will be considered complete on the date when the revised Report and any other deliverables have been delivered to Owner. A1.02 Preliminary Design Phase A. After acceptance by Owner of the Report and any other deliverables, selection by Owner of a recommended solution and indication of any specific modifications or changes in the scope, extent, character, or design requirements of the Project desired by Owner, and upon written authorization from Owner, Engineer shall: 1. Prepare Preliminary Design Phase documents consisting of final design criteria, preliminary drawings, outline specifications, and written descriptions of the Project. 2. Provide necessary field surveys and topographic and utility mapping for design purposes. Utility mapping will be based upon information obtained from utility owners. 3. Advise Owner if additional reports, data, information, or services of the types described in Exhibit B are necessary and assist Owner in obtaining such reports, data, information, or services. 4. Based on the information contained in the Preliminary Design Phase documents, prepare a revised opinion of probable Construction Cost, and assist Owner in collating the various cost categories which comprise Total Project Costs. 5. Perform or provide the following additional Preliminary Design Phase tasks or deliverables: See attached Professional Service Agreement. 6. Furnish 2 review copies of the Preliminary Design Phase documents and any other deliverables to Owner within 60 calendar days of authorization to proceed with this phase, and review them with Owner. Within 14 calendar days of receipt, Owner shall submit to Engineer any comments regarding the Preliminary Design Phase documents and any other deliverables. 7. Revise the Preliminary Design Phase documents and any other deliverables in response to Owner’s comments, as appropriate, and furnish to Owner 2 copies of the revised Preliminary Design Phase documents, revised opinion of probable Construction Cost, and any other deliverables within 14 calendar days after receipt of Owner’s comments. B. Engineer’s services under the Preliminary Design Phase will be considered complete on the date when the revised Preliminary Design Phase documents, revised opinion of probable Construction Cost, and any other deliverables have been delivered to Owner. Page 3 (Exhibit A – Engineer’s Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. A1.03 Final Design Phase A. After acceptance by Owner of the Preliminary Design Phase documents, revised opinion of probable Construction Cost as determined in the Preliminary Design Phase, and any other deliverables subject to any Owner-directed modifications or changes in the scope, extent, character, or design requirements of or for the Project, and upon written authorization from Owner, Engineer shall: 1. Prepare final Drawings and Specifications indicating the scope, extent, and character of the Work to be performed and furnished by 2. Contractor. 3. Provide technical criteria, written descriptions, and design data for Owner’s use in filing applications for permits from or approvals of governmental authorities having jurisdiction to review or approve the final design of the Project; assist Owner in consultations with such authorities; and revise the Drawings and Specifications in response to directives from such authorities. 4. Advise Owner of any adjustments to the opinion of probable Construction Cost known to Engineer. 5. Perform or provide the following additional Final Design Phase tasks or deliverables: 6. Prepare and furnish bidding documents for review by Owner, its legal counsel, and other advisors, and assist Owner in the preparation of other related documents. Within days of receipt, Owner shall submit to Engineer any comments and, subject to the provisions of Paragraph 6.01.G, instructions for revisions. 7. Revise the bidding documents in accordance with comments and instructions from the Owner, as appropriate, and submit final copies of the bidding documents, a revised opinion of probable Construction Cost, and any other deliverables to Owner within calendar days after receipt of Owner’s comments and instructions. B. Engineer’s services under the Final Design Phase will be considered complete on the date when the submittals required by Paragraph A1.03.A.6 have been delivered to Owner. C. In the event that the Work designed or specified by Engineer is to be performed or furnished under more than one prime contract, or if Engineer’s services are to be separately sequenced with the work of one or more prime Contractors (such as in the case of fast-tracking), Owner and Engineer shall, prior to commencement of the Final Design D. Phase, develop a schedule for performance of Engineer’s services during the Final Design, Bidding or Negotiating, Construction, and Post-Construction Phases in order to se E. quence and coordinate properly such services as are applicable to the work under such separate prime contracts. This schedule is to be prepared and included in or become an amendment to Exhibit A whether or not the work under such contracts is to proceed concurrently. F. The number of prime contracts for Work designed or specified by Engineer upon which the Engineer’s compensation has been established under this Agreement is . If more prime Page 4 (Exhibit A – Engineer’s Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. contracts are awarded, Engineer shall be entitled to an equitable increase in its compensation under this Agreement. A1.04 Bidding or Negotiating Phase A. After acceptance by Owner of the bidding documents and the most recent opinion of probable Construction Cost as determined in the Final Design Phase, and upon written authorization by Owner to proceed, Engineer shall: 1. Assist Owner in advertising for and obtaining bids or proposals for the Work and, where applicable, maintain a record of prospective bidders to whom Bidding Documents have been issued, attend pre-bid conferences, if any, and receive and process contractor deposits or charges for the bidding do 2. cuments. 3. Issue addenda as appropriate to clarify, correct, or change the bidding documents. 4. Provide information or assistance needed by Owner in the course of any negotiations with prospective contractors. 5. Consult with Owner as to the acceptability of subcontractors, suppliers, and other individuals and entities proposed by prospective contractors for those portions of the Work as to which such acceptability is required by the bidding documents. 6. If bidding documents require, the Engineer shall evaluate and determine the acceptability of "or equals" and substitute materials and equipment proposed by bidders, but subject to the provisions of paragraph A2.02.A.2 of this Exhibit A. 7. Attend the Bid opening, prepare Bid tabulation sheets, and assist Owner in evaluating Bids or proposals and in assembling and awarding contracts for the Work. 8. Perform or provide the following additional Bidding or Negotiating Phase tasks or deliverables: [here list any such tasks or deliverables] B. The Bidding or Negotiating Phase will be considered complete upon commencement of the Construction Phase or upon cessation of negotiations with prospective contractors (except as may be required if Exhibit F is a part of this Agreement). A1.05 Construction Phase A. Upon successful completion of the Bidding and Negotiating Phase, and upon written authorization from Owner, Engineer shall: 1. General Administration of Construction Contract: Consult with Owner and act as Owner’s representative as provided in the Construction Contract. The extent and limitations of the duties, responsibilities, and authority of Engineer as assigned in the Construction Contract shall not be modified, except as Engineer may otherwise agree in writing. All of Owner’s instructions to Contractor will be issued through Engineer, which shall have authority to act Page 5 (Exhibit A – Engineer’s Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. on behalf of Owner in dealings with Contractor to the extent provided in this Agreement and the Const 2. ru 3. ction Contract except as otherwise provided in writing. 4. DELETED 5. Selecting Independent Testing Laboratory: Assist Owner in the selection of an independent testing laboratory to perform the services identified in Exhibit B, Paragraph B2.01.0. 6. Pre-Construction Conference: Participate in a Pre-Construction Conference prior to commencement of Work at the Site. 7. Schedules: Receive, review, and determine the acceptability of any and all schedules that Contractor is required to submit to Engineer, including the Progress Schedule, Schedule of Submittals, and Schedule of Values. 8. Baselines and Benchmarks: As appropriate, establish baselines and benchmarks for locating the Work which in Engineer’s judgment are necessary to enable Contractor to proceed. 9. Visits to Site and Observation of Construction: In connection with observations of Contractor’s Work while it is in progress: a. Make visits to the Site at intervals appropriate to the various stages of construction, as Engineer deems necessary, to observe as an experienced and qualified design professional the progress of Contractor’s executed Work. Such visits and observations by Engineer, and the Resident Project Representative, if any, are not intended to be exhaustive or to extend to every aspect of Contractor’s Work in progress or to involve detailed inspections of Contractor’s Work in progress beyond the responsibilities specifically assigned to Engineer in this Agreement and the Contract Documents, but rather are to be limited to spot checking, selective sampling, and similar methods of general observation of the Work based on Engineer’s exercise of professional judgment, as assisted by the Resident Project Representative, if any. Based on information obtained during such visits and observations, Engineer will determine in general if the Work is p b. roceeding in accordance with the Contract Documents, and Engineer shall keep Own c. er informed of the progress of the Work. d. The purpose of Engineer’s visits to, and representation by the Resident Project Representative, if any, at the Site, will be to enable Engineer to better carry out the duties and responsibilities assigned to and undertaken by Engineer during the Construction Phase, and, in addition, by the exercise of Engineer’s efforts as an experienced and qualified design professional, to provide for Owner a greater degree of confidence that the completed Work will conform in general to the Contract Documents and that Contractor has implemented and maintained the integrity of the design concept of the completed Project as a functioning whole as indicated in the Page 6 (Exhibit A – Engineer’s Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Contract Documents. Engineer shall not, during such visits or as a result of such observations of Contractor’s Work in progress, supervise, direct, or have control over Contractor’s Work, nor shall Engineer have authority over or responsibility for the means, methods, techniques, sequences, or procedures of construction sele e. cted or used by Contractor, for security f. or safety at the Site, for safety precautions and programs incident to Contractor’s Work, nor for any failure of Contractor to comply with Laws and Regulations applicable to Contractor’s furnishing and performing the Work. Accordingly, Engineer neither guarantees the performance of any Contractor nor assumes responsibility for any Contractor’s failure to furnish or perform the Work in accordance with the Contract Documents. 10. Defective Work: Reject Work if, on the basis of Engineer’s observations, Engineer believes that such Work (a) is defective under the standards set forth in the Contract Documents, (b) will not produce a completed Project that conforms to the Contract Documents, or (c) will imperil the integrity of the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. 11. Clarifications and Interpretations; Field Orders: Issue necessary clarifications and interpretations of the Contract Documents as appropriate to the orderly completion of Contractor’s work. Such clarifications and interpretations will be consistent with the intent of and reasonably inferable from the Contract Documents. Subject to any limitations in the Contract Documents, Engineer may issue field orders authorizing minor variations in the Work from the requirements of the Contract Documents. 12. Change Orders and Work Change Directives: Recommend change orders and work change directives to Owner, as appropriate, and prepare change orders and work change directives as required. 13. Shop Drawings and Samples: Review and approve or take other appropriate action in respect to Shop Drawings and Samples and other data which Contractor is required to submit, but only for conformance with the information given in the Contract Documents and compatibility with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. Such reviews and approvals or other action will not extend to means, methods, techniques, sequences, or procedures of construction or to safety precautio 14. n 15. s and programs incident thereto. Engineer shall meet any Contractor’s submittal schedule that Engineer has accepted. 16. Substitutes and “or-equal”: Evaluate and determine the acceptability of substitute or “or- equal” materials and equipment proposed by Contractor, but subject to the provisions of Paragraph A2.02.A.2 of this Exhibit A. 17. Inspections and Tests: Require such special inspections or tests of Contractor’s work as deemed reasonably necessary, and receive and review all certificates of inspections, tests, and approvals required by Laws and Regulations or the Contract Documents. Engineer’s review of such certificates will be for the purpose of determining that the results certified Page 7 (Exhibit A – Engineer’s Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. indicate compliance with the Contract Documents and will not constitute an independent evaluation that the content or procedures of such inspections, tests, or approvals c 18. o 19. mply with the requirements of the Contract Documents. Engineer shall be entitled to rely on the results of such tests. 20. Disagreements between Owner and Contractor: Render formal written decisions on all duly submitted issues relating to the acceptability of Contractor’s work or the interpretation of the requirements of the Contract Documents pertaining to the execution, performance, or progress of Contractor’s Work; review each duly submitted Claim by Owner or Contractor, and in writing either deny such Claim in whole or in part, approve such Claim, or decline to resolve such Claim if Engineer in its discretion concludes that to do so would be inappropriate. In r 21. e 22. ndering such decisions, Engineer shall be fair and not show partiality to Owner or Contractor and shall not be liable in connection with any decision rendered in good faith in such capacity. 23. Applications for Payment: Based on Engineer’s observations as an experienced and qualified design professional and on review of Applications for Payment and accompanying supporting documentation: a. Determine the amounts that Engineer recommends Contractor be paid. Such recommendations of payment will be in writing and will constitute Engineer’s representation to Owner, based on such observations and review, that, to the best of Engineer’s knowledge, information and belief, Contractor’s Work has progressed to the point indicated, the Work is generally in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning whole prior to or upon Substantial Completion, to the results of any subsequent tests called for in the Contract Documents, and to any other qualifications stated in the recommendation), and the conditions precedent to Contractor’s being entitled to such payment appear to have been fulfilled in so far as it is Engineer’s responsibility to observe Contractor’s Work. In the case of unit price b. work, Engineer’s recommendations of payment will include final determinations of quantities and classifications of Contractor’s Work (subject to any subsequent adjustments c. allowed by the Contract Documents). d. By recommending any payment, Engineer shall not thereby be deemed to have represented that observations made by Engineer to check the quality or quantity of Contractor’s Work as it is performed and furnished have been exhaustive, extended to every aspect of Contractor’s Work in progress, or involved detailed inspections of the Work beyond the responsibilities specifically assigned to Engineer in this Agreement and the Contract Documents. Neither Engineer’s review of Contractor’s Work for the purposes of recommending payments nor Engineer’s recommendation of any payment including final payment will impose on Engineer responsibility to supervise, direct, or control Contractor’s Work in progress or for the means, methods, techniques, sequences, or procedures of construction or safety precautions or programs incident Page 8 (Exhibit A – Engineer’s Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. thereto, or Contractor’s compliance with Laws and Regulations applicable to Contractor’s furnishing and performing the Work. It will also not impose responsibi e. lity on Engineer to make any examinati f. on to ascertain how or for what purposes Contractor has used the moneys paid on account of the Contract Price, or to determine that title to any portion of the Work in progress, materials, or equipment has passed to Owner free and clear of any liens, claims, security interests, or encumbrances, or that there may not be other matters at issue between Owner and Contractor that might affect the amount that should be paid. 24. Contractor’s Completion Documents: Receive, review, and transmit to Owner maintenance and operating instructions, schedules, guarantees, bonds, certificates or other evidence of insurance required by the Contract Documents, certificates of inspection, tests and approvals, Shop Drawings, Samples and other data approved as provided under Paragraph A1.05.A.11, and transmit the annotated record documents which are to be assembled by Contractor in accordance with the Contract Documents to obtain final payment. The extent of such review by Engi 25. ne 26. er will be limited as provided in Paragraph A1.05.A.11. 27. Substantial Completion: Promptly after notice from Contractor that Contractor considers the entire Work ready for its intended use, in company with Owner and Contractor, visit the Project to determine if the Work is substantially complete. If after considering any objections of Owner, Engineer considers the Work substantially complete, Engineer shall deliver a certificate of Substantial Completion to Owner and Contractor. 28. Additional Tasks: Perform or provide the following additional Construction Phase tasks or deliverables: [here list any such tasks or deliverables]. 29. Final Notice of Acceptability of the Work: Conduct a final visit to the Project to determine if the completed Work of Contractor is acceptable so that Engineer may recommend, in writing, final payment to Contractor. Accompanying the recommendation for final payment, Engineer shall also provide a notice in the form attached hereto as Exhibit E (the “Notice of Acceptability of Work”) that the Work is acceptable (subject to the provisions of Paragraph A1.05.A.15.b) to the best of Engineer’s knowledge, information, and belief and based on the extent of the services p 30. rovided by Engineer u 31. nder this Agreement. B. Duration of Construction Phase: The Construction Phase will commence with the execution of the first Construction Contract for the Project or any part thereof and will terminate upon written recommendation by Engineer for final payment to Contractors. If the Project involves more than one prime contract as indicated in Paragraph A1.03.C, then Construction Phase services may be rendered at different times in respect to the separate contracts. Subject to the provisions of Article 3, Engineer shall be entitled to an equitable increase i C. n D. compensation if Construction Phase services (including Resident Project Representative services, if any) are required after the original date for completion and readiness for final payment of Contractor as set forth in the Construction Contract. Page 9 (Exhibit A – Engineer’s Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. E. Limitation of Responsibilities: Engineer shall not be responsible for the acts or omissions of any Contractor, Subcontractor or Supplier, or other individuals or entities performing or furnishing any of the Work, for safety or security at the Site, or for safety precautions and programs incident to Contractor's Work, during the Construction Phase or otherwise. Engineer shall not be responsible for the failure of any Contractor to perform or furnish the Work in accordance with the Contract Documents. A1.06 Post-Construction Phase A. Upon written authorization from Ownerduring the Post-Construction Phase Engineer shall: 1. Together with Owner, visit the Project to observe any apparent defects in the Work, assist Owner in consultations and discussions with Contractor concerning correction of any such defects, and make recommendations as to replacement or correction of defective Work, if any. 2. Together with Owner or Owner’s representative, visit the Project within one month before the end of the correction period to ascertain whether any portion of the Work is subject to correction. 3. Perform or provide the following additional Post-Construction Phase tasks or deliverables: [Here list any such tasks or deliverables] B. The Post-Construction Phase services may commence during the Construction Phase and, if not otherwise modified in this Exhibit A, will terminate twelve months after the commencement of the Construction Contract’s correction period. PART 2 – ADDITIONAL SERVICES A2.01 Additional Services Requiring Owner’s Written Authorization A. If authorized in writing by Owner, Engineer shall furnish or obtain from others Additional Services of the types listed below. 1. Preparation of applications and supporting documents (in addition to those furnished under Basic Services) for private or governmental grants, loans, or advances in connection with the Project; preparation or review of environmental assessments and impact statements; review and evaluation of the effects on the design requirements for the Project of any such statements and documents prepared by others; and assistance in obtaining approvals of authorities having jurisdiction over the anticipated environmental impact of the Project. 2. Services to make measured drawings of or to investigate existing conditions or facilities, or to verify the accuracy of drawings or other information furnished by Owner or others. 3. Services resulting from significant changes in the scope, extent, or character of the portions of the Project designed or specified by Engineer or its design requirements including, but not limited to, changes in size, complexity, Owner’s schedule, character of construction, or method of financing; and revising previously accepted studies, reports, Drawings, Specifications, or Contract Documents when such revisions are required by changes in Page 10 (Exhibit A – Engineer’s Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Laws and Regulations enacted subsequent to the Effective Date or are due to any other causes beyond Engineer’s control. 4. Services resulting from Owner’s request to evaluate additional Study and Report Phase alternative solutions beyond those identified in Paragraph A1.01.A.4. 5. Services required as a result of Owner’s providing incomplete or incorrect Project information to Engineer. 6. Providing renderings or models for Owner’s use. 7. Undertaking investigations and studies including, but not limited to, detailed consideration of operations, maintenance, and overhead expenses; the preparation of financial feasibility and cash flow studies, rate schedules, and appraisals; assistance in obtaining financing for the Project; evaluating processes available for licensing, and assisting Owner in obtaining process licensing; detailed quantity surveys of materials, equipment, and labor; and audits or inventories required in connection with construction performed by Owner. 8. Furnishing services of Consultants for other than Basic Services. 9. Services attributable to more prime construction contracts than specified in Paragraph A1.03.D. 10. Services during out-of-town travel required of Engineer other than for visits to the Site or Owner’s office. 11. Preparing for, coordinating with, participating in and responding to structured independent review processes, including, but not limited to, construction management, cost estimating, project peer review, value engineering, and constructibility review requested by Owner; and performing or furnishing services required to revise studies, reports, Drawings, Specifications, or other Bidding Documents as a result of such review processes. 12. Preparing additional Bidding Documents or Contract Documents for alternate bids or prices requested by Owner for the Work or a portion thereof. 13. Assistance in connection with Bid protests, rebidding, or renegotiating contracts for construction, materials, equipment, or services, except when such assistance is required by Exhibit F. 14. Providing construction surveys and staking to enable Contractor to perform its work other than as required under Paragraph A1.05.A.6, and any type of property surveys or related engineering services needed for the transfer of interests in real property; and providing other special field surveys. 15. Providing Construction Phase services beyond the original date for completion and readiness for final payment of Contractor. 16. Providing assistance in responding to the presence of any Constituent of Concern at the Site, in compliance with current Laws and Regulations. Page 11 (Exhibit A – Engineer’s Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. 17. Preparing Record Drawings showing appropriate record information based on Project annotated record documents received from Contractor, and furnishing such Record Drawings to Owner. 18. Preparation of operation and maintenance manuals. 19. Preparing to serve or serving as a consultant or witness for Owner in any litigation, arbitration, or other dispute resolution process related to the Project. 20. Providing more extensive services required to enable Engineer to issue notices or certifications requested by Owner. 21. Assistance in connection with the adjusting of Project equipment and systems. 22. Assistance to Owner in training Owner’s staff to operate and maintain Project equipment and systems. 23. Assistance to Owner in developing procedures for (a) control of the operation and maintenance of Project equipment and systems, and (b) related record-keeping. 24. Overtime work requiring higher than regular rates. 25. Other services performed or furnished by Engineer not otherwise provided for in this Agreement. A2.02 Additional Services Not Requiring Owner’s Written Authorization A. Engineer shall advise Owner in advance that Engineer will immediately commence to perform or furnish the Additional Services of the types listed below. For such Additional Services, Engineer need not request or obtain specific advance written authorization from Owner. Engineer shall cease performing or furnishing such Additional Services upon receipt of written notice from Owner. 1. Services in connection with work change directives and change orders to reflect changes requested by Owner. 2. Services in making revisions to Drawings and Specifications occasioned by the acceptance of substitute materials or equipment other than “or-equal” items; services after the award of the Construction Contract in evaluating and determining the acceptability of a proposed "or equal" or substitution which is found to be inappropriate for the Project; evaluation and determination of an excessive number of proposed "or equals" or substitutions, whether proposed before or after award of the Construction Contract. 3. Services resulting from significant delays, changes, or price increases occurring as a direct or indirect result of materials, equipment, or energy shortages. 4. Additional or extended services during construction made necessary by (1) emergencies or acts of God endangering the Work (advance notice not required), (2) the presence at the Site of any Constituent of Concern or items of historical or cultural significance, (3) Work Page 12 (Exhibit A – Engineer’s Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. damaged by fire or other cause during construction, (4) a significant amount of defective, neglected, or delayed work by Contractor, (5) acceleration of the progress schedule involving services beyond normal working hours, or (6) default by Contractor. 5. Services (other than Basic Services during the Post-Construction Phase) in connection with any partial utilization of any part of the Work by Owner prior to Substantial Completion. 6. Evaluating an unreasonable claim or an excessive number of claims submitted by Contractor or others in connection with the Work. 7. Services during the Construction Phase rendered after the original date for completion of the Work referred to in A1.05.B. 8. Reviewing a Shop Drawing more than three times, as a result of repeated inadequate submissions by Contractor. 9. While at the Site, compliance by Engineer and its staff with those terms of Owner's or Contractor's safety program provided to Engineer subsequent to the Effective Date that exceed those normally required of engineering personnel by federal, state, or local safety authorities for similar construction sites. Page 1 (Exhibit B – Owner's Responsibilities) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. This is EXHIBIT B, consisting of 3 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated , . Owner’s Responsibilities Article 2 of the Agreement is supplemented to include the following agreement of the parties. B2.01 In addition to other responsibilities of Owner as set forth in this Agreement, Owner shall at its expense: A. Provide Engineer with all criteria and full information as to Owner’s requirements for the Project, including design objectives and constraints, space, capacity and performance requirements, flexibility, and expandability, and any budgetary limitations; and furnish copies of all design and construction standards which Owner will require to be included in the Drawings and Specifications; and furnish copies of Owner’s standard forms, conditions, and related documents for Engineer to include in the Bidding Documents, when applicable. B. Furnish to Engineer any other available information pertinent to the Project including reports and data relative to previous designs, or investigation at or adjacent to the Site. C. Following Engineer’s assessment of initially-available Project information and data and upon Engineer’s request, furnish or otherwise make available such additional Project related information and data as is reasonably required to enable Engineer to complete its Basic and Additional Services. Such additional information or data would generally include the following: 1. Property descriptions. 2. Zoning, deed, and other land use restrictions. 3. Property, boundary, easement, right-of-way, and other special surveys or data, including establishing relevant reference points. 4. Explorations and tests of subsurface conditions at or contiguous to the Site, drawings of physical conditions relating to existing surface or subsurface structures at the Site, or hydrographic surveys, with appropriate professional interpretation thereof. 5. Environmental assessments, audits, investigations, and impact statements, and other relevant environmental or cultural studies as to the Project, the Site, and adjacent areas. 6. Data or consultations as required for the Project but not otherwise identified in the Agreement or the Exhibits thereto. D. Give prompt written notice to Engineer whenever Owner observes or otherwise becomes aware of the presence at the Site of any Constituent of Concern, or of any other development that affects the scope or time of performance of Engineer’s services, or any defect or nonconformance in Engineer’s services, the Work, or in the performance of any Contractor. Page 2 (Exhibit B – Owner's Responsibilities) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. E. Authorize Engineer to provide Additional Services as set forth in Part 2 of Exhibit A of the Agreement as required. F. Arrange for safe access to and make all provisions for Engineer to enter upon public and private property as required for Engineer to perform services under the Agreement. G. Examine all alternate solutions, studies, reports, sketches, Drawings, Specifications, proposals, and other documents presented by Engineer (including obtaining advice of an attorney, insurance counselor, and other advisors or consultants as Owner deems appropriate with respect to such examination) and render in writing timely decisions pertaining thereto. H. Provide reviews, approvals, and permits from all governmental authorities having jurisdiction to approve all phases of the Project designed or specified by Engineer and such reviews, approvals, and consents from others as may be necessary for completion of each phase of the Project. I. Recognizing and acknowledging that Engineer's services and expertise do not include the following services, provide, as required for the Project: 1. Accounting, bond and financial advisory, independent cost estimating, and insurance counseling services. 2. Legal services with regard to issues pertaining to the Project as Owner requires, Contractor raises, or Engineer reasonably requests. 3. Such auditing services as Owner requires to ascertain how or for what purpose Contractor has used the moneys paid. J. Place and pay for advertisement for Bids in appropriate publications. K. Advise Engineer of the identity and scope of services of any independent consultants employed by Owner to perform or furnish services in regard to the Project, including, but not limited to, cost estimating, project peer review, value engineering, and constructibility review. L. Furnish to Engineer data as to Owner’s anticipated costs for services to be provided by others (including, but not limited to, accounting, bond and financial, independent cost estimating, insurance counseling, and legal advice) for Owner so that Engineer may assist Owner in collating the various cost categories which comprise Total Project Costs. M. If Owner designates a construction manager or an individual or entity other than, or in addition to, Engineer to represent Owner at the Site, define and set forth as an attachment to this Exhibit B the duties, responsibilities, and limitations of authority of such other party and the relation thereof to the duties, responsibilities, and authority of Engineer. N. If more than one prime contract is to be awarded for the Work designed or specified by Engineer, designate a person or entity to have authority and responsibility for coordinating the activities among the various prime Contractors, and define and set forth the duties, responsibilities, and limitations of authority of such individual or entity and the relation thereof to the duties, Page 3 (Exhibit B – Owner's Responsibilities) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. responsibilities, and authority of Engineer as an attachment to this Exhibit B that is to be mutually agreed upon and made a part of this Agreement before such services begin. O. Attend the pre-bid conference, bid opening, pre-construction conferences, construction progress and other job related meetings, and Substantial Completion and final payment visits to the Project. P. Provide the services of an independent testing laboratory to perform all inspections, tests, and approvals of samples, materials, and equipment required by the Contract Documents, or to evaluate the performance of materials, equipment, and facilities of Owner, prior to their incorporation into the Work with appropriate professional interpretation thereof. Q. Provide Engineer with the findings and reports generated by the entities providing services to Owner pursuant to this paragraph. R. Inform Engineer in writing of any specific requirements of safety or security programs that are applicable to Engineer, as a visitor to the Site. S. Perform or provide the following additional services: Page 1 Exhibit C –Compensation Packet BC-2: Basic Services (other than RPR) – Standard Hourly Rates Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. This is EXHIBIT C, consisting of pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated , . Payments to Engineer for Services and Reimbursable Expenses COMPENSATION PACKET BC-2: Basic Services – Standard Hourly Rates Article 2 of the Agreement is supplemented to include the following agreement of the parties: ARTICLE 2 – OWNER’S RESPONSIBILITIES C2.01 Compensation For Basic Services (other than Resident Project Representative) – Standard Hourly Rates Method of Payment A. Owner shall pay Engineer for Basic Services set forth in Exhibit A, except for services of Engineer’s Resident Project Representative, if any, as follows: 1. An amount equal to the cumulative hours charged to the Project by each class of Engineer’s personnel times Standard Hourly Rates for each applicable billing class for all services performed on the Project, plus Reimbursable Expenses and Engineer’s Consultants' charges, if any. 2. Engineer’s Reimbursable Expenses Schedule and Standard Hourly Rates are attached to this Exhibit C as Appendices 1 and 2. 3. The total compensation for services under Paragraph C2.01 is estimated to be $ 31,200 based on the following estimated distribution of compensation: a. Study and Report Phase $_N/A___________________ b. Preliminary Design Phase $_31,200__________________ c. Final Design Phase $_TBD___________________ d. Bidding or Negotiating Phase $_TBD___________________ e. Construction Phase $_TBD___________________ f. Post-Construction Phase $_TBD___________________ 4. Engineer may alter the distribution of compensation between individual phases of the work noted herein to be consistent with services actually rendered, but shall not exceed the total estimated compensation amount unless approved in writing by Owner. See also C2.03.C.2 below. 5. The total estimated compensation for Engineer’s services included in the breakdown by phases as noted in Paragraph C2.01.A.3 incorporates all labor, overhead, profit, Reimbursable Expenses and Engineer’s Consultants' charges. Page 2 Exhibit C –Compensation Packet BC-2: Basic Services (other than RPR) – Standard Hourly Rates Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. 6. The amounts billed for Engineer’s services under Paragraph C2.01 will be based on the cumulative hours charged to the Project during the billing period by each class of Engineer’s employees times Standard Hourly Rates for each applicable billing class, plus Reimbursable Expenses and Engineer’s Consultants' charges. 7. The Standard Hourly Rates and Reimbursable Expenses Schedule will be adjusted annually (as of 12/31/2026 ) to reflect equitable changes in the compensation payable to Engineer. C2.02 Compensation For Reimbursable Expenses A. Owner shall pay Engineer for all Reimbursable Expenses at the rates set forth in Appendix 1 to this Exhibit C. B. Reimbursable Expenses include the following categories: transportation and subsistence incidental thereto; providing and maintaining field office facilities including furnishings and utilities; toll telephone calls and mobile phone charges; reproduction of reports, Drawings, Specifications, Bidding Documents, and similar Project-related items in addition to those required under Exhibit A. In addition, if authorized in advance by Owner, Reimbursable Expenses will also include expenses incurred for the use of highly specialized equipment. C. The amounts payable to Engineer for Reimbursable Expenses will be the Project-related internal expenses actually incurred or allocated by Engineer, plus all invoiced external Reimbursable Expenses allocable to the Project, the latter multiplied by a factor of 1.12 . C2.03 Other Provisions Concerning Payment A. Whenever Engineer is entitled to compensation for the charges of Engineer’s Consultants, those charges shall be the amounts billed by Engineer’s Consultants to Engineer times a factor of 1.0 . B. Factors. The external Reimbursable Expenses and Engineer’s Consultants' factors include Engineer’s overhead and profit associated with Engineer’s responsibility for the administration of such services and costs. Page 3 Exhibit C –Compensation Packet BC-2: Basic Services (other than RPR) – Standard Hourly Rates Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. C. Estimated Compensation Amounts: 1. Engineer’s estimate of the amounts that will become payable for specified services are only estimates for planning purposes, are not binding on the parties, and are not the minimum or maximum amounts payable to Engineer under the Agreement. 2. When estimated compensation amounts have been stated herein and it subsequently becomes apparent to Engineer that the total compensation amount thus estimated will be exceeded, Engineer shall give Owner written notice thereof, allowing Owner to consider its options, including suspension or termination of Engineer's services for Owner's convenience. Upon notice, Owner and Engineer promptly shall review the matter of services remaining to be performed and compensation for such services. Owner shall either exercise its right to suspend or terminate Engineer's services for Owner's convenience, agree to such compensation exceeding said estimated amount, or agree to a reduction in the remaining services to be rendered by Engineer, so that total compensation for such services will not exceed said estimated amount when such services are completed. If Owner decides not to suspend the Engineer's services during the negotiations and Engineer exceeds the estimated amount before Owner and Engineer have agreed to an increase in the compensation due Engineer or a reduction in the remaining services, then Engineer shall be paid for all services rendered hereunder. D. To the extent necessary to verify Engineer’s charges and upon Owner’s timely request, Engineer shall make copies of such records available to Owner at cost. Page 1 Exhibit C – Compensation Packet RPR-2: Resident Project Representative Services Standard Hourly Rates Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. COMPENSATION PACKET RPR-2: Resident Project Representative – Standard Hourly Rates Article 2 of the Agreement is supplemented to include the following agreement of the parties: C2.04 Compensation for Resident Project Representative Basic Services – Standard Hourly Rates Method of Payment A. Owner shall pay Engineer for Resident Project Representative Basic Services as follows: 1. Resident Project Representative Services: For services of Engineer’s Resident Project Representative under Paragraph A1.05A of Exhibit A, an amount equal to the cumulative hours charged to the Project by each class of Engineer’s personnel times Standard Hourly Rates for each applicable billing class for all Resident Project Representative services performed on the Project, plus related Reimbursable Expenses and Engineer’s Consultant’s charges, if any. The total compensation under this Paragraph is estimated to be $ based upon full-time RPR services on an eight-hour workday, Monday through Friday, over a day construction schedule. B. Compensation for Reimbursable Expenses: 1. For those Reimbursable Expenses that are not accounted for in the compensation for Basic Services under Paragraph C2.01, and are directly related to the provision of Resident Project Representative or Post-Construction Basic Services, Owner shall pay Engineer at the rates set forth in Appendix 1 to this Exhibit C. 2. Reimbursable Expenses include the following categories: transportation and subsistence incidental thereto; ; providing and maintaining field office facilities including furnishings and utilities; 3. subsistence and transportation of Resident Project Representative and assistants; toll telephone calls and mobile phone charges; reproduction of reports, Drawings, Specifications, Bidding Documents, and similar Project-related items in addition to those required under Exhibit A. In addition, if authorized in adva 4. nce by Owner, Reimbursable Expenses will also include expenses incurred for the use of highly specialized equipment. 5. The amounts payable to Engineer for Reimbursable Expenses, if any, will be those internal expenses related to the Resident Project Representative Basic Services that are actually incurred or allocated by Engineer, plus all invoiced external Reimbursable Expenses allocable to such services, the latter multiplied by a factor of . 6. The Reimbursable Expenses Schedule will be adjusted annually (as of ) to reflect equitable changes in the compensation payable to Engineer. Page 2 Exhibit C – Compensation Packet RPR-2: Resident Project Representative Services Standard Hourly Rates Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. C. Other Provisions Concerning Payment Under this Paragraph C2.04: 1. Whenever Engineer is entitled to compensation for the charges of Engineer’s Consultants, those charges shall be the amounts billed by Engineer’s Consultants to Engineer times a factor of 1.0. 2. Factors: The external Reimbursable Expenses and Engineer’s Consultant’s factors include Engineer’s overhead and profit associated with Engineer’s responsibility for the administration of such services and costs. 3. Estimated Compensation Amounts: a. Engineer’s estimate of the amounts that will become payable for specified services are only estimates for planning purposes, are not binding on the parties, and are not the minimum or maximum amounts payable to Engineer under the Agreement. b. When estimated compensation amounts have been stated herein and it subsequently becomes apparent to Engineer that the total compensation amount thus estimated will be exceeded, Engineer shall give Owner written notice thereof, allowing Owner to consider its options, including suspension or termination of Engineer's services for Owner's convenience. Upon notice Owner and Engineer promptly shall review the matter of services remaining to be performed and compensation for such services. Owner shall either exercise its right to suspend or terminate Engineer's services for Owner's convenience, agree to such compensation exceeding said estimated amount, or agree to a reduction in the remaining services to be rendered by Engineer, so that total compensation for such services c. will not exceed said estimated amount when such services are completed. If Owner decides not to suspend Engineer's services during negotiations and Engineer exceeds the estimated amount before Owner and Engineer have agreed to an increase in d. the compensation due Engineer or a reduction in the remaining services, then Engineer shall be paid for all services rendered hereunder. 4. To the extent necessary to verify Engineer’s charges and upon Owner’s timely request, Engineer shall make copies of such records available to Owner at cost. Page 1 Exhibit C – Compensation Packet AS-1: Additional Services – Standard Hourly Rates Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. COMPENSATION PACKET AS-1: Additional Services – Standard Hourly Rates Article 2 of the Agreement is supplmented to include the following agreement of the parties: C2.05 Compensation for Additional Services – Standard Hourly Rates Method of Payment A. Owner shall pay Engineer for Additional Services, if any, as follows: 1. General: For services of Engineer’s personnel engaged directly on the Project pursuant to Paragraph A2.01 or A2.02 of Exhibit A, except for services as a consultant or witness under Paragraph A2.01.A.20, (which if needed shall be separately negotiated based on the nature of the required consultation or testimony) an amount equal to the cumulative hours charged to the Project by each class of Engineer’s personnel times Standard Hourly Rates for each applicable billing class for all Additional Services performed on the Project, plus related Reimbursable Expenses and Engineer’s Consultant’s charges, if any. B. Compensation For Reimbursable Expenses: 1. For those Reimbursable Expenses that are not accounted for in the compensation for Basic Services under Paragraph C2.01 and are directly related to the provision of Additional Services, Owner shall pay Engineer at the rates set forth in Appendix 1 to this Exhibit C. 2. Reimbursable Expenses include the following categories: transportation and subsistence incidental thereto; providing and maintaining field office facilities including furnishings and utilities; toll telephone calls and mobile phone charges; reproduction of reports, Drawings, Specifications, Bidding Documents, and similar Project-related items in addition to those required under Exhibit A. In addition, if authorized in advance by Owner, Reimbursable Expenses will also include expenses incurred for the use of highly specialized equipment. 3. The amounts payable to Engineer for Reimbursable Expenses, if any, will be the Additional Services-related internal expenses actually incurred or allocated by Engineer, plus all invoiced external Reimbursable Expenses allocable to such Additional Services, the latter multiplied by a factor of 1.12 . 4. The Reimbursable Expenses Schedule will be adjusted annually (as of 12/31/2026 ) to reflect equitable changes in the compensation payable to Engineer. C. Other Provisions Concerning Payment For Additional Services: 1. Whenever Engineer is entitled to compensation for the charges of Engineer’s Consultants, those charges shall be the amounts billed by Engineer’s Consultants to Engineer times a factor of 1.0 . Page 2 Exhibit C – Compensation Packet AS-1: Additional Services – Standard Hourly Rates Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. 2. Factors: The external Reimbursable Expenses and Engineer’s Consultant’s Factors include Engineer’s overhead and profit associated with Engineer’s responsibility for the administration of such services and costs. 3. To the extent necessary to verify Engineer’s charges and upon Owner’s timely request, Engineer shall make copies of such records available to Owner at cost. Page 1 Exhibit C – Appendix 1: Reimbursable Expenses Schedule EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. This is Appendix 1 to EXHIBIT C, consisting of 1 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated , . Reimbursable Expenses Schedule Current agreements for engineering services stipulate that the Reimbursable Expenses are subject to review and adjustment per Exhibit C. Reimbursable expenses for services performed on the date of the Agreement are: 8"x11" Copies/Impressions 0.07/page Plotting 6.00/ea. Supplies (binders, tabs, etc.) 25.00/set Mileage (auto) 0.70 /mile Page 1 Exhibit C – Appendix 2: Standard Hourly Rates Schedule EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. This is Appendix 2 to EXHIBIT C, consisting of 1 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated , . Standard Hourly Rates Schedule A. Standard Hourly Rates: 1. Standard Hourly Rates are set forth in this Appendix 2 to this Exhibit C and include salaries and wages paid to personnel in each billing class plus the cost of customary and statutory benefits, general and administrative overhead, non-project operating costs, and operating margin or profit. 2. The Standard Hourly Rates apply only as specified in Article C2. B. Schedule: Hourly rates for services performed on or after the date of the Agreement are: Page 1 (Exhibit G - Insurance) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. This is EXHIBIT G, consisting of 3 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated , . Insurance Paragraph 6.04 of the Agreement is supplemented to include the following agreement of the parties. G6.04 Insurance A. The limits of liability for the insurance required by Paragraph 6.04.A and 6.04.B of the Agreement are as follows: 1. By Engineer: a. Workers’ Compensation: Statutory b. Employer’s Liability -- 1) Each Accident: $____1,000,000___ 2) Disease, Policy Limit: $________1,000,000________ 3) Disease, Each Employee: $______1,000,000__________ c. General Liability -- 1) Each Occurrence (Bodily Injury and Property Damage): $_____1,000,000___________ 2) General Aggregate: $_________2,000,000_______ d. Excess or Umbrella Liability -- 1) Each Occurrence: $______1,000,000__________ 2) General Aggregate: $_______2,000,000_________ e. Automobile Liability --Combined Single Limit (Bodily Injury and Property Damage): Each Accident $_________1,000,000_______ f. Professional Liability – Page 2 (Exhibit G - Insurance) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. 1) Each Claim Made $_______1,000,000 _________ 2) Annual Aggregate $______2,000,000__________ g. Other (specify): $________________ 2. By Owner: a. The City of South Bend is a municipal corporation organized under the laws of the State of Indiana, and is self-insured under provisions of Indiana statutes and local ordinance. Specifically, the City of South Bend maintains blanket insurance coverage over real and personal property, and is covered by a non-reverting insurance premium and liability reserve fund created by the City of South Bend, Ordinance #6657-79, pursuant to Indiana Code 34-13-3-4, as amended from time to time. Under said statute, the City’s liability is limited to: 1) Seven hundred thousand dollars ($700,000) for a cause of action that accrues on or after January 1, 2008; and 2) Five million dollars ($5,000,000) for injury to or death of all persons in that occurrence,; and 3) A governmental entity or an employee of a governmental entity acting within the scope of employment is not liable for punitive damages. B. Additional Insureds: 1. The following persons or entities are to be listed on Owner’s general liability policies of insurance as additional insureds, and on any applicable property insurance policy as loss payees, as provided in Paragraph 6.04.B: Page 3 (Exhibit G - Insurance) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. a. Engineer b. Engineer’s Consultant c. Engineer’s Consultant 2. During the term of this Agreement the Engineer shall notify Owner of any other Consultant to be listed as an additional insured on Owner’s general liability and property policies of insurance. 3. The Owner shall be listed on Engineer’s general liability policy as provided in Paragraph 6.04.A. Page 1 (Exhibit J - Special Provisions) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. This is EXHIBIT I, consisting of 1 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated , . Limitations of Liability Paragraph 6.10 of the Agreement is supplemented to include the following agreement of the parties: A. Limitation of Engineer’s Liability 1. Engineer’s Liability Limited to Amount of Insurance Proceeds: Engineer shall procure and maintain insurance as required by and set forth in Exhibit G to this Agreement. Notwithstanding any other provision of this Agreement, and to the fullest extent permitted by law, the total liability, in the aggregate, of Engineer and Engineer’s officers, directors, members, partners, agents, employees, and Consultants to Owner and anyone claiming by, through, or under Owner for any and all claims, losses, costs, or damages whatsoever arising out of, resulting from, or in any way related to the Project or the Agreement from any cause or causes, including but not limited to the negligence, professional errors or omissions, strict liability, breach of contract, indemnity obligations, or warranty express or implied, of Engineer or Engineer’s officers, directors, members, partners, agents, employees, or Consultantss (hereafter “Owner’s Claims”), shall not exceed the total insurance proceeds paid on behalf of or to Engineer by Engineer’s insurers in settlement or satisfaction of Owner’s Claims under the terms and conditions of Engineer’s insurance policies applicable thereto (excluding fees, costs and expenses of investigation, claims adjustment, defense, and appeal). If no such insurance coverage is provided with respect to Owner’s Claims, then the total liability, in the aggregate, of Engineer and Engineer’s officers, directors, members, partners, agents, employees, and Consultants to Owner and anyone claiming by, through, or under Owner for any and all such uninsured Owner’s Claims shall not exceed $_____________ B. Indemnification by Owner: To the fullest extent permitted by law, Owner shall indemnify and hold harmless Engineer and its officers, directors, members, partners, agents, employees, and Consultants from and against any and all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals, and all court, arbitration, or other dispute resolution costs) arising out of or relating to the Project, provided that any such claim, cost, loss, or damage is attributable to bodily injury, sickness, disease, or death or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom, but only to the extent caused by any negligent act or omission of Owner or Owner’s officers, directors, members, partners, agents, employees, consultants, or others retained by or under contract to the Owner with respect to this Agreement or to the Project. Angela Boulevard Sidealk Extension 19.R250141.00000 October 31, 2025 1 Christopher B. Burke Engineering, LLC 220 W. Colfax Ave., Suite 700 | South Bend, IN 46601 574.282.8001 | cbbel-in.com October 31, 2025 Dan Jones City of South Bend 215 S. Dr. Martin Luther King Blvd., Ste. 400 South Bend, IN 46601 Subject: Angela Blvd Sidewalk Extension from Twyckenham Dr to SR 23 Professional Services Proposal Dear Mr. Jones, Christopher B. Burke Engineering, LLC is pleased to provide this proposal for professional engineering services related to the Angela Boulevard sidewalk extension in South Bend, Indiana. The following is our understanding of the assignment, scope of services, and estimated fee in support of the project. UNDERSTANDING OF THE ASSIGNMENT The project will consist of preliminary engineering for a proposed sidewalk extension along Angela Boulevard between Twyckenham Drive and State Road 23. Both the north and south sides of Angela Boulevard will be assessed to determine the preferred location to provide the sidewalk based on evaluating right-of- way/easement needs and existing grades to accommodate ADA compliance along the proposed route. The total length of the sidewalk extension will be approximately 560 feet. In addition to the sidewalk extension, the city would like to verify the right of way on the north and south sides of Angela Boulevard along the sidewalk route and the northwest corner of the intersection of Angela Boulevard and Twyckenham Drive. SCOPE OF SERVICES Task 1 – Topographic Survey and Right-of-Way Determination: Task 1A Topographic Survey: Burke will subcontract Abonmarche to provide topographic surveying services for the project, including: • Request utility locations utilizing “Call Before You Dig” (811) utility locating service. Please note that this service only locates those utilities that are members of this service. Nonmembers or private utilities located within the project limits will not be marked by the 811 service. A private utility locating firm would need to be contacted to locate private utilities. This proposal does not include costs associated with private utility locates. • Establish horizontal and vertical control within the project limits. Horizontal datum will be based upon the Indiana State Plan Coordinate System, East Zone. The vertical datum will be NAVD88 datum. • Topographic survey limits will be from the existing curb ramp at Twyckenham to the existing curb ramp at SR 23 from back of curb to 15 feet behind the back of curb on both the north and south sides of the road. This task includes time for Burke to perform a field check to examine the thoroughness of the topographic survey and coordination with Abonmarche. The topographic survey will be the basis of our design. Task 1B Right-of-Way Determination: Abonmarche will perform title searches for the parcels on both the north and sides of Angela Boulevard between Twyckenham Drive and SR 23 and at the northwest corner of the intersection Twyckenham Drive and Angela Boulevard. A total of seven parcels are included for title Angela Boulevard Sidewalk Extension 19.R250141.00000 October 31, 2025 2 searches. Abonmarche will utilize the title searches for these parcels and found property corners in the field to establish the right of way in this area. Task 2 – Preliminary Engineering: Burke will use the topographic survey provided by Abonmarche to evaluate the preferred location for the sidewalk extension. We will establish a preliminary alignment and profile for the proposed sidewalk. We will develop preliminary plans to approximately 30% design and provide them to city staff for review. Burke has budgeted for one meeting with city staff in this phase to review the 30% design plans and determine scope for final design of the project. ESTIMATED FEE We have estimated the total fee for completing this project will not exceed $31,200. We will bill you monthly, on a time and material basis, for assigned tasks in accordance with our attached standard charges for professional services. Should the requested services exceed the estimated fee, Burke will prepare an amendment for the additional requested services. Task Estimated Fee Task 1A Topographic Survey $8,250 Task 1B Title Search ($650/parcel; 7 parcels total) $ 4,550 Establish Right-of-Way $3,500 Task 2 Preliminary Engineering $14,900 TOTAL $31,200 In addition, our contract will be established in accordance with the attached general terms and conditions, which are expressly incorporated into and are an integral part of this contract for professional services. It should be emphasized that any requested additional meetings or additional services that are not included in the preceding fee will be billed at the attached hourly rates. If this proposal meets with your approval, please sign where indicated and return an executed original to us as our notice to proceed. The executed proposal, along with the estimated fee, and the attached standard charges for professional services and general terms and conditions constitute the whole of our agreement. Any modification to any part of this agreement without prior acknowledgement and consent by Burke will null and void this agreement. Any time commitment made by Burke as part of the agreement does not begin until Burke has received an executed original. Christopher B. Burke Engineering, LLC has enrolled in and is verifying the work eligibility of all newly hired employees through the E-verify program operated by the United States Department of Homeland Security. The undersigned affirms under the penalty of perjury that Christopher B. Burke Engineering, LLC does not knowingly employ an unauthorized alien. In addition, the undersigned, on behalf of Christopher B. Burke Engineering, LLC certifies that, as required by IC 5-22-16.5-13, Christopher B. Burke Engineering, LLC is not engaged in investment activities in Iran. We appreciate the opportunity to submit this proposal and look forward to working with you on this project. Please contact me at 317.266.8000 or Andy Gebhard at the number listed above if you have any questions. Sincerely, Jon D. Stolz, PE Managing Vice President Angela Boulevard Sidewalk Extension 19.R250141.00000 October 31, 2025 3 THIS PROPOSAL, ESTIMATED FEE, STANDARD CHARGES FOR PROFESSIONAL SERVICES AND GENERAL TERMS AND CONDITIONS ARE ACCEPTED BY THE CITY OF SOUTH BEND: Signature: ______________________________________________________ Name (Printed): ______________________________________________________ Title: ______________________________________________________ Date: ______________________________________________________ Enclosures: Standard Charges for Professional Services General Terms and Conditions Angela Boulevard Sidewalk Extension 19.R250141.00000 October 31, 2025 Christopher B. Burke Engineering, LLC 2025 Standard Charges for Professional Services 4 Personnel ($/Hr) Engineer VI 300 Engineer V 270 Engineer IV 215 Engineer III 190 Engineer I/II 160 Resource Planner V 215 Resource Planner IV 180 Resource Planner III 150 Resource Planner I/II 130 Engineering Technician IV 185 Engineering Technician III 165 Engineering Technician I/II 125 CAD II 155 CAD I 125 GIS Specialist IV 185 GIS Specialist III 185 GIS Specialist I/II 125 Environmental Resource Specialist V 215 Environmental Resource Specialist IV 190 Environmental Resource Specialist III 150 Environmental Resource Specialist I/II 130 Environmental Resource Technician 115 Administrative 100 Engineering Intern 75 Information Technician I/II 100 *Charges include overhead and profit Direct Costs Outside copies, messenger, delivery services, mileage Cost + 12% Christopher B. Burke Engineering, LLC reserves the right to increase these rates after December 31, 2025. Angela Boulevard Sidewalk Extension 19.R250141.00000 October 31, 2025 Christopher B. Burke Engineering, LLC General Terms and Conditions 5 1. Relationship Between Engineer and Client: Christopher B. Burke Engineering, LLC (Engineer) shall serve as Client's professional engineer consultant in those phases of the Project to which this Agreement applies. This relationship is that of a buyer and seller of professional services and as such the Engineer is an independent contractor in the performance of this Agreement and it is understood that the parties have not entered into any joint venture or partnership with the other. The Engineer shall not be considered to be the agent of the Client. Nothing contained in this Agreement shall create a contractual relationship with a cause of action in favor of a third party against either the Client or Engineer. Furthermore, causes of action between the parties to this Agreement pertaining to acts or failures to act shall be deemed to have accrued and the applicable statute of limitations shall commence to run not later than the date of substantial completion. 2. Responsibility of the Engineer: Engineer will strive to perform services under this Agreement in accordance with generally accepted and currently recognized engineering practices and principles, and in a manner consistent with that level of care and skill ordinarily exercised by members of the profession currently practicing in the same locality under similar conditions. No other representation, express or implied, and no warranty or guarantee is included or intended in this Agreement, or in any report, opinion, document, or otherwise. Notwithstanding anything to the contrary which may be contained in this Agreement or any other material incorporated herein by reference, or in any Agreement between the Client and any other party concerning the Project, the Engineer shall not have control or be in charge of and shall not be responsible for the means, methods, techniques, sequences or procedures of construction, or the safety, safety precautions or programs of the Client, the construction contractor, other contractors or subcontractors performing any of the work or providing any of the services on the Project. Nor shall the Engineer be responsible for the acts or omissions of the Client, or for the failure of the Client, any architect, engineer, consultant, contractor or subcontractor to carry out their respective responsibilities in accordance with the Project documents, this Agreement or any other agreement concerning the Project. Any provision which purports to amend this provision shall be without effect unless it contains a reference that the content of this condition is expressly amended for the purposes described in such amendment and is signed by the Engineer. 3. Changes: Client reserves the right by written change order or amendment to make changes in requirements, amount of work, or engineering time schedule adjustments, and Engineer and Client shall negotiate appropriate adjustments acceptable to both parties to accommodate any changes, if commercially possible. 4. Suspension of Services: Client may, at any time, by written order to Engineer (Suspension of Services Order), require Engineer to stop all, or any part, of the services required by this Agreement. Upon receipt of such an order, Engineer shall immediately comply with its terms and take all reasonable steps to minimize the costs associated with the services affected by such order. Client, however, shall pay all costs incurred by the suspension, including all costs necessary to maintain continuity and for the resumptions of the services upon expiration of the Suspension of Services Order. Engineer will not be obligated to provide the same personnel employed prior to suspension, when the services are resumed, in the event that the period of suspension is greater than thirty (30) days. 5. Termination: This Agreement may be terminated by either party upon thirty (30) days written notice in the event of substantial failure by the other party to perform in accordance with the terms hereof through no fault of the terminating party. This Agreement may be terminated by Client, under the same terms, whenever Client shall determine that termination is in its best interests. Cost of termination, including salaries, overhead and fee, incurred by Engineer either before or after the termination date shall be reimbursed by Client. 6. Documents Delivered to Client: Drawings, specifications, reports, and any other Project Documents prepared by Engineer in connection with any or all of the services furnished hereunder shall be delivered to the Client for the use of the Client. Engineer shall have the right to retain originals of all Project Documents and drawings for its files. Angela Boulevard Sidewalk Extension 19.R250141.00000 October 31, 2025 6 Furthermore, it is understood and agreed that the Project Documents such as, but not limited to reports, calculations, drawings, and specifications prepared for the Project, whether in hard copy or machine- readable form, are instruments of professional service intended for one-time use in the construction of this Project. These Project Documents are and shall remain the property of the Engineer. The Client may retain copies, including copies stored on magnetic tape or disk, for information and reference in connection with the occupancy and use of the Project. When and if record drawings are to be provided by the Engineer, Client understands that information used in the preparation of record drawings is provided by others and Engineer is not responsible for accuracy, completeness, nor sufficiency of such information. Client also understands that the level of detail illustrated by record drawings will generally be the same as the level of detail illustrated by the design drawing used for project construction. If additional detail is requested by the Client to be included on the record drawings, then the Client understands and agrees that the Engineer will be due additional compensation for additional services. It is also understood and agreed that because of the possibility that information and data delivered in machine readable form may be altered, whether inadvertently or otherwise, the Engineer reserves the right to retain the original tapes/disks and to remove from copies provided to the Client all identification reflecting the involvement of the Engineer in their preparation. The Engineer also reserves the right to retain hard copy originals of all Project Documentation delivered to the Client in machine readable form, which originals shall be referred to and shall govern in the event of any inconsistency between the two. The Client understands that the automated conversion of information and data from the system and format used by the Engineer to an alternate system or format cannot be accomplished without the introduction of inexactitudes, anomalies, and errors. In the event Project Documentation provided to the Client in machine readable form is so converted, the Client agrees to assume all risks associated therewith and, to the fullest extent permitted by law, to hold harmless and indemnify the Engineer from and against all claims, liabilities, losses, damages, and costs, including but not limited to attorney's fees, arising therefrom or in connection therewith. The Client recognizes that changes or modifications to the Engineer's instruments of professional service introduced by anyone other than the Engineer may result in adverse consequences which the Engineer can neither predict nor control. Therefore, and in consideration of the Engineer's agreement to deliver its instruments of professional service in machine readable form, the Client agrees, to the fullest extent permitted by law, to hold harmless and indemnify the Engineer from and against all claims, liabilities, losses, damages, and costs, including but not limited to attorney's fees, arising out of or in any way connected with the modification, misinterpretation, misuse, or reuse by others of the machine readable information and data provided by the Engineer under this Agreement. The foregoing indemnification applies, without limitation, to any use of the Project Documentation on other projects, for additions to this Project, or for completion of this Project by others, excepting only such use as may be authorized, in writing, by the Engineer. 7. Reuse of Documents: All Project Documents including but not limited to reports, opinions of probable costs, drawings and specifications furnished by Engineer pursuant to this Agreement are intended for use on the Project only. They cannot be used by Client or others on extensions of the Project or any other project. Any reuse, without specific written verification or adaptation by Engineer, shall be at Client's sole risk, and Client shall indemnify and hold harmless Engineer from all claims, damages, losses, and expenses including attorney's fees arising out of or resulting therefrom. The Engineer shall have the right to include representations of the design of the Project, including photographs of the exterior and interior, among the Engineer's promotional and professional materials. The Engineer's materials shall not include the Client's confidential and proprietary information if the Client has previously advised the Engineer in writing of the specific information considered by the Client to be confidential and proprietary. Angela Boulevard Sidewalk Extension 19.R250141.00000 October 31, 2025 7 8. Standard of Practice: The Engineer will strive to conduct services under this agreement in a manner consistent with that level of care and skill ordinarily exercised by members of the profession currently practicing in the same locality under similar conditions as of the date of this Agreement. 9. Compliance with Laws: The Engineer will strive to exercise usual and customary professional care in his/her efforts to comply with those laws, codes, ordinance and regulations which are in effect as of the date of this Agreement. With specific respect to prescribed requirements of the Americans with Disabilities Act of 1990 or certified state or local accessibility regulations (ADA), Client understands ADA is a civil rights legislation and that interpretation of ADA is a legal issue and not a design issue and, accordingly, retention of legal counsel (by Client) for purposes of interpretation is advisable. As such and with respect to ADA, Client agrees to waive any action against Engineer, and to indemnify and defend Engineer against any claim arising from Engineer's alleged failure to meet ADA requirements prescribed. Further to the law and code compliance, the Client understands that the Engineer will strive to provide designs in accordance with the prevailing Standards of Practice as previously set forth, but that the Engineer does not warrant that any reviewing agency having jurisdiction will not for its own purposes comment, request changes and/or additions to such designs. In the event such design requests are made by a reviewing agency, but which do not exist in the form of a written regulation, ordinance or other similar document as published by the reviewing agency, then such design changes (at substantial variance from the intended design developed by the Engineer), if effected and incorporated into the project documents by the Engineer, shall be considered as Supplementary Task(s) to the Engineer's Scope of Service and compensated for accordingly. 10. Indemnification: Engineer shall indemnify and hold harmless Client up to the amount of this contract fee (for services) from loss or expense, including reasonable attorney's fees for claims for personal injury (including death) or property damage to the extent caused by the sole negligent act, error or omission of Engineer. Client shall indemnify and hold harmless Engineer under this Agreement, from loss or expense, including reasonable attorney's fees, for claims for personal injuries (including death) or property damage arising out of the sole negligent act, error or omission of Client. In the event of joint or concurrent negligence of Engineer and Client, each shall bear that portion of the loss or expense that its share of the joint or concurrent negligence bears to the total negligence (including that of third parties), which caused the personal injury or property damage. Engineer shall not be liable for special, incidental or consequential damages, including, but not limited to loss of profits, revenue, use of capital, claims of customers, cost of purchased or replacement power, or for any other loss of any nature, whether based on contract, tort, negligence, strict liability or otherwise, by reasons of the services rendered under this Agreement. 11. Opinions of Probable Cost: Since Engineer has no control over the cost of labor, materials or equipment, or over the Contractor(s) method of determining process, or over competitive bidding or market conditions, his/her opinions of probable Project Construction Cost provided for herein are to be made on the basis of his/her experience and qualifications and represent his/her judgment as a design professional familiar with the construction industry, but Engineer cannot and does not guarantee that proposal, bids or the Construction Cost will not vary from opinions of probable construction cost prepared by him/her. If prior to the Bidding or Negotiating Phase, Client wishes greater accuracy as to the Construction Cost, the Client shall employ an independent cost estimator Consultant for the purpose of obtaining a second construction cost opinion independent from Engineer. 12. Governing Law and Dispute Resolutions: This Agreement shall be governed by and construed in accordance with Articles previously set forth by (Item 9 of) this Agreement, together with the laws of the State of Indiana. Angela Boulevard Sidewalk Extension 19.R250141.00000 October 31, 2025 8 Any claim, dispute or other matter in question arising out of or related to this Agreement, which cannot be mutually resolved by the parties of this Agreement, shall be subject to mediation as a condition precedent to arbitration (if arbitration is agreed upon by the parties of this Agreement) or the institution of legal or equitable proceedings by either party. If such matter relates to or is the subject of a lien arising out of the Engineer's services, the Engineer may proceed in accordance with applicable law to comply with the lien notice or filing deadlines prior to resolution of the matter by mediation or by arbitration. The Client and Engineer shall endeavor to resolve claims, disputes and other matters in question between them by mediation which, unless the parties mutually agree otherwise, shall be in accordance with the Construction Industry Mediation Rules of the American Arbitration Association currently in effect. Requests for mediation shall be filed in writing with the other party to this Agreement and with the American Arbitration Association. The request may be made concurrently with the filing of a demand for arbitration but, in such event, mediation shall proceed in advance of arbitration or legal or equitable proceedings, which shall be stayed pending mediation for a period of 60 days from the date of filing, unless stayed for a longer period by agreement of the parties or court order. The parties shall share the mediator's fee and any filing fees equally. The mediation shall be held in the place where the Project is located, unless another location is mutually agreed upon. Agreements reached in mediation shall be enforceable as settlement agreements in any court having jurisdiction thereof. 13. Successors and Assigns: The terms of this Agreement shall be binding upon and inure to the benefit of the parties and their respective successors and assigns, provided, however, that neither party shall assign this Agreement in whole or in part without the prior written approval of the other. 14. Waiver of Contract Breach: The waiver of one party of any breach of this Agreement or the failure of one party to enforce at any time, or for any period of time, any of the provisions hereof, shall be limited to the particular instance, shall not operate or be deemed to waive any future breaches of this Agreement and shall not be construed to be a waiver of any provision, except for the particular instance. 15. Entire Understanding of Agreement: This Agreement represents and incorporates the entire understanding of the parties hereto, and each party acknowledges that there are no warranties, representations, covenants or understandings of any kind, matter or description whatsoever, made by either party to the other except as expressly set forth herein. Client and the Engineer hereby agree that any purchase orders, invoices, confirmations, acknowledgments or other similar documents executed or delivered with respect to the subject matter hereof that conflict with the terms of the Agreement shall be null, void and without effect to the extent they conflict with the terms of this Agreement. 16. Amendment: This Agreement shall not be subject to amendment unless another instrument is duly executed by duly authorized representatives of each of the parties and entitled "Amendment of Agreement." 17. Severability of Invalid Provisions: If any provision of the Agreement shall be held to contravene or to be invalid under the laws of any particular state, county or jurisdiction where used, such contravention shall not invalidate the entire Agreement, but it shall be construed as if not containing the particular provisions held to be invalid in the particular state, country or jurisdiction and the rights or obligations of the parties hereto shall be construed and enforced accordingly. 18. Force Majeure: Neither Client nor Engineer shall be liable for any fault or delay caused by any contingency beyond their control including but not limited to acts of God, wars, strikes, walkouts, fires, natural calamities, or demands or requirements of governmental agencies. 19. Subcontracts: Engineer may subcontract portions of the work, but each subcontractor must be approved by Client in writing. 20. Access and Permits: Client shall arrange for Engineer to enter upon public and private property and obtain all necessary approvals and permits required from all governmental authorities having jurisdiction over the Project. Client shall pay costs Angela Boulevard Sidewalk Extension 19.R250141.00000 October 31, 2025 9 (including Engineer's employee salaries, overhead and fee) incident to any effort by Engineer toward assisting Client in such access, permits or approvals, if Engineer performs such services. 21. Designation of Authorized Representative: Each party (to this Agreement) shall designate one or more persons to act with authority in its behalf in respect to appropriate aspects of the Project. The persons designated shall review and respond promptly to all communications received from the other party. 22. Notices: Any notice or designation required to be given to either party hereto shall be in writing, and unless receipt of such notice is expressly required by the terms hereof shall be deemed to be effectively served when deposited in the mail with sufficient first class postage affixed, and addressed to the party to whom such notice is directed at such party's place of business or such other address as either party shall hereafter furnish to the other party by written notice as herein provided. 23. Limit of Liability: The Client and the Engineer have discussed the risks, rewards, and benefits of the project and the Engineer's total fee for services. In recognition of the relative risks and benefits of the Project to both the Client and the Engineer, the risks have been allocated such that the Client agrees that to the fullest extent permitted by law, the Engineer's total aggregate liability to the Client for any and all injuries, claims, costs, losses, expenses, damages of any nature whatsoever or claim expenses arising out of this Agreement from any cause or causes, including attorney's fees and costs, and expert witness fees and costs, shall not exceed the total Engineer's fee for professional engineering services rendered on this project as made part of this Agreement. Such causes included but are not limited to the Engineer's negligence, errors, omissions, strict liability or breach of contract. It is intended that this limitation apply to any and all liability or cause of action however alleged or arising, unless otherwise prohibited by law. 24. Client's Responsibilities: The Client agrees to provide full information regarding requirements for and about the Project, including a program which shall set forth the Client's objectives, schedule, constraints, criteria, special equipment, systems and site requirements. The Client agrees to furnish and pay for all legal, accounting and insurance counseling services as may be necessary at any time for the Project, including auditing services which the Client may require to verify the Contractor's Application for Payment or to ascertain how or for what purpose the Contractor has used the money paid by or on behalf of the Client. The Client agrees to require the Contractor, to the fullest extent permitted by law, to indemnify, hold harmless, and defend the Engineer, its consultants, and the employees and agents of any of them from and against any and all claims, suits, demands, liabilities, losses, damages, and costs ("Losses"), including but not limited to costs of defense, arising in whole or in part out of the negligence of the Contractor, its subcontractors, the officers, employees, agents, and subcontractors of any of them, or anyone for whose acts any of them may be liable, regardless of whether or not such Losses are caused in part by a party indemnified hereunder. Specifically excluded from the foregoing are Losses arising out of the preparation or approval of maps, drawings, opinions, reports, surveys, change orders, designs, or specifications, and the giving of or failure to give directions by the Engineer, its consultants, and the agents and employees of any of them, provided such giving or failure to give is the primary cause of Loss. The Client also agrees to require the Contractor to provide to the Engineer the required certificate of insurance. The Client further agrees to require the Contractor to name the Engineer, its agents and consultants as additional insureds on the Contractor's policy or policies of comprehensive or commercial general liability insurance. Such insurance shall include products and completed operations and contractual liability coverages, shall be primary and noncontributing with any insurance maintained by the Engineer or its agents and consultants, and shall provide that the Engineer be given thirty days, unqualified written notice prior to any cancellation thereof. In the event the foregoing requirements, or any of them, are not established by the Client and met by the Contractor, the Client agrees to indemnify and hold harmless the Engineer, its employees, agents, and consultants from and against any and all Losses which would have been indemnified and insured against by the Contractor, but were not. Angela Boulevard Sidewalk Extension 19.R250141.00000 October 31, 2025 10 When Contract Documents prepared under the Scope of Services of this contract require insurance(s) to be provided, obtained and/or otherwise maintained by the Contractor, the Client agrees to be wholly responsible for setting forth any and all such insurance requirements. Furthermore, any document provided for Client review by the Engineer under this Contract related to such insurance(s) shall be considered as sample insurance requirements and not the recommendation of the Engineer. Client agrees to have their own risk management department review any and all insurance requirements for adequacy and to determine specific types of insurance(s) required for the project. Client further agrees that decisions concerning types and amounts of insurance are specific to the project and shall be the product of the Client. As such, any and all insurance requirements made part of Contract Documents prepared by the Engineer are not to be considered the Engineer's recommendation, and the Client shall make the final decision regarding insurance requirements. 25. Information Provided by Others: The Engineer shall indicate to the Client the information needed for rendering of the services of this Agreement. The Client shall provide to the Engineer such information as is available to the Client and the Client's consultants and contractors, and the Engineer shall be entitled to rely upon the accuracy and completeness thereof. The Client recognizes that it is impossible for the Engineer to assure the accuracy, completeness and sufficiency of such information, either because it is impossible to verify, or because of errors or omissions which may have occurred in assembling the information the Client is providing. Accordingly, the Client agrees, to the fullest extent permitted by law, to indemnify and hold the Engineer and the Engineer's subconsultants harmless from any claim, liability or cost (including reasonable attorneys' fees and cost of defense) for injury or loss arising or allegedly arising from errors, omissions or inaccuracies in documents or other information provided by the Client to the Engineer. 26. Payment: Client shall be invoiced once each month for work performed during the preceding period. Client agrees to pay each invoice within thirty (30) days of its receipt. The Client further agrees to pay interest on all amounts invoiced and not paid or objected to for valid cause within said thirty (30) day period at the rate of eighteen (18) percent per annum (or the maximum interest rate permitted under applicable law, whichever is the lesser) until paid. Client further agrees to pay Engineer's cost of collection of all amounts due and unpaid after sixty (60) days, including court costs and reasonable attorney's fees, as well as costs attributed to suspension of services accordingly and as follows: Collection Costs. In the event legal action is necessary to enforce the payment provisions of this Agreement, the Engineer shall be entitled to collect from the Client any judgment or settlement sums due, reasonable attorneys' fees, court costs and expenses incurred by the Engineer in connection therewith and, in addition, the reasonable value of the Engineer's time and expenses spent in connection with such collection action, computed at the Engineer's prevailing fee schedule and expense policies. Suspension of Services. If the Client fails to make payments when due or otherwise is in breach of this Agreement, the Engineer may suspend performance of services upon five (5) calendar days' notice to the Client. The Engineer shall have no liability whatsoever to the Client for any costs or damages as a result of such suspension caused by any breach of this Agreement by the Client. Client will reimburse Engineer for all associated costs as previously set forth in (Item 4 of) this Agreement. 27. Indemnity Clause: When construction observation tasks are part of the service to be performed by the Engineer under this Agreement, the Client will include the following clause in the construction contract documents and the Client agrees not to modify or delete it: Contractor (and any subcontractor into whose subcontract this clause is incorporated) agrees and acknowledges that Engineer shall be considered a third party beneficiary of those contracts into which this clause has been incorporated; and agrees to assume the entire liability for all personal injury claims suffered by its employees, including without limitation, claims asserted by persons allegedly injured on the Project; waives any limitation of liability defense based on the Workers’ Compensation Act, court interpretations of said Act or otherwise; and to the fullest extent permitted by Angela Boulevard Sidewalk Extension 19.R250141.00000 October 31, 2025 11 law, agrees to indemnify and hold harmless and defend Owner and Engineer and their agents, employees, and consultants (the “Indemnitees”) from and against any such loss, expense, damage or injury, including attorneys’ fees and costs that the Indemnitees may sustain as a result of such claims. 28. Job Site Safety/Supervision and Construction Observation: The Engineer shall neither have control over or charge of, nor be responsible for, the construction means, methods, techniques, sequences of procedures, or for safety precautions and programs in connection with the Work since they are solely the Contractor's rights and responsibilities. The Client agrees that the Contractor shall supervise and direct the work efficiently with his/her best skill and attention; and that the Contractor shall be solely responsible for the means, methods, techniques, sequences and procedures of construction and safety at the job site. The Client agrees and warrants that this intent shall be carried out in the Client's contract with the Contractor. The Client further agrees that the Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the work; and that the Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to all employees on the subject site and all other persons who may be affected thereby. The Engineer shall have no authority to stop the work of the Contractor or the work of any subcontractor on the project. When construction observation services are included in the Scope of Services, the Engineer shall visit the site at intervals appropriate to the stage of the Contractor's operation, or as otherwise agreed to by the Client and the Engineer to: 1) become generally familiar with and to keep the Client informed about the progress and quality of the Work; 2) to strive to bring to the Client's attention defects and deficiencies in the Work and; 3) to determine in general if the Work is being performed in a manner indicating that the Work, when fully completed, will be in accordance with the Contract Documents. However, the Engineer shall not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. If the Client desires more extensive project observation, the Client shall request that such services be provided by the Engineer as Additional and Supplemental Construction Observation Services in accordance with the terms of this Agreement. The Engineer shall not be responsible for any acts or omissions of the Contractor, subcontractor, any entity performing any portions of the Work, or any agents or employees of any of them. The Engineer does not guarantee the performance of the Contractor and shall not be responsible for the Contractor's failure to perform its Work in accordance with the Contract Documents or any applicable laws, codes, rules or regulations. When municipal review services are included in the Scope of Services, the Engineer (acting on behalf of the municipality), when acting in good faith in the discharge of its duties, shall not thereby render itself liable personally and is, to the maximum extent permitted by law, relieved from all liability for any damage that may accrue to persons or property by reason of any act or omission in the discharge of its duties. Any suit brought against the Engineer which involves the acts or omissions performed by it in the enforcement of any provisions of the Client's rules, regulation and/or ordinance shall be defended by the Client until final termination of the proceedings. The Engineer shall be entitled to all defenses and municipal immunities that are, or would be, available to the Client. 29. Insurance and Indemnification: The Engineer and the Client understand and agree that the Client will contractually require the Contractor to defend and indemnify the Engineer and/or any subconsultants from any claims arising from the Work. The Engineer and the Client further understand and agree that the Client will contractually require the Contractor to procure commercial general liability insurance, naming the Engineer as an additional named insured with respect to the work. The Contractor shall provide to the Client certificates of insurance evidencing that the contractually required insurance coverage has been procured. However, the Contractor’s failure to provide the Client with the requisite certificates of insurance shall not constitute a waiver of this provision by the Engineer. Angela Boulevard Sidewalk Extension 19.R250141.00000 October 31, 2025 12 The Client and Engineer waive all rights against each other and against the Contractor and consultants, agents and employees of each of them for damages to the extent covered by property insurance during construction. The Client and Engineer each shall require similar waivers from the Contractor, consultants, agents and persons or entities awarded separate contracts administered under the Client's own forces. 30. Hazardous Materials/Pollutants: Unless otherwise provided by this Agreement, the Engineer and Engineer's consultants shall have no responsibility for the discovery, presence, handling, removal or disposal of or exposure of persons to hazardous materials/pollutants in any form at the Project site, including but not limited to mold/ mildew, asbestos, asbestos products, polychlorinated biphenyl (PCB) or other toxic/hazardous/pollutant type substances. Furthermore, Client understands that the presence of mold/mildew and the like are results of prolonged or repeated exposure to moisture and the lack of corrective action. Client also understands that corrective action is an operation, maintenance and repair activity for which the Engineer is not responsible. February 23, 2010-INDIANA BOARD OF PUBLIC WORKS AGENDA ITEM REVIEW REQUEST FORM Date 12/2/2025 Name Dan Jones Department DPW BPW Date 12/9/2025 Phone Extension 9245 Review and Approval Required Prior to Submittal to Board Diversity Compliance and Inclusion Officer Officer Name BPW Attorney Attorney Name Dept. Attorney Attorney Name Purchasing Check the Appropriate Item Type –Required for All Submissions Professional Services Agreement Contract Proposal Open Market Contract Amendment/Addendum Special Purchase, QPA Bid Opening Bid Award Req. to Advertise Title Sheet Quote Opening Quote Award Reject Bids/Quotes Proposal Opening C/O & PCA No. PCA Chg. Order, No. Traffic Control Resolution Other: Ease./Encroach Required Information Company or Vendor Name Christopher Burke Engineering, LLC New Vendor Yes If Yes, Approved by Purchasing No MBE/WBE Contractor MBE WBE Completed E-Verify Form Attached Yes No Project Name Angela Blvd & SR23 Sidewalk Improvements Project Number 125-078 Funding Source 429-431002, 429-442001 Account No.PR-44736 Amount $31,200 Terms of Contract Lump Sum, per task Purpose/Description Services agreement to prepare preliminary design options for sidewalk (and crosswalk) improvements near the corner of Angela Blvd & State Road 23. For Change Orders Only Amount of Increase Decrease $ ($ ) Previous Amount $ Current Percent of Change: Increase Decrease % (%) New Amount $ Total Percent of Change: Increase Decrease % (%) Time Extension Amount: New Completion Date: