Loading...
HomeMy WebLinkAboutPSA - Design Services for Well replacments Cleveland and Pinhook Proj No 125-033 - Commonwealth1316 COUNTY -CITY BUILDING 227 W. JEFFERSON BOULEVARD SOUTH BEND, INDIANA 46601-1830 PHONE 574/235-9251 FAx 574/235-9171 CITY OF SOUTH BEND JAMES MUELLER, MAYOR BOARD OF PUBLIC WORKS July 22, 2025 Mr. Jeremy Hardy Commonwealth Engineers, Inc. 100 East Wayne Street, Suite 315 South Bend, IN 46601 j hardy&contactcei. c om RE: Professional Services Agreement Dear Mr. Hardy: At its July 22, 2025 meeting, the Board of Public Works approved the above referenced agreement for design services for the well replacements at Cleveland and Pinhook Water Treatment Plant, Project No. 125-033 in the amount of $207,301. Enclosed please find a copy of the agreement for your records. If you have any further questions, please call this office at (574) 235-9251. Sincerely, /s/HiIlary Horvath Hillary Horvath, Clerk Enclosures HH ELIZABETH A. MARADIK JOSEPH R. MOLNAR GARY A. GILOT MURRAY L. MILLER BREANA N. MIcou Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 This document has important legal consequences; consultation with an attorney is encouraged with respect to its use or modification. This document should be adapted to the particular circumstances of the contemplated Project and the Controlling Laws and Regulations. AGREEMENT BETWEEN OWNER AND ENGINEER FOR PROFESSIONAL SERVICES Prepared by ENGINEERS JOINT CONTRACT DOCUMENTS COMMITTEE EJCDC.-..= ENGINEERS JOINT CONTRACT DOCUMENTS COMMITTEE and Issued and Published Jointly by ACEC AMERICAN CollNCT OF E.NGINEERTNc COM-ES ASCEAmerican Society of Civil Engineers THE ALC GENE Ame �ASSOCKND R qualily "le. 7"7 P.o0d, National Society of Professional Engineers Prefeajenel Engineers in Private Practice AMERICAN COUNCIL OF ENGINEERING COMPANIES ASSOCIATED GENERAL CONTRACTORS OF AMERICA AMERICAN SOCIETY OF CIVIL ENGINEERS PROFESSIONAL ENGINEERS IN PRIVATE PRACTICE A Practice Division of the NATIONAL SOCIETY OF PROFESSIONAL ENGINEERS EJCDC E-500 Standard Form of Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 This Agreement has been prepared for use with the Standard General Conditions of the Construction Contract (EJCDC C-700, 2007 Edition). Their provisions are interrelated, and a change in one may necessitate a change in the other. For guidance on the completion and use of this Agreement, see EJCDC User's Guide to the Owner -Engineer Agreement, EJCDC E-001, 2009 Edition. Copyright © 2008 National Society of Professional Engineers 1420 King Street, Alexandria, VA 22314-2794 (703) 684-2882 www.nspeorg American Council of Engineering Companies 1015 15th Street N.W., Washington, DC 20005 (202) 347-7474 www.acec.org American Society of Civil Engineers 1801 Alexander Bell Drive, Reston, VA 20191-4400 (800) 548-2723 www.asce.org Associated General Contractors of America 2300 Wilson Boulevard, Suite 400, Arlington, VA 22201-3308 (703) 548-3118 The copyright for this EJCDC document is owned jointly by the four EJCDC sponsoring organizations and held in trust for their benefit by NSPE. EJCDC E-500 Standard Form of Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 TABLE OF CONTENTS Page ARTICLE 1— SERVICES OF ENGINEER.................................................................................................... 1 1.01 Scope.............................................................................................................................................1 ARTICLE 2 — OWNER'S RESPONSIBILITIES............................................................................................ 1 2.01 General..........................................................................................................................................1 ARTICLE 3 — SCHEDULE FOR RENDERING SERVICES........................................................................ 2 3.01 Commencement............................................................................................................................ 2 3.02 Time for Completion.................................................................................................................... 2 ARTICLE 4 — INVOICES AND PAYMENTS............................................................................................... 2 4.01 Invoices......................................................................................................................................... 2 4.02 Payments....................................................................................................................................... 2 ARTICLE 5 — OPINIONS OF COST.............................................................................................................. 3 5.01 Opinions of Probable Construction Cost..................................................................................... 3 5.02 Designing to Construction Cost Limit......................................................................................... 3 5.03 Opinions of Total Project Costs................................................................................................... 3 ARTICLE 6 — GENERAL CONSIDERATIONS........................................................................................... 4 6.01 Standards of Performance............................................................................................................ 4 6.02 Design Without Construction Phase Services............................................................................. 5 6.03 Use of Documents........................................................................................................................ 5 6.04 Insurance....................................................................................................................................... 7 6.05 Suspension and Termination........................................................................................................ 8 6.06 Controlling Law............................................................................................................................ 9 6.07 Successors, Assigns, and Beneficiaries........................................................................................ 9 6.08 Dispute Resolution...................................................................................................................... 10 6.09 Environmental Condition of Site................................................................................................ 10 6.10 Indemnification and Mutual Waiver.......................................................................................... 10 6.11 Miscellaneous Provisions........................................................................................................... 11 ARTICLE 7 — DEFINITIONS........................................................................................................................ 12 7.01 Defined Terms............................................................................................................................ 12 ARTICLE 8 — EXHIBITS AND SPECIAL PROVISIONS.......................................................................... 15 8.01 Exhibits Included........................................................................................................................ 15 8.02 Total Agreement......................................................................................................................... 16 8.03 Designated Representatives........................................................................................................ 16 8.04 Engineer's Certifications............................................................................................................. 16 Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 ENGINEERS JOINT CONTRACT DOCUMENTS COMMITTEE AGREEMENT BETWEEN OWNER AND ENGINEER FOR PROFESSIONAL SERVICES THIS IS AN AGREEMENT effective as of ("Effective Date") between Board of Public Works, City of South Bend, Indiana ("Owner") and Commonwealth Engineers, Inc. ("Engineer") Owner's Project, of which Engineer's services under this Agreement are a part, is generally identified as follows: Water Well Replacement Project ("Project"). Engineer's services under this Agreement are generally identified as follows: (a) Preliminary Design. (b) Final Design. (c) Bidding and Ne2otiatina. (d) Construction Services. and the following Additional Services: (e) Well Hydrogeological Design & Permitting Coordination, (i Geotechnical Field Work, and (g) Permit Assistance, as further described in the attached Water Well Replacement Project Description, Scope of Services, and Schedule dated 6/30/2025. Owner and Engineer further agree as follows: ARTICLE 1— SERVICES OF ENGINEER 1.01 Scope A. Engineer shall provide, or cause to be provided, the services set forth herein and in Exhibit A. ARTICLE 2 — OWNER'S RESPONSIBILITIES 2.01 General A. Owner shall have the responsibilities set forth herein and in Exhibit B. B. Owner shall pay Engineer as set forth in Exhibit C. Page 1 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright C 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 C. Owner shall be responsible for, and Engineer may rely upon, the accuracy and completeness of all requirements, programs, instructions, reports, data, and other information furnished by Owner to Engineer pursuant to this Agreement. Engineer may use such requirements, programs, instructions, reports, data, and information in performing or furnishing services under this Agreement. ARTICLE 3 — SCHEDULE FOR RENDERING SERVICES 3.01 Commencement A. Engineer is authorized to begin rendering services as of the Effective Date. 3.02 Time for Completion A. Engineer shall complete its obligations within a reasonable time. Specific periods of time for rendering services are set forth or specific dates by which services are to be completed are provided in Exhibit A, and are hereby agreed to be reasonable. B. If, through no fault of Engineer, such periods of time or dates are changed, or the orderly and continuous progress of Engineer's services is impaired, or Engineer's services are delayed or suspended, then the time for completion of Engineer's services, and the rates and amounts of Engineer's compensation, shall be adjusted equitably. C. If Owner authorizes changes in the scope, extent, or character of the Project, then the time for completion of Engineer's services, and the rates and amounts of Engineer's compensation, shall be adjusted equitably. D. Owner shall make decisions and carry out its other responsibilities in a timely manner so as not to delay the Engineer's performance of its services. E. If Engineer fails, through its own fault, to complete the performance required in this Agreement within the time set forth, as duly adjusted, then Owner shall be entitled, as its sole remedy, to the recovery of direct damages, if any, resulting from such failure. ARTICLE 4 — INVOICES AND PAYMENTS 4.01 Invoices A. Preparation and Submittal of Invoices: Engineer shall prepare invoices in accordance with its standard invoicing practices and the terms of Exhibit C. Engineer shall submit its invoices to Owner on a monthly basis. Invoices are due and payable within 35 days of receipt. 4.02 Payments A. Application to Interest and Principal: Payment will be credited first to any interest owed to Engineer and then to principal. B. Failure to Pay: If Owner fails to make any payment due Engineer for services and expenses within 30 days after receipt of Engineer's invoice, then: Page 2 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 2. Engineer may, after giving seven days written notice to Owner, suspend services under this Agreement until Owner has paid in full all non -disputed amounts due for services, expenses, and other related charges. Owner waives any and all claims against Engineer for any such suspension. C. Disputed Invoices: If Owner contests an invoice, Owner shall promptly advise Engineer of the specific basis for doing so, may withhold only that portion so contested, and must pay the undisputed portion. D. Legislative Actions: If after the Effective Date any governmental entity takes a legislative action that imposes taxes, fees, or charges on Engineer's services or compensation under this Agreement, then the Engineer may invoice such new taxes, fees, or charges as a Reimbursable Expense to which a factor of 1.0 shall be applied. Owner shall reimburse Engineer for the cost of such invoiced new taxes, fees, and charges; such reimbursement shall be in addition to the compensation to which Engineer is entitled under the terms of Exhibit C. ARTICLE 5 — OPINIONS OF COST 5.01 Opinions of Probable Construction Cost A. Engineer's opinions of probable Construction Cost are to be made on the basis of Engineer's experience and qualifications and represent Engineer's best judgment as an experienced and qualified professional generally familiar with the construction industry. However, because Engineer has no control over the cost of labor, materials, equipment, or services furnished by others, or over contractors' methods of determining prices, or over competitive bidding or market conditions, Engineer cannot and does not guarantee that proposals, bids, or actual Construction Cost will not vary from opinions of probable Construction Cost prepared by Engineer. If Owner requires greater assurance as to probable Construction Cost, Owner must employ an independent cost estimator as provided in Exhibit B. 5.02 Designing to Construction Cost Limit A. If a Construction Cost limit is established between Owner and Engineer, such Construction Cost limit and a statement of Engineer's rights and responsibilities with respect thereto will be specifically set forth in Exhibit F, "Construction Cost Limit," to this Agreement. 5.03 Opinions of Total Project Costs A. The services, if any, of Engineer with respect to Total Project Costs shall be limited to assisting the Owner in collating the various cost categories which comprise Total Project Costs. Engineer assumes no responsibility for the accuracy of any opinions of Total Project Costs. Page 3 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 ARTICLE 6 — GENERAL CONSIDERATIONS 6.01 Standards of Performance A. Standard of Care: The standard of care for all professional engineering and related services performed or furnished by Engineer under this Agreement will be the care and skill ordinarily used by members of the subject profession practicing under similar circumstances at the same time and in the same locality. Engineer makes no warranties, express or implied, under this Agreement or otherwise, in connection with Engineer's services. B. Technical Accuracy: Owner shall not be responsible for discovering deficiencies in the technical accuracy of Engineer's services. Engineer shall correct deficiencies in technical accuracy without additional compensation, unless such corrective action is directly attributable to deficiencies in Owner -furnished information. C. Consultants: Engineer may employ such Consultants as Engineer deems necessary to assist in the performance or furnishing of the services, subject to reasonable, timely, and substantive objections by Owner. D. Reliance on Others: Subject to the standard of care set forth in Paragraph 6.0l.A, Engineer and its Consultants may use or rely upon design elements and information ordinarily or customarily furnished by others, including, but not limited to, specialty contractors, manufacturers, suppliers, and the publishers of technical standards. E. Compliance with Laws and Regulations, and Policies and Procedures: 1. Engineer and Owner shall comply with applicable Laws and regulations. 2. Prior to the Effective Date, Owner provided to Engineer in writing any and all policies and procedures of Owner applicable to Engineer's performance of services under this Agreement. provided to Engineer in writing. Engineer shall comply with such policies and procedures, subject to the standard of care set forth in Paragraph 6.0l.A, and to the extent compliance is not inconsistent with professional practice requirements. 3. This Agreement is based on Laws and Regulations and Owner -provided written policies and procedures as of the Effective Date. Changes after the Effective Date to these Laws and Regulations, or to Owner -provided written policies and procedures, may be the basis for modifications to Owner's responsibilities or to Engineer's scope of services, times of performance, or compensation. F. Engineer shall not be required to sign any documents, no matter by whom requested, that would result in the Engineer having to certify, guarantee, or warrant the existence of conditions whose existence the Engineer cannot ascertain. Owner agrees not to make resolution of any dispute with the Engineer or payment of any amount due to the Engineer in any way contingent upon the Engineer signing any such documents. G. The general conditions for any construction contract documents prepared hereunder are to be the "Standard General Conditions of the Construction Contract" as prepared by the Engineers Joint Page 4 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 Contract Documents Committee (EJCDC C-700, 2007 Edition) unless both parties mutually agree to use other general conditions by specific reference in Exhibit J. H. Engineer shall not at any time supervise, direct, control, or have authority over any contractor work, nor shall Engineer have authority over or be responsible for the means, methods, techniques, sequences, or procedures of construction selected or used by any contractor, or the safety precautions and programs incident thereto, for security or safety at the Site, nor for any failure of a contractor to comply with Laws and Regulations applicable to such contractor's furnishing and performing of its work. I. Engineer neither guarantees the performance of any Contractor nor assumes responsibility for any Contractor's failure to furnish and perform the Work in accordance with the Contract Documents. J. Engineer shall not provide or have any responsibility for surety bonding or insurance -related advice, recommendations, counseling, or research, or enforcement of construction insurance or surety bonding requirements. K. Engineer shall not be responsible for the acts or omissions of any Contractor, Subcontractor, or Supplier, or of any of their agents or employees or of any other persons (except Engineer's own agents, employees, and Consultants) at the Site or otherwise furnishing or performing any Work; or for any decision made regarding the Contract Documents, or any application, interpretation, or clarification, of the Contract Documents, other than those made by Engineer. L. While at the Site, Engineer's employees and representatives shall comply with the specific applicable requirements of Contractor's and Owner's safety programs of which Engineer has been informed in writing. 6.02 Design Without Construction Phase Services A. Engineer shall be responsible only for those Construction Phase services expressly required of Engineer in Exhibit A, Paragraph A1.05. With the exception of such expressly required services, Engineer shall have no design, Shop Drawing review, or other obligations during construction and Owner assumes all responsibility for the application and interpretation of the Contract Documents, review and response to Contractor claims, contract administration, processing Change Orders, revisions to the Contract Documents during construction, construction surety bonding and insurance requirements, construction observation and review, review of payment applications, and all other necessary Construction Phase engineering and professional services. Owner waives all claims against the Engineer that may be connected in any way to Construction Phase engineering or professional services except for those services that are expressly required of Engineer in Exhibit A, Paragraph A1.05. 6.03 Use of Documents A. The Owner acknowledges the Engineer's construction documents, including all electronic files, as instruments of professional services. Nevertheless, the final construction documents, including all electronic files, prepared under this agreement shall become the property of the Owner upon completion of services and payment in full of all monies due to the Engineer. The Owner shall not reuse or make any modification to the construction documents without the prior written authorization of the Engineer.All ee;tments afe Page 5 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 pfepefty interest ther-ein (ineluding the eepyr-igl# and the right of reuse at the diser-etion of the Eagineef) whetheF or- not the Prej eetis- cempleted. Owner shall not rely in any way on any Document unless it is in printed form, signed or sealed by the Engineer or one of its Consultants. B. Either parry to this Agreement may rely that data or information set forth on paper (also known as hard copies) that the parry receives from the other party by mail, hand delivery, or facsimile, are the items that the other party intended to send. Files in electronic media format of text, data, graphics, or other types that are furnished by one party to the other are furnished only for convenience, not reliance by the receiving party. Any conclusion or information obtained or derived from such electronic files will be at the user's sole risk. If there is a discrepancy between the electronic files and the hard copies, the hard copies govern. If the parties agree to other electronic transmittal procedures, such are set forth in Exhibit J. C. Because data stored in electronic media format can deteriorate or be modified inadvertently or otherwise without authorization of the data's creator, the party receiving electronic files agrees that it will perform acceptance tests or procedures within 60 days, after which the receiving parry shall be deemed to have accepted the data thus transferred. Any transmittal errors detected within the 60-day acceptance period will be corrected by the party delivering the electronic files. D. When transferring documents in electronic media format, the transferring parry makes no representations as to long-term compatibility, usability, or readability of such documents resulting from the use of software application packages, operating systems, or computer hardware differing from those used by the documents' creator. E. Owner may make and retain copies of Documents for information and reference in connection with use on the Project by Owner. Engineer grants Owner a limited license to use the Documents on the Project, extensions of the Project, and for related uses of the Owner, subject to receipt by Engineer of full payment for all services relating to preparation of the Documents and subject to the following limitations: (1) Owner acknowledges that such Documents are not intended or represented to be suitable for use on the Project unless completed by Engineer, or for use or reuse by Owner or others on extensions of the Project, on any other project, or for any other use or purpose, without written verification or adaptation by Engineer; (2) any such use or reuse, or any modification of the Documents, without written verification, completion, or adaptation by Engineer, as appropriate for the specific purpose intended, will be at Owner's sole risk and without liability or legal exposure to Engineer or to its officers, directors, members, partners, agents, employees, and Consultants; (3) Owner shall indemnify and hold harmless Engineer and its officers, directors, members, partners, agents, employees, and Consultants from all claims, damages, losses, and expenses, including attorneys' fees, arising out of or resulting from any use, reuse, or modification of the Documents without written verification, completion, or adaptation by Engineer; and (4) such limited license to Owner shall not create any rights in third parties. F. If Engineer at Owner's request verifies the suitability of the Documents, completes them, or adapts them for extensions of the Project or for any other purpose, then Owner shall compensate Engineer at rates or in an amount to be agreed upon by Owner and Engineer. G. At completion of any survey services and upon payment of monies due the Engineer for those services, the Engineer shall provide the owner with all survey data and drawings, upon which it will become the property of the Owner. Page 6 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright C 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 H. At completion of any traffic study services and upon payment of monies due the Engineer for those services, the Engineer shall provide the owner with all data and models, upon which it will become the property of the Owner. I. At completion of any geotechnical or material investigation services and upon payment of monies due the Engineer for those services, the Engineer shall provide the owner with all data, upon which it will become the property of the Owner. 6.04 Insurance A. Engineer shall procure and maintain insurance as set forth in Exhibit G, "Insurance." Engineer shall cause Owner to be listed as an additional insured on any applicable general liability insurance policy carried by Engineer. B. Owner shall procure and maintain insurance as set forth in Exhibit G, "Insurance." Owner shall eattse Engineer- and its Consultants to be listed as additional insufeds on any gener-al liabi4y applieable to the Pfejeet. C. Owner shall require Contractor to purchase and maintain policies of insurance covering workers' compensation, general liability, property damage (other than to the Work itself), motor vehicle damage and injuries, and other insurance necessary to protect Owner's and Engineer! interests in the Project. Ow-nef shall r-equir-e Gentraeter- to eause Engineer- and its Consultants to be listed as additional insufeds with r-espeet to sueh liability and other- insur-anee pofehased a -Rd fRaifAakied by D. 9�A%ef an Engineer shall eaelrdeliver to the Owner ether- certificates of insurance evidencing the coverages indicated in Exhibit G. Such certificates shall be furnished prior to commencement of Engineer's services and at renewals thereafter during the life of the Agreement. MI'M� F. All policies of insurance shall contain a provision or endorsement that the coverage afforded will not be canceled or reduced in limits by endorsement, and that renewal will not be refused, until at least 30 days prior written notice has been given to Owner and Engineef and to each other additional insured (if any) to which a certificate of insurance has been issued. G. At any time, Owner may request that Engineer or its Consultants, at Owner's sole expense, provide additional insurance coverage, increased limits, or revised deductibles that are more protective than those specified in Exhibit G. If so requested by Owner, and if commercially available, Engineer shall obtain and shall require its Consultants to obtain such additional insurance coverage, different limits, or revised deductibles for such periods of time as requested by Owner, and Exhibit G will be supplemented to incorporate these requirements. Page 7 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 6.05 Suspension and Termination A. Suspension: 1. By Owner: Owner may suspend the Project for up to 90 days upon seven days written notice to Engineer. 2. By Engineer: Engineer may, after giving seven days written notice to Owner, suspend services under this Agreement if Engineer's performance has been substantially delayed through no fault of Engineer. B. Termination: The obligation to provide further services under this Agreement may be terminated: 1. For cause, a. By either party upon 30 days written notice in the event of substantial failure by the other parry to perform in accordance with the terms hereof through no fault of the terminating party. b. By Engineer: 1) upon seven days written notice if Owner demands that Engineer furnish or perform services contrary to Engineer's responsibilities as a licensed professional; or 2) upon seven days written notice if the Engineer's services for the Project are delayed or suspended for more than 90 days for reasons beyond Engineer's control. 3) Engineer shall have no liability to Owner on account of such termination. C. Notwithstanding the foregoing, this Agreement will not terminate under Paragraph 6.05.B. La if the party receiving such notice begins, within seven days of receipt of such notice, to correct its substantial failure to perform and proceeds diligently to cure such failure within no more than 30 days of receipt thereof; provided, however, that if and to the extent such substantial failure cannot be reasonably cured within such 30 day period, and if such party has diligently attempted to cure the same and thereafter continues diligently to cure the same, then the cure period provided for herein shall extend up to, but in no case more than, 60 days after the date of receipt of the notice. 2. For convenience, a. By Owner effective upon Engineer's receipt of notice from Owner. C. Effective Date of Termination: The terminating party under Paragraph 6.05.B may set the effective date of termination at a time up to 30 days later than otherwise provided to allow Engineer to demobilize personnel and equipment from the Site, to complete tasks whose value Page 8 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 would otherwise be lost, to prepare notes as to the status of completed and uncompleted tasks, and to assemble Project materials in orderly files. D. Payments Upon Termination: In the event of any termination under Paragraph 6.05, Engineer will be entitled to invoice Owner and to receive full payment for all services performed or furnished in accordance with this Agreement and all Reimbursable Expenses incurred through the effective date of termination. Upon making such payment, Owner shall have the limited right to the use of Documents, at Owner's sole risk, subject to the provisions of Paragraph 6.03.E. 2. In the event of termination by Owner for convenience or by Engineer for cause, Engineer shall be entitled, in addition to invoicing for those items identified in Paragraph 6.05.D.1, to invoice Owner and to payment of a reasonable amount for services and expenses directly attributable to termination, both before and after the effective date of termination, such as reassignment of personnel, costs of terminating contracts with Engineer's Consultants, and other related close-out costs, using methods and rates for Additional Services as set forth in Exhibit C. 6.06 Controlling Law A. This Agreement is to be governed by the law of the state or jurisdiction in which the Project is located. 6.07 Successors, Assigns, and Beneficiaries A. Owner and Engineer are hereby bound and the successors, executors, administrators, and legal representatives of Owner and Engineer (and to the extent permitted by Paragraph 6.07.B the assigns of Owner and Engineer) are hereby bound to the other parry to this Agreement and to the successors, executors, administrators and legal representatives (and said assigns) of such other party, in respect of all covenants, agreements, and obligations of this Agreement. B. Neither Owner nor Engineer may assign, sublet, or transfer any rights under or interest (including, but without limitation, moneys that are due or may become due) in this Agreement without the written consent of the other, except to the extent that any assignment, subletting, or transfer is mandated or restricted by law. Unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under this Agreement. C. Unless expressly provided otherwise in this Agreement: Nothing in this Agreement shall be construed to create, impose, or give rise to any duty owed by Owner or Engineer to any Contractor, Subcontractor, Supplier, other individual or entity, or to any surety for or employee of any of them. 2. All duties and responsibilities undertaken pursuant to this Agreement will be for the sole and exclusive benefit of Owner and Engineer and not for the benefit of any other parry. 3. Owner agrees that the substance of the provisions of this Paragraph 6.07.0 shall appear in the Contract Documents. Page 9 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 6.08 Dispute Resolution A. OAnef and Engineer- agfee to negotiate all dispu4es between them in good faith for- a period of 30 Elays 4em the date of notiee prior- to 4voking the pr-eeedtwes of Exhibit 14 or- other pFevisiefis E) this , o e�ier-eising their- rights undeF law-. B. , then either- of both may invoke the pr-oeedufes of Exh 1��If Exhibit H is not included, or if no dispute resolution method is specified in Exhibit H, then the parties may exercise their rights under law. 6.09 Environmental Condition of Site A. Owner has disclosed to Engineer in writing the existence of all known and suspected Asbestos, PCBs, Petroleum, Hazardous Waste, Radioactive Material, hazardous substances, and other Constituents of Concern located at or near the Site, including type, quantity, and location. B. Owner represents to Engineer that to the best of its knowledge no Constituents of Concern, other than those disclosed in writing to Engineer, exist at the Site. C. If Engineer encounters or learns of an undisclosed Constituent of Concern at the Site, then Engineer shall notify (1) Owner and (2) appropriate governmental officials if Engineer reasonably concludes that doing so is required by applicable Laws or Regulations. D. It is acknowledged by both parties that Engineer's scope of services does not include any services related to Constituents of Concern. If Engineer or any other parry encounters an undisclosed Constituent of Concern, or if investigative or remedial action, or other professional services, are necessary with respect to disclosed or undisclosed Constituents of Concern, then Engineer may, at its option and without liability for consequential or any other damages, suspend performance of services on the portion of the Project affected thereby until Owner: (1) retains appropriate specialist consultants or contractors to identify and, as appropriate, abate, remediate, or remove the Constituents of Concern; and (2) warrants that the Site is in full compliance with applicable Laws and Regulations. E. If the presence at the Site of undisclosed Constituents of Concern adversely affects the performance of Engineer's services under this Agreement, then the Engineer shall have the option of (1) accepting an equitable adjustment in its compensation or in the time of completion, or both; or (2) terminating this Agreement for cause on 30 days notice. F. Owner acknowledges that Engineer is performing professional services for Owner and that Engineer is not and shall not be required to become an "owner" "arranger," "operator," "generator," or "transporter" of hazardous substances, as defined in the Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA), as amended, which are or may be encountered at or near the Site in connection with Engineer's activities under this Agreement. 6.10 Indemnification and Mutual Waiver A. Indemnification by Engineer: To the fullest extent permitted by law, Engineer shall indemnify and hold harmless Owner, and Owner's officers, directors, members, partners, agents, consultants, and employees from reasonable claims, costs, losses, and damages arising out of or relating to the Page 10 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 Project, provided that any such claim, cost, loss, or damage is attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom, but only to the extent caused by any negligent act or omission of Engineer or Engineer's officers, directors, members, partners, agents, employees, or Consultants. This indemnification provision is subject to and limited by the provisions, if any, agreed to by Owner and Engineer in Exhibit I, "Limitations of Liability." B. Indemnification by Owner: Owner shall indemnify and hold harmless Engineer and its officers, directors, members, partners, agents, employees, and Consultants as required by Laws and Regulations and to the extent (if any) required in Exhibit I, Limitations of Liability. C. Environmental Indemnification: To the fullest extent permitted by law, Owner shall indemnify and hold harmless Engineer and its officers, directors, members, partners, agents, employees, and Consultants from and against any and all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys and other professionals, and all court, arbitration, or other dispute resolution costs) caused by, arising out of, relating to, or resulting from a Constituent of Concern at, on, or under the Site, provided that (1) any such claim, cost, loss, or damage is attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom, and (2) nothing in this paragraph shall obligate Owner to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence or willful misconduct. D. Percentage Share of Negligence: To the fullest extent permitted by law, a party's total liability to the other parry and anyone claiming by, through, or under the other parry for any cost, loss, or damages caused in part by the negligence of the party and in part by the negligence of the other parry or any other negligent entity or individual, shall not exceed the percentage share that the party's negligence bears to the total negligence of Owner, Engineer, and all other negligent entities and individuals. E. Mutual Waiver: To the fullest extent permitted by law, Owner and Engineer waive against each other, and the other's employees, officers, directors, members, agents, insurers, partners, and consultants, any and all claims for or entitlement to special, incidental, indirect, or consequential damages arising out of, resulting from, or in any way related to the Project. 6.11 Miscellaneous Provisions A. Notices: Any notice required under this Agreement will be in writing, addressed to the appropriate party at its address on the signature page and given personally, by facsimile, by registered or certified mail postage prepaid, or by a commercial courier service. All notices shall be effective upon the date of receipt. B. Survival: All express representations, waivers, indemnifications, and limitations of liability included in this Agreement will survive its completion or termination for any reason. C. Severability: Any provision or part of the Agreement held to be void or unenforceable under any Laws or Regulations shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon Owner and Engineer, which agree that the Agreement shall be reformed to Page 11 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provision. D. Waiver: A party's non -enforcement of any provision shall not constitute a waiver of that provision, nor shall it affect the enforceability of that provision or of the remainder of this Agreement. E. Accrual of Claims: To the fullest extent permitted by law, all causes of action arising under this Agreement shall be deemed to have accrued, and all statutory periods of limitation shall commence, no later than the date of Substantial Completion. ARTICLE 7 — DEFINITIONS 7.01 Defined Terms A. Wherever used in this Agreement (including the Exhibits hereto) terms (including the singular and plural forms) printed with initial capital letters have the meanings indicated in the text above, in the exhibits, or in the following provisions: 1. Additional Services — The services to be performed for or furnished to Owner by Engineer in accordance with Part 2 of Exhibit A of this Agreement. 2. Agreement — This written contract for professional services between Owner and Engineer, including all exhibits identified in Paragraph 8.01 and any duly executed amendments. 3. Asbestos — Any material that contains more than one percent asbestos and is friable or is releasing asbestos fibers into the air above current action levels established by the United States Occupational Safety and Health Administration. 4. Basic Services — The services to be performed for or furnished to Owner by Engineer in accordance with Part 1 of Exhibit A of this Agreement. 5. Construction Contract — The entire and integrated written agreement between Owner and Contractor concerning the Work. 6. Construction Cost — The cost to Owner of those portions of the entire Project designed or specified by Engineer. Construction Cost does not include costs of services of Engineer or other design professionals and consultants; cost of land or rights -of -way, or compensation for damages to properties; Owner's costs for legal, accounting, insurance counseling or auditing services; interest or financing charges incurred in connection with the Project; or the cost of other services to be provided by others to Owner pursuant to Exhibit B of this Agreement. Construction Cost is one of the items comprising Total Project Costs. 7. Constituent of Concern — Any substance, product, waste, or other material of any nature whatsoever (including, but not limited to, Asbestos, Petroleum, Radioactive Material, and PCBs) which is or becomes listed, regulated, or addressed pursuant to (a) the Comprehensive Environmental Response, Compensation and Liability Act, 42 U.S.C. §§9601 et seq. ("CERCLA"); (b) the Hazardous Materials Transportation Act, 49 U.S.C. Page 12 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 §§1801 et seq.; (c) the Resource Conservation and Recovery Act, 42 U.S.C. §§6901 et seq. ("RCRA"); (d) the Toxic Substances Control Act, 15 U.S.C. §§2601 et seq.; (e) the Clean Water Act, 33 U.S.C. §§1251 et seq.; (f) the Clean Air Act, 42 U.S.C. §§7401 et seq.; and (g) any other federal, state, or local statute, law, rule, regulation, ordinance, resolution, code, order, or decree regulating, relating to, or imposing liability or standards of conduct concerning, any hazardous, toxic, or dangerous waste, substance, or material. Consultants — Individuals or entities having a contract with Engineer to furnish services with respect to this Project as Engineer's independent professional associates and consultants; subcontractors; or vendors. 9. Contract Documents — Those items so designated in the Construction Contract, including the Drawings, Specifications, construction agreement, and general and supplementary conditions. Only printed or hard copies of the items listed in the Construction Contract are Contract Documents. Approved Shop Drawings, other Contractor submittals, and the reports and drawings of subsurface and physical conditions are not Contract Documents. 10. Contractor — The entity or individual with which Owner has entered into a Construction Contract. 11. Documents — Data, reports, Drawings, Specifications, Record Drawings, and other deliverables, whether in printed or electronic media format, provided or furnished in appropriate phases by Engineer to Owner pursuant to this Agreement. 12. Drawings — That part of the Contract Documents prepared or approved by Engineer which graphically shows the scope, extent, and character of the Work to be performed by Contractor. Shop Drawings are not Drawings as so defined. 13. Effective Date — The date indicated in this Agreement on which it becomes effective, but if no such date is indicated, the date on which this Agreement is signed and delivered by the last of the parties to sign and deliver. 14. Engineer — The individual or entity named as such in this Agreement. 15. Hazardous Waste — The term Hazardous Waste shall have the meaning provided in Section 1004 of the Solid Waste Disposal Act (42 USC Section 6903) as amended from time to time. 16. Laws and Regulations; Laws or Regulations — Any and all applicable laws, rules, regulations, ordinances, codes, and orders of any and all governmental bodies, agencies, authorities, and courts having jurisdiction. 17. Owner — The individual or entity with which Engineer has entered into this Agreement and for which the Engineer's services are to be performed. Unless indicated otherwise, this is the same individual or entity that will enter into any Construction Contracts concerning the Project. 18. PCBs — Polychlorinated biphenyls. Page 13 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 19. Petroleum — Petroleum, including crude oil or any fraction thereof which is liquid at standard conditions of temperature and pressure (60 degrees Fahrenheit and 14.7 pounds per square inch absolute), such as oil, petroleum, fuel oil, oil sludge, oil refuse, gasoline, kerosene, and oil mixed with other non -hazardous waste and crude oils. 20. Project — The total construction of which the Work to be performed under the Contract Documents may be the whole, or a part. 21. Radioactive Material — Source, special nuclear, or byproduct material as defined by the Atomic Energy Act of 1954 (42 USC Section 2011 et seq.) as amended from time to time. 22. Record Drawings — Drawings depicting the completed Project, prepared by Engineer as an Additional Service and based solely on Contractor's record copy of all Drawings, Specifications, addenda, change orders, work change directives, field orders, and written interpretations and clarifications, as delivered to Engineer and annotated by Contractor to show changes made during construction. 23. Reimbursable Expenses — The expenses incurred directly by Engineer in connection with the performing or furnishing of Basic and Additional Services for the Project. 24. Resident Project Representative — The authorized representative of Engineer assigned to assist Engineer at the Site during the Construction Phase. As used herein, the term Resident Project Representative or "RPR" includes any assistants or field staff of Resident Project Representative agreed to by Owner. The duties and responsibilities of the Resident Project Representative, if any, are as set forth in Exhibit D. 25. Samples — Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and which establish the standards by which such portion of the Work will be judged. 26. Shop Drawings — All drawings, diagrams, illustrations, schedules, and other data or information which are specifically prepared or assembled by or for Contractor and submitted by Contractor to illustrate some portion of the Work. 27. Site — Lands or areas to be indicated in the Contract Documents as being furnished by Owner upon which the Work is to be performed, including rights -of -way and easements for access thereto, and such other lands furnished by Owner which are designated for the use of Contractor. 28. Specifications — That part of the Contract Documents consisting of written technical descriptions of materials, equipment, systems, standards, and workmanship as applied to the Work and certain administrative details applicable thereto. 29. Subcontractor — An individual or entity having a direct contract with Contractor or with any other Subcontractor for the performance of a part of the Work at the Site. 30. Substantial Completion — The time at which the Work (or a specified part thereof) has progressed to the point where, in the opinion of Engineer, the Work (or a specified part thereof) is sufficiently complete, in accordance with the Contract Documents, so that the Page 14 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 Work (or a specified part thereof) can be utilized for the purposes for which it is intended. The terms "substantially complete" and "substantially completed" as applied to all or part of the Work refer to Substantial Completion thereof. 31. Supplier — A manufacturer, fabricator, supplier, distributor, materialman, or vendor having a direct contract with Contractor or with any Subcontractor to furnish materials or equipment to be incorporated in the Work by Contractor or Subcontractor. 32. Total Project Costs — The sum of the Construction Cost, allowances for contingencies, and the total costs of services of Engineer or other design professionals and consultants, together with such other Project -related costs that Owner furnishes for inclusion, including but not limited to cost of land, rights -of -way, compensation for damages to properties, Owner's costs for legal, accounting, insurance counseling and auditing services, interest and financing charges incurred in connection with the Project, and the cost of other services to be provided by others to Owner pursuant to Exhibit B of this Agreement. 33. Work — The entire construction or the various separately identifiable parts thereof required to be provided under the Contract Documents. Work includes and is the result of performing or providing all labor, services, and documentation necessary to produce such construction, and furnishing, installing, and incorporating all materials and equipment into such construction, all as required by the Contract Documents. ARTICLE 8 — EXHIBITS AND SPECIAL PROVISIONS 8.01 Exhibits Included: A. Exhibit A, Engineer's Services. B. Exhibit B, Owner's Responsibilities. C. Exhibit C, Payments to Engineer for Services and Reimbursable Expenses. D. EAiibit D, Duties, Responsibilities and Limitations of Authofity of Resident Pf0ject. NOT INCLUDED E. Exhibit E, Notice of Acceptability of Work. F. Exhibit F, reef..,,,,+,., Cost r iflnit NOT INCLUDED G. Exhibit G, Insurance. H. Exhibit H, Dispttte .NOT INCLUDED I. Exhibit I, Limitations of Liability. J. Exhibit J, Special Provisions. K. EAiibitKAmexdment to Ovmel`Engineer- Agreement-. NOT INCLUDED Page 15 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 8.02 Total Agreement: A. This Agreement, (together with the exhibits identified above) constitutes the entire agreement between Owner and Engineer and supersedes all prior written or oral understandings. This Agreement may only be amended, supplemented, modified, or canceled by a duly executed written instrument based on the format of Exhibit K to this Agreement. 8.03 Designated Representatives: A. With the execution of this Agreement, Engineer and Owner shall designate specific individuals to act as Engineer's and Owner's representatives with respect to the services to be performed or furnished by Engineer and responsibilities of Owner under this Agreement. Such an individual shall have authority to transmit instructions, receive information, and render decisions relative to the Project on behalf of the respective party whom the individual represents. 8.04 Engineer's Certifications: A. Engineer certifies that it has not engaged in corrupt, fraudulent, or coercive practices in competing for or in executing the Agreement. For the purposes of this Paragraph 8.04: 1. "corrupt practice" means the offering, giving, receiving, or soliciting of any thing of value likely to influence the action of a public official in the selection process or in the Agreement execution; 2. "fraudulent practice" means an intentional misrepresentation of facts made (a) to influence the selection process or the execution of the Agreement to the detriment of Owner, or (b) to deprive Owner of the benefits of free and open competition; 3. "coercive practice" means harming or threatening to harm, directly or indirectly, persons or their property to influence their participation in the selection process or affect the execution of the Agreement. Page 16 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 IN WITNESS WHEREOF, the parties hereto have executed this Agreement, the Effective Date of which is indicated on page 1. Owner: CITY OF SOUTH BEND, INDIANA BOARD OF PUBLIC WORKS Elizabeth A. Maradik, President Joseph R. Molnar, Vice President OA 5�q A&t- Gary A. Gilot, Member Breana Micou, Member Murray L. Miller, Member ATTEST: Madeline Hostetler, Acting Clerk Date: July 22, 2025 Engineer: Commonwealth EnEn ineers, Inc. By: Title: Al ert C. Stong, P.E. President Date: 7/1 /2025 Engineer License or Firm's Certificate No. State of. Indiana Address for giving notices: Address for giving notices: 227 West Jefferson Boulevard 100 East Wayne Street, Suite 315 South Bend, Indiana 46601 South Bend, Indiana 46601 Designated Representative (Paragraph 8.03.A): Eric Horvath. P.E. Title: Director of Public Works Phone Number: (574) 235-5932 E-Mail Address: ehorvath(a),southbendin.gov 10201336 Designated Representative (Paragraph 8.03.A): Jeremy D. Hardy, P.E. Title: Partner, Project Manager / Office Manager Phone Number: (574) 800-1171 E-Mail Address: jhardy(a,contactcei.com Page 17 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 This is EXHIBIT A, consisting of 12 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated Engineer's Services Article 1 of the Agreement is supplemented to include the following agreement of the parties. Engineer shall provide Basic and Additional Services as set forth below. PART 1— BASIC SERVICES Y Page 1 (Exhibit A — Engineer's Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright c0 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 � � � .�!tsses!�.s�r_serrl_e�s� • A1.02 Preliminary Design Phase A. After acceptance by Owner of the Report and any other deliverables, selection by Owner of a recommended solution and indication of any specific modifications or changes in the scope, extent, character, or design requirements of the Project desired by Owner, and upon written authorization from Owner, Engineer shall: Prepare Preliminary Design Phase documents consisting of final design criteria, preliminary drawings, outline specifications, and written descriptions of the Project. 2. Provide necessary field surveys and topographic and utility mapping for design purposes. Utility mapping will be based upon information obtained from utility owners. 3. Advise Owner if additional reports, data, information, or services of the types described in Exhibit B are necessary and assist Owner in obtaining such reports, data, information, or services. 4. Based on the information contained in the Preliminary Design Phase documents, prepare a revised opinion of probable Construction Cost, and assist Owner in collating the various cost categories which comprise Total Project Costs. 5. Perform or provide the following additional Preliminary Design Phase tasks or deliverables: See attached Scone of Services. Tasks 1-4. 6. Furnish 4 review copies of the Preliminary Design Phase documents and any other deliverables to Owner within 60 calendar days of authorization to proceed with this phase, and review them with Owner. Within 14 calendar days of receipt, Owner shall submit to Engineer any comments regarding the Preliminary Design Phase documents and any other deliverables. 7. Revise the Preliminary Design Phase documents and any other deliverables in response to Owner's comments, as appropriate, and furnish to Owner 4 copies of the revised Preliminary Design Phase documents, revised opinion of probable Construction Cost, and any other deliverables within 60 calendar days after receipt of Owner's comments. B. Engineer's services under the Preliminary Design Phase will be considered complete on the date when the revised Preliminary Design Phase documents, revised opinion of probable Construction Cost, and any other deliverables have been delivered to Owner. Page 2 (Exhibit A — Engineer's Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 A1.03 Final Design Phase A. After acceptance by Owner of the Preliminary Design Phase documents, revised opinion of probable Construction Cost as determined in the Preliminary Design Phase, and any other deliverables subject to any Owner -directed modifications or changes in the scope, extent, character, or design requirements of or for the Project, and upon written authorization from Owner, Engineer shall: 1. Prepare final Drawings and Specifications indicating the scope, extent, and character of the Work to be performed and furnished by Contractor. 2. Provide technical criteria, written descriptions, and design data for Owner's use in filing applications for permits from or approvals of governmental authorities having jurisdiction to review or approve the final design of the Project; assist Owner in consultations with such authorities; and revise the Drawings and Specifications in response to directives from such authorities. 3. Advise Owner of any adjustments to the opinion of probable Construction Cost known to Engineer. 4. Perform or provide the following additional Final Design Phase tasks or deliverables: See Basic Scope of Engineering Services, Task 5. 5. Prepare and furnish bidding documents for review by Owner, its legal counsel, and other advisors, and assist Owner in the preparation of other related documents. Within 14 days of receipt, Owner shall submit to Engineer any comments and, subject to the provisions of Paragraph 6.0LG, instructions for revisions. 6. Revise the bidding documents in accordance with comments and instructions from the Owner, as appropriate, and submit 4 final copies of the bidding documents, a revised opinion of probable Construction Cost, and any other deliverables to Owner within 14 calendar days after receipt of Owner's comments and instructions. B. Engineer's services under the Final Design Phase will be considered complete on the date when the submittals required by Paragraph A1.03.A.6 have been delivered to Owner. C. In the event that the Work designed or specified by Engineer is to be performed or furnished under more than one prime contract, or if Engineer's services are to be separately sequenced with the work of one or more prime Contractors (such as in the case of fast -tracking), Owner and Engineer shall, prior to commencement of the Final Design Phase, develop a schedule for performance of Engineer's services during the Final Design, Bidding or Negotiating, Construction, and Post - Construction Phases in order to sequence and coordinate properly such services as are applicable to the work under such separate prime contracts. This schedule is to be prepared and included in or become an amendment to Exhibit A whether or not the work under such contracts is to proceed concurrently. D. The number of prime contracts for Work designed or specified by Engineer upon which the Engineer's compensation has been established under this Agreement is one (1). If more prime Page 3 (Exhibit A — Engineer's Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 contracts are awarded, Engineer shall be entitled to an equitable increase in its compensation under this Agreement. A 1.04 Bidding or Negotiating Phase A. After acceptance by Owner of the bidding documents and the most recent opinion of probable Construction Cost as determined in the Final Design Phase, and upon written authorization by Owner to proceed, Engineer shall: Assist Owner in advertising for and obtaining bids or proposals for the Work and, where applicable, maintain a record of prospective bidders to whom Bidding Documents have been issued, attend pre -bid conferences, if any, and receive and process contractor deposits or charges for the bidding documents. 2. Issue addenda as appropriate to clarify, correct, or change the bidding documents. 3. Provide information or assistance needed by Owner in the course of any negotiations with prospective contractors. 4. Consult with Owner as to the acceptability of subcontractors, suppliers, and other individuals and entities proposed by prospective contractors for those portions of the Work as to which such acceptability is required by the bidding documents. 5. If bidding documents require, the Engineer shall evaluate and determine the acceptability of "or equals" and substitute materials and equipment proposed by bidders, but subject to the provisions of paragraph A2.02.A.2 of this Exhibit A. 6. Attend the Bid opening, prepare Bid tabulation sheets, and assist Owner in evaluating Bids or proposals and in assembling and awarding contracts for the Work. 7. Perform or provide the following additional Bidding or Negotiating Phase tasks or deliverables: See Basic Scope of Engineering Services, Task 8 B. The Bidding or Negotiating Phase will be considered complete upon commencement of the Construction Phase or upon cessation of negotiations with prospective contractors (except as may be required if Exhibit F is a part of this Agreement). A1.05 Construction Phase A. Upon successful completion of the Bidding and Negotiating Phase, and upon written authorization from Owner, Engineer shall: General Administration of Construction Contract: Consult with Owner and act as Owner's representative as provided in the Construction Contract. The extent and limitations of the duties, responsibilities, and authority of Engineer as assigned in the Construction Contract shall not be modified, except as Engineer may otherwise agree in writing. All of Owner's instructions to Contractor will be issued through Engineer, which shall have authority to act on behalf of Owner in dealings with Contractor to the extent provided in this Agreement and the Construction Contract except as otherwise provided in writing. Page 4 (Exhibit A — Engineer's Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 2. Resident Project Representative (RPR): DELETED 3. Selecting Independent Testing Laboratory: Assist Owner in the selection of an independent testing laboratory to perform the services identified in Exhibit B, Paragraph B2.01.0. 4. Pre -Construction Conference: Participate in a Pre -Construction Conference prior to commencement of Work at the Site. 5. Schedules: Receive, review, and determine the acceptability of any and all schedules that Contractor is required to submit to Engineer, including the Progress Schedule, Schedule of Submittals, and Schedule of Values. 6. Baselines and Benchmarks: As appropriate, establish baselines and benchmarks for locating the Work which in Engineer's judgment are necessary to enable Contractor to proceed. 7. Visits to Site and Observation of Construction: In connection with observations of Contractor's Work while it is in progress: a. Make visits to the Site at intervals appropriate to the various stages of construction, as Engineer deems necessary, to observe as an experienced and qualified design professional the progress of Contractor's executed Work. Such visits and observations by Engineer, and the Resident Project Representative, if any, are not intended to be exhaustive or to extend to every aspect of Contractor's Work in progress or to involve detailed inspections of Contractor's Work in progress beyond the responsibilities specifically assigned to Engineer in this Agreement and the Contract Documents, but rather are to be limited to spot checking, selective sampling, and similar methods of general observation of the Work based on Engineer's exercise of professional judgment, as assisted by the Resident Project Representative, if any. Based on information obtained during such visits and observations, Engineer will determine in general if the Work is proceeding in accordance with the Contract Documents, and Engineer shall keep Owner informed of the progress of the Work. b. The purpose of Engineer's visits to, and representation by the Resident Project Representative, if any, at the Site, will be to enable Engineer to better carry out the duties and responsibilities assigned to and undertaken by Engineer during the Construction Phase, and, in addition, by the exercise of Engineer's efforts as an experienced and qualified design professional, to provide for Owner a greater degree of confidence that the completed Work will conform in general to the Contract Documents and that Contractor has implemented and maintained the integrity of the design concept of the completed Project as a functioning whole as indicated in the Contract Documents. Engineer shall not, during such visits or as a result of such observations of Contractor's Work in progress, supervise, direct, or have control over Contractor's Work, nor shall Engineer have authority over or responsibility for the means, methods, techniques, sequences, or procedures of construction selected or used by Contractor, for security or safety at the Site, for safety precautions and programs incident to Contractor's Work, nor for any failure of Contractor to comply with Laws Page 5 (Exhibit A — Engineer's Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 and Regulations applicable to Contractor's furnishing and performing the Work. Accordingly, Engineer neither guarantees the performance of any Contractor nor assumes responsibility for any Contractor's failure to furnish or perform the Work in accordance with the Contract Documents. 8. Defective Work: Reject Work if, on the basis of Engineer's observations, Engineer believes that such Work (a) is defective under the standards set forth in the Contract Documents, (b) will not produce a completed Project that conforms to the Contract Documents, or (c) will imperil the integrity of the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. 9. Clarifications and Interpretations; Field Orders: Issue necessary clarifications and interpretations of the Contract Documents as appropriate to the orderly completion of Contractor's work. Such clarifications and interpretations will be consistent with the intent of and reasonably inferable from the Contract Documents. Subject to any limitations in the Contract Documents, Engineer may issue field orders authorizing minor variations in the Work from the requirements of the Contract Documents. 10. Change Orders and Work Change Directives: Recommend change orders and work change directives to Owner, as appropriate, and prepare change orders and work change directives as required. 11. Shop Drawings and Samples: Review and approve or take other appropriate action in respect to Shop Drawings and Samples and other data which Contractor is required to submit, but only for conformance with the information given in the Contract Documents and compatibility with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. Such reviews and approvals or other action will not extend to means, methods, techniques, sequences, or procedures of construction or to safety precautions and programs incident thereto. Engineer shall meet any Contractor's submittal schedule that Engineer has accepted. 12. Substitutes and "or -equal ": Evaluate and determine the acceptability of substitute or "or - equal" materials and equipment proposed by Contractor, but subject to the provisions of Paragraph A2.02.A.2 of this Exhibit A. 13. Inspections and Tests: Require such special inspections or tests of Contractor's work as deemed reasonably necessary, and receive and review all certificates of inspections, tests, and approvals required by Laws and Regulations or the Contract Documents. Engineer's review of such certificates will be for the purpose of determining that the results certified indicate compliance with the Contract Documents and will not constitute an independent evaluation that the content or procedures of such inspections, tests, or approvals comply with the requirements of the Contract Documents. Engineer shall be entitled to rely on the results of such tests. 14. Disagreements between Owner and Contractor: Render formal written decisions on all duly submitted issues relating to the acceptability of Contractor's work or the interpretation of the requirements of the Contract Documents pertaining to the execution, performance, or progress of Contractor's Work; review each duly submitted Claim by Page 6 (Exhibit A — Engineer's Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 Owner or Contractor, and in writing either deny such Claim in whole or in part, approve such Claim, or decline to resolve such Claim if Engineer in its discretion concludes that to do so would be inappropriate. In rendering such decisions, Engineer shall be fair and not show partiality to Owner or Contractor and shall not be liable in connection with any decision rendered in good faith in such capacity. 15. Applications for Payment: Based on Engineer's observations as an experienced and qualified design professional and on review of Applications for Payment and accompanying supporting documentation: a. Determine the amounts that Engineer recommends Contractor be paid. Such recommendations of payment will be in writing and will constitute Engineer's representation to Owner, based on such observations and review, that, to the best of Engineer's knowledge, information and belief, Contractor's Work has progressed to the point indicated, the Work is generally in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning whole prior to or upon Substantial Completion, to the results of any subsequent tests called for in the Contract Documents, and to any other qualifications stated in the recommendation), and the conditions precedent to Contractor's being entitled to such payment appear to have been fulfilled in so far as it is Engineer's responsibility to observe Contractor's Work. In the case of unit price work, Engineer's recommendations of payment will include final determinations of quantities and classifications of Contractor's Work (subject to any subsequent adjustments allowed by the Contract Documents). b. By recommending any payment, Engineer shall not thereby be deemed to have represented that observations made by Engineer to check the quality or quantity of Contractor's Work as it is performed and furnished have been exhaustive, extended to every aspect of Contractor's Work in progress, or involved detailed inspections of the Work beyond the responsibilities specifically assigned to Engineer in this Agreement and the Contract Documents. Neither Engineer's review of Contractor's Work for the purposes of recommending payments nor Engineer's recommendation of any payment including final payment will impose on Engineer responsibility to supervise, direct, or control Contractor's Work in progress or for the means, methods, techniques, sequences, or procedures of construction or safety precautions or programs incident thereto, or Contractor's compliance with Laws and Regulations applicable to Contractor's furnishing and performing the Work. It will also not impose responsibility on Engineer to make any examination to ascertain how or for what purposes Contractor has used the moneys paid on account of the Contract Price, or to determine that title to any portion of the Work in progress, materials, or equipment has passed to Owner free and clear of any liens, claims, security interests, or encumbrances, or that there may not be other matters at issue between Owner and Contractor that might affect the amount that should be paid. 16. Contractor's Completion Documents: Receive, review, and transmit to Owner maintenance and operating instructions, schedules, guarantees, bonds, certificates or other evidence of insurance required by the Contract Documents, certificates of inspection, tests and approvals, Shop Drawings, Samples and other data approved as provided under Paragraph A1.05.A.11, and transmit the annotated record documents which are to be Page 7 (Exhibit A — Engineer's Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 assembled by Contractor in accordance with the Contract Documents to obtain final payment. The extent of such review by Engineer will be limited as provided in Paragraph A1.05.A.11. 17. Substantial Completion: Promptly after notice from Contractor that Contractor considers the entire Work ready for its intended use, in company with Owner and Contractor, visit the Project to determine if the Work is substantially complete. If after considering any objections of Owner, Engineer considers the Work substantially complete, Engineer shall deliver a certificate of Substantial Completion to Owner and Contractor. 18. Additional Tasks: Perform or provide the following additional Construction Phase tasks or deliverables: See Basic Scope of Engineering Services, Task 9. 19. Final Notice of Acceptability of the Work: Conduct a final visit to the Project to determine if the completed Work of Contractor is acceptable so that Engineer may recommend, in writing, final payment to Contractor. Accompanying the recommendation for final payment, Engineer shall also provide a notice in the form attached hereto as Exhibit E (the "Notice of Acceptability of Work") that the Work is acceptable (subject to the provisions of Paragraph Al. 05.A.15.b) to the best of Engineer's knowledge, information, and belief and based on the extent of the services provided by Engineer under this Agreement. B. Duration of Construction Phase: The Construction Phase will commence with the execution of the first Construction Contract for the Project or any part thereof and will terminate upon written recommendation by Engineer for final payment to Contractors. If the Project involves more than one prime contract as indicated in Paragraph A1.03.C, then Construction Phase services may be rendered at different times in respect to the separate contracts. Subject to the provisions of Article 3, Engineer shall be entitled to an equitable increase in compensation if Construction Phase services (including Resident Project Representative services, if any) are required after the original date for completion and readiness for final payment of Contractor as set forth in the Construction Contract. C. Limitation of Responsibilities: Engineer shall not be responsible for the acts or omissions of any Contractor, Subcontractor or Supplier, or other individuals or entities performing or furnishing any of the Work, for safety or security at the Site, or for safety precautions and programs incident to Contractor's Work, during the Construction Phase or otherwise. Engineer shall not be responsible for the failure of any Contractor to perform or furnish the Work in accordance with the Contract Documents. Page 8 (Exhibit A — Engineer's Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 !*liS.Tisri .nq 11 J= 11 ''1 1 1 111 1 IN PART 2 — ADDITIONAL SERVICES A2.01 Additional Services Requiring Owner's Written Authorization A. If authorized in writing by Owner, Engineer shall furnish or obtain from others Additional Services of the types listed below. 1. Preparation of applications and supporting documents (in addition to those furnished under Basic Services) for private or governmental grants, loans, or advances in connection with the Project; preparation or review of environmental assessments and impact statements; review and evaluation of the effects on the design requirements for the Project of any such statements and documents prepared by others; and assistance in obtaining approvals of authorities having jurisdiction over the anticipated environmental impact of the Project. 2. Services to make measured drawings of or to investigate existing conditions or facilities, or to verify the accuracy of drawings or other information furnished by Owner or others. 3. Services resulting from significant changes in the scope, extent, or character of the portions of the Project designed or specified by Engineer or its design requirements including, but not limited to, changes in size, complexity, Owner's schedule, character of construction, or method of financing; and revising previously accepted studies, reports, Drawings, Specifications, or Contract Documents when such revisions are required by changes in Laws and Regulations enacted subsequent to the Effective Date or are due to any other causes beyond Engineer's control. 4. Services resulting from Owner's request to evaluate additional Study and Report Phase alternative solutions beyond those identified in Paragraph A1.0I.A.4. Services required as a result of Owner's providing incomplete or incorrect Project information to Engineer. 6. Providing renderings or models for Owner's use. 7. Undertaking investigations and studies including, but not limited to, detailed consideration of operations, maintenance, and overhead expenses; the preparation of financial feasibility and cash flow studies, rate schedules, and appraisals; assistance in obtaining financing for the Project; evaluating processes available for licensing, and assisting Owner in obtaining Page 9 (Exhibit A — Engineer's Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 process licensing; detailed quantity surveys of materials, equipment, and labor; and audits or inventories required in connection with construction performed by Owner. 8. Furnishing services of Consultants for other than Basic Services. 9. Services attributable to more prime construction contracts than specified in Paragraph A 1.03.D. 10. Services during out-of-town travel required of Engineer other than for visits to the Site or Owner's office. 11. Preparing for, coordinating with, participating in and responding to structured independent review processes, including, but not limited to, construction management, cost estimating, project peer review, value engineering, and constructibility review requested by Owner; and performing or furnishing services required to revise studies, reports, Drawings, Specifications, or other Bidding Documents as a result of such review processes. 12. Preparing additional Bidding Documents or Contract Documents for alternate bids or prices requested by Owner for the Work or a portion thereof. 13. Assistance in connection with Bid protests, rebidding, or renegotiating contracts for construction, materials, equipment, or services, except when such assistance is required by Exhibit F. 14. Providing construction surveys and staking to enable Contractor to perform its work other than as required under Paragraph A1.05.A.6, and any type of property surveys or related engineering services needed for the transfer of interests in real property; and providing other special field surveys. 15. Providing Construction Phase services beyond the original date for completion and readiness for final payment of Contractor. 16. Providing assistance in responding to the presence of any Constituent of Concern at the Site, in compliance with current Laws and Regulations. 17. Preparing Record Drawings showing appropriate record information based on Project annotated record documents received from Contractor, and furnishing such Record Drawings to Owner. 18. Preparation of operation and maintenance manuals. 19. Preparing to serve or serving as a consultant or witness for Owner in any litigation, arbitration, or other dispute resolution process related to the Project. 20. Providing more extensive services required to enable Engineer to issue notices or certifications requested by Owner. 21. Assistance in connection with the adjusting of Project equipment and systems. Page 10 (Exhibit A — Engineer's Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 22. Assistance to Owner in training Owner's staff to operate and maintain Project equipment and systems. 23. Assistance to Owner in developing procedures for (a) control of the operation and maintenance of Project equipment and systems, and (b) related record -keeping. 24. Overtime work requiring higher than regular rates. 25. Other services performed or furnished by Engineer not otherwise provided for in this Agreement. A2.02 Additional Services Not Requiring Owner's Written Authorization A. Engineer shall advise Owner in advance that Engineer is will immediately commence to perform or furnish the Additional Services of the types listed below. For such Additional Services, Engineer need not request or obtain specific advance written authorization from Owner. Engineer shall cease performing or furnishing such Additional Services upon receipt of written notice from Owner. Services in connection with work change directives and change orders to reflect changes requested by Owner. 2. Services in making revisions to Drawings and Specifications occasioned by the acceptance of substitute materials or equipment other than "or -equal" items; services after the award of the Construction Contract in evaluating and determining the acceptability of a proposed "or equal" or substitution which is found to be inappropriate for the Project; evaluation and determination of an excessive number of proposed "or equals" or substitutions, whether proposed before or after award of the Construction Contract. 3. Services resulting from significant delays, changes, or price increases occurring as a direct or indirect result of materials, equipment, or energy shortages. 4. Additional or extended services during construction made necessary by (1) emergencies or acts of God endangering the Work (advance notice not required), (2) the presence at the Site of any Constituent of Concern or items of historical or cultural significance, (3) Work damaged by fire or other cause during construction, (4) a significant amount of defective, neglected, or delayed work by Contractor, (5) acceleration of the progress schedule involving services beyond normal working hours, or (6) default by Contractor. 5. Services (other than Basic Services during the Post -Construction Phase) in connection with any partial utilization of any part of the Work by Owner prior to Substantial Completion. 6. Evaluating an unreasonable claim or an excessive number of claims submitted by Contractor or others in connection with the Work. 7. Services during the Construction Phase rendered after the original date for completion of the Work referred to in A1.05.B. Page 11 (Exhibit A — Engineer's Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 8. Reviewing a Shop Drawing more than three times, as a result of repeated inadequate submissions by Contractor. 9. While at the Site, compliance by Engineer and its staff with those terms of Owner's or Contractor's safety program provided to Engineer subsequent to the Effective Date that exceed those normally required of engineering personnel by federal, state, or local safety authorities for similar construction sites. Page 12 (Exhibit A — Engineer's Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 This is EXHIBIT B, consisting of 3 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated Owner's Responsibilities Article 2 of the Agreement is supplemented to include the following agreement of the parties. B2.01 In addition to other responsibilities of Owner as set forth in this Agreement, Owner shall at its expense: A. Provide Engineer with all criteria and full information as to Owner's requirements for the Project, including design objectives and constraints, space, capacity and performance requirements, flexibility, and expandability, and any budgetary limitations; and furnish copies of all design and construction standards which Owner will require to be included in the Drawings and Specifications; and furnish copies of Owner's standard forms, conditions, and related documents for Engineer to include in the Bidding Documents, when applicable. B. Furnish to Engineer any other available information pertinent to the Project including reports and data relative to previous designs, or investigation at or adjacent to the Site. C. Following Engineer's assessment of initially -available Project information and data and upon Engineer's request, furnish or otherwise make available such additional Project related information and data as is reasonably required to enable Engineer to complete its Basic and Additional Services. Such additional information or data would generally include the following: 1. Property descriptions. 2. Zoning, deed, and other land use restrictions. 3. Property, boundary, easement, right-of-way, and other special surveys or data, including establishing relevant reference points. 4. Explorations and tests of subsurface conditions at or contiguous to the Site, drawings of physical conditions relating to existing surface or subsurface structures at the Site, or hydrographic surveys, with appropriate professional interpretation thereof. 5. Environmental assessments, audits, investigations, and impact statements, and other relevant environmental or cultural studies as to the Project, the Site, and adjacent areas. 6. Data or consultations as required for the Project but not otherwise identified in the Agreement or the Exhibits thereto. D. Give prompt written notice to Engineer whenever Owner observes or otherwise becomes aware of the presence at the Site of any Constituent of Concern, or of any other development that affects the scope or time of performance of Engineer's services, or any defect or nonconformance in Engineer's services, the Work, or in the performance of any Contractor. Page 1 (Exhibit B — Owner's Responsibilities) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 E. Authorize Engineer to provide Additional Services as set forth in Part 2 of Exhibit A of the Agreement as required. F. Arrange for safe access to and make all provisions for Engineer to enter upon public and private property as required for Engineer to perform services under the Agreement. G. Examine all alternate solutions, studies, reports, sketches, Drawings, Specifications, proposals, and other documents presented by Engineer (including obtaining advice of an attorney, insurance counselor, and other advisors or consultants as Owner deems appropriate with respect to such examination) and render in writing timely decisions pertaining thereto. H. Provide reviews, approvals, and permits from all governmental authorities having jurisdiction to approve all phases of the Project designed or specified by Engineer and such reviews, approvals, and consents from others as may be necessary for completion of each phase of the Project. I. Recognizing and acknowledging that Engineer's services and expertise do not include the following services, provide, as required for the Project: 1. Accounting, bond and financial advisory, independent cost estimating, and insurance counseling services. 2. Legal services with regard to issues pertaining to the Project as Owner requires, Contractor raises, or Engineer reasonably requests. 3. Such auditing services as Owner requires to ascertain how or for what purpose Contractor has used the moneys paid. J. Place and pay for advertisement for Bids in appropriate publications. K. Advise Engineer of the identity and scope of services of any independent consultants employed by Owner to perform or furnish services in regard to the Project, including, but not limited to, cost estimating, project peer review, value engineering, and constructibility review. L. Furnish to Engineer data as to Owner's anticipated costs for services to be provided by others (including, but not limited to, accounting, bond and financial, independent cost estimating, insurance counseling, and legal advice) for Owner so that Engineer may assist Owner in collating the various cost categories which comprise Total Project Costs. M. If Owner designates a construction manager or an individual or entity other than, or in addition to, Engineer to represent Owner at the Site, define and set forth as an attachment to this Exhibit B the duties, responsibilities, and limitations of authority of such other party and the relation thereof to the duties, responsibilities, and authority of Engineer. N. If more than one prime contract is to be awarded for the Work designed or specified by Engineer, designate a person or entity to have authority and responsibility for coordinating the activities among the various prime Contractors, and define and set forth the duties, responsibilities, and limitations of authority of such individual or entity and the relation thereof to the duties, Page 2 (Exhibit B — Owner's Responsibilities) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 responsibilities, and authority of Engineer as an attachment to this Exhibit B that is to be mutually agreed upon and made a part of this Agreement before such services begin. O. Attend the pre -bid conference, bid opening, pre -construction conferences, construction progress and other job related meetings, and Substantial Completion and final payment visits to the Project. P. Provide the services of an independent testing laboratory to perform all inspections, tests, and approvals of samples, materials, and equipment required by the Contract Documents, or to evaluate the performance of materials, equipment, and facilities of Owner, prior to their incorporation into the Work with appropriate professional interpretation thereof. Q. Provide Engineer with the findings and reports generated by the entities providing services to Owner pursuant to this paragraph. R. Inform Engineer in writing of any specific requirements of safety or security programs that are applicable to Engineer, as a visitor to the Site. S. Perform or provide the following additional services: N/A. Page 3 (Exhibit B — Owner's Responsibilities) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. i i Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 I i. t-;ompensanon for lsasic services gnoi including Resident Project Representative) (as described in Exhibit A, Part I) Decision Question: Which method of compensation is to be used? Percentage of Direct Labor Direct Labor Lump Standard Hourly Construction Costs Times a Costs Plus Salary Costs Sum Rates Costs Factor Overhead Plus a Times a Factor Fixed Fee Use This Base packet Compensation Packet BC-2 Packet BC-3 Packet BC-4 Packet BC-5 Packet BC-6 Packet BC -I Include This N/A Appendices I and 2 N/A Appendix 1 Appendix 1 Appendix 1 Appendix 2. Compensation for Resident Project Representative (as described in Exhibit A, Paragraph A1.05.A.2, and in Exhibit D) Decision Question: Which method of compensation is to be used? Standard Hourly Percentage ofDirect Labor Costs Salary Costs Times a Lump Sum Rates Construction Times a Factor Factor Costs Use This RPR Compensation Packet RPR-I Packet RPR-2 Packet RPR-3 Packet RPR-4 Packet RPR-5 Packet Include This NSA Appendices 1 N/A Appendix 1 Appendix 1 Appendix and 2 Page 1 (Exhibit C — Compensation Decision Guide) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 3. Compensation for Additional Services (as described in Exhibit A, Part 2) Decision Question: Which method of compensation is to be used? Standard Hourly Rates Direct Labor Costs Times a Factor Salary Costs Times a Factor Use This Additional Services Packet AS-1 Packet AS-2 Packet AS-3 Compensation Packet Include This Appendices 1 and 2 Appendix 1 Appendix 1 Appendix Example: If Basic Services (other than RPR) will be compensated using Lump Sum; RPR services using Direct Labor Times a Factor; and Additional Services using Standard Hourly Rates; then use Packet BC-1; Packet RPR-4; Packet AS-1; and Appendices 1 and 2 to form Exhibit C. Page 2 (Exhibit C — Compensation Decision Guide) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 SUGGESTED FORMAT (for use with E-500, 2008 Edition) This is EXHIBIT C, consisting of 2 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated Payments to Engineer for Services and Reimbursable Expenses COMPENSATION PACKET BC-1: Basic Services — LumD Sum Article 2 of the Agreement is supplemented to include the following agreement of the parties: ARTICLE 2 — OWNER'S RESPONSIBILITIES C2.01 Compensation for Basic Services (other than Resident Project Representative) — Lump Sum Method of Payment A. Owner shall pay Engineer for Basic Services set forth in Exhibit A, except for services of Engineer's Resident Project Representative, if any, as follows: 1. A Lump Sum amount of $125,591 based on the following estimated distribution of compensation: a. Study and Report Phase N/A b. Preliminary Design Phase $102,889 c. Final Design Phase $22,702 d. Bidding and Negotiating Phase See BC-2 e. Construction Phase See BC-2 £ Post -Construction Phase N/A 2. Engineer may alter the distribution of compensation between individual phases noted herein to be consistent with services actually rendered, but shall not exceed the total Lump Sum amount unless approved in writing by the Owner. 3. The Lump Sum includes compensation for Engineer's services and services of Engineer's Consultants, if any. Appropriate amounts have been incorporated in the Lump Sum to account for labor, overhead, profit, and Reimbursable Expenses. 4. The portion of the Lump Sum amount billed for Engineer's services will be based upon Engineer's estimate of the percentage of the total services actually completed during the billing period. Page 1 Exhibit C —Compensation Packet BC-1: Basic Services (other than RPR) — Lump Sum Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 B. Period of Service: The compensation amount stipulated in Compensation Packet BC-1 is conditioned on a period of service not exceeding eight 8 months. If such period of service is extended, the compensation amount for Engineer's services shall be appropriately adjusted. Page 2 Exhibit C —Compensation Packet BC-1: Basic Services (other than RPR) — Lump Sum Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 This is EXHIBIT C, consisting of 3 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated Payments to Engineer for Services and Reimbursable Expenses COMPENSATION PACKET BC-2: Basic Services — Standard Hourly Rates Article 2 of the Agreement is supplemented to include the following agreement of the parties: ARTICLE 2 — OWNER'S RESPONSIBILITIES C2.01 Compensation For Basic Services (other than Resident Project Representative) — Standard Hourly Rates Method of Payment A. Owner shall pay Engineer for Basic Services set forth in Exhibit A, except for services of Engineer's Resident Project Representative, if any, as follows: 1. An amount equal to the cumulative hours charged to the Project by each class of Engineer's personnel times Standard Hourly Rates for each applicable billing class for all services performed on the Project, plus Reimbursable Expenses and Engineer's Consultants' charges, if any. 2. Engineer's Reimbursable Expenses Schedule and Standard Hourly Rates are attached to this Exhibit C as Appendices 1 and 2. 3. The total compensation for services under Paragraph C2.01 is estimated to be $57,662 based on the following estimated distribution of compensation: a. Study and Report Phase N/A b. Preliminary Design Phase See BC-1 c. Final Design Phase See BC-1 d. Bidding or Negotiating Phase $13,225 e. Construction Phase $44,437 f. Post -Construction Phase N/A 4. Engineer may alter the distribution of compensation between individual phases of the work noted herein to be consistent with services actually rendered, but shall not exceed the total estimated compensation amount unless approved in writing by Owner. See also C2.03.C.2 below. 5. The total estimated compensation for Engineer's services included in the breakdown by phases as noted in Paragraph C2.01.A.3 incorporates all labor, overhead, profit, Reimbursable Expenses and Engineer's Consultants' charges. Page 1 Exhibit C —Compensation Packet BC-2: Basic Services (other than RPR) — Standard Hourly Rates Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 6. The amounts billed for Engineer's services under Paragraph C2.01 will be based on the cumulative hours charged to the Project during the billing period by each class of Engineer's employees times Standard Hourly Rates for each applicable billing class, plus Reimbursable Expenses and Engineer's Consultants' charges. 7. The Standard Hourly Rates and Reimbursable Expenses Schedule will be adjusted annually (as of Jules) to reflect equitable changes in the compensation payable to Engineer. C2.02 Compensation For Reimbursable Expenses A. Owner shall pay Engineer for all Reimbursable Expenses at the rates set forth in Appendix 1 to this Exhibit C. B. Reimbursable Expenses include the following categories: transportation and subsistence incidental thereto; providing and maintaining field office facilities including furnishings and utilities; toll telephone calls and mobile phone charges; reproduction of reports, Drawings, Specifications, Bidding Documents, and similar Project -related items in addition to those required under Exhibit A. In addition, if authorized in advance by Owner, Reimbursable Expenses will also include expenses incurred for the use of highly specialized equipment. C. The amounts payable to Engineer for Reimbursable Expenses will be the Project -related internal expenses actually incurred or allocated by Engineer, plus all invoiced external Reimbursable Expenses allocable to the Project, the latter multiplied by a factor of 1.15. C2.03 Other Provisions Concerning Payment A. Whenever Engineer is entitled to compensation for the charges of Engineer's Consultants, those charges shall be the amounts billed by Engineer's Consultants to Engineer times a factor of 1.15. B. Factors. The external Reimbursable Expenses and Engineer's Consultants' factors include Engineer's overhead and profit associated with Engineer's responsibility for the administration of such services and costs. Page 2 Exhibit C —Compensation Packet BC-2: Basic Services (other than RPR) — Standard Hourly Rates Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 C. Estimated Compensation Amounts: 1. Engineer's estimate of the amounts that will become payable for specified services are only estimates for planning purposes, are not binding on the parties, and are not the minimum or maximum amounts payable to Engineer under the Agreement. 2. When estimated compensation amounts have been stated herein and it subsequently becomes apparent to Engineer that the total compensation amount thus estimated will be exceeded, Engineer shall give Owner written notice thereof, allowing Owner to consider its options, including suspension or termination of Engineer's services for Owner's convenience. Upon notice, Owner and Engineer promptly shall review the matter of services remaining to be performed and compensation for such services. Owner shall either exercise its right to suspend or terminate Engineer's services for Owner's convenience, agree to such compensation exceeding said estimated amount, or agree to a reduction in the remaining services to be rendered by Engineer, so that total compensation for such services will not exceed said estimated amount when such services are completed. If Owner decides not to suspend the Engineer's services during the negotiations and Engineer exceeds the estimated amount before Owner and Engineer have agreed to an increase in the compensation due Engineer or a reduction in the remaining services, then Engineer shall be paid for all services rendered hereunder. D. To the extent necessary to verify Engineer's charges and upon Owner's timely request, Engineer shall make copies of such records available to Owner at cost. Page 3 Exhibit C —Compensation Packet BC-2: Basic Services (other than RPR) — Standard Hourly Rates Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 COMPENSATION PACKET AS-1: Additional Services — Standard Hourly Rates Article 2 of the Agreement is supplemented to include the following agreement of the parties: C2.05 Compensation for Additional Services — Standard Hourly Rates Method of Payment A. Owner shall pay Engineer for Additional Services, if any, as follows: 1. General: For services of Engineer's personnel engaged directly on the Project pursuant to Paragraph A2.01 or A2.02 of Exhibit A, except for services as a consultant or witness under Paragraph A2.01.A.20, (which if needed shall be separately negotiated based on the nature of the required consultation or testimony) an amount equal to the cumulative hours charged to the Project by each class of Engineer's personnel times Standard Hourly Rates for each applicable billing class for all Additional Services performed on the Project, plus related Reimbursable Expenses and Engineer's Consultant's charges, if any. The total compensation under this para�_raph is estimated to be $24,048.00 and this amount shall not be exceeded without written approval of Owner. An itemized estimate of this amount shall be attached as Exhibit J to this Agreement. B. Compensation For Reimbursable Expenses: 1. For those Reimbursable Expenses that are not accounted for in the compensation for Basic Services under Paragraph C2.01 and are directly related to the provision of Additional Services, Owner shall pay Engineer at the rates set forth in Appendix 1 to this Exhibit C. 2. Reimbursable Expenses include the following categories: transportation and subsistence incidental thereto; providing and maintaining field office facilities including furnishings and utilities; toll telephone calls and mobile phone charges; reproduction of reports, Drawings, Specifications, Bidding Documents, and similar Project -related items in addition to those required under Exhibit A. In addition, if authorized in advance by Owner, Reimbursable Expenses will also include expenses incurred for the use of highly specialized equipment. The amounts payable to Engineer for Reimbursable Expenses, if any, will be the Additional Services -related internal expenses actually incurred or allocated by Engineer, plus all invoiced external Reimbursable Expenses allocable to such Additional Services, the latter multiplied by a factor of 1.15. 4. The Reimbursable Expenses Schedule will be adjusted annually (as of July P5 to reflect equitable changes in the compensation payable to Engineer. C. Other Provisions Concerning Payment For Additional Services: 1. Whenever Engineer is entitled to compensation for the charges of Engineer's Consultants, those charges shall be the amounts billed by Engineer's Consultants to Engineer times a factor of 1.15. Page 1 Exhibit C — Compensation Packet AS-3: Additional Services — Salary Costs Times a Factor Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 2. Factors: The external Reimbursable Expenses and Engineer's Consultant's Factors include Engineer's overhead and profit associated with Engineer's responsibility for the administration of such services and costs. To the extent necessary to verify Engineer's charges and upon Owner's timely request, Engineer shall make copies of such records available to Owner at cost. Page 2 Exhibit C — Compensation Packet AS-3: Additional Services — Salary Costs Times a Factor Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 This is Appendix 1 to EXHIBIT C, consisting of 1 page, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated Reimbursable Expenses Schedule Current agreements for engineering services stipulate that the Reimbursable Expenses are subject to review and adjustment per Exhibit C. Reimbursable expenses for services performed on the date of the Agreement are: Reimbursable Expenses 1. Travel: Starts at the office and shall be at the then approved rate by the U.S. Internal Revenue Service, plus 15% profit. 2. Subsistence and Lodging: Actual Cost, plus 15% profit. 3. Express Charges and Postage, other than first class mail: Actual Cost, plus 15% profit. 4. Paper Prints: $0.75 per square foot, plus 15% profit. 5. Special Tests and Services of Special Consultants (not used without specific written consent of Owner): Actual Costs, plus 15% profit. Page 1 Exhibit C — Appendix 1: Reimbursable Expenses Schedule EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 This is Appendix 2 to EXHIBIT C, consisting of 2 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated Standard Hourly Rates Schedule A. Standard Hourly Rates: 1. Standard Hourly Rates are set forth in this Appendix 2 to this Exhibit C and include salaries and wages paid to personnel in each billing class plus the cost of customary and statutory benefits, general and administrative overhead, non -project operating costs, and operating margin or profit. 2. The Standard Hourly Rates apply only as specified in Article C2. B. Schedule: Hourly rates for services performed on or after the date of the Agreement are attached hereto: Page 1 Exhibit C — Appendix 2: Standard Hourly Rates Schedule EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 COMMONWEALTH ENGINEERS, INC. STANDARD HOURLY RATES AND REIMBURSABLE EXPENSES SCHEDULE July 1, 2025 - June 30, 2026 Billing Class Rate Per Hour Billing Class Rate Per Hour Principal III $ 126.20 Environmental Scientist II $ 38.64 Principal II $ 115.80 Environmental Scientist 1 $ 34.81 Principal $ 105.85 Construction Manager $ 66.23 Project Manager IV $ 104.76 Project Manager III $ 98.01 Resident Project Representative IV $ 52.52 Project Manager II $ 79.93 Resident Project Representative III $ 43.67 Project Manager 1 $ 71.96 Resident Project Representative 11 $ 39.42 Resident Project Representative 1 $ 35.15 Senior Electrical Engineer $ 98.01 Clerical III $ 43.68 Senior Process Engineer $ 86.70 Clerical II $ 32.87 Clerical $ 24.11 Project Engineer IV $ 81.37 Project Engineer III $ 65.27 Reproduction Processor $ 30.14 Project Engineer 11 $ 61.47 Project Engineer 1 $ 56.99 Trainee $ 23.42 Engineering Intern III $ 50.66 CADD Specialist IV $ 49.56 Engineering Intern II $ 47.64 CADD Specialist III $ 45.03 Engineering Intern 1 $ 42.97 CADD Specialist II $ 38.51 CADD Specialist 1 $ 30.84 Designer IV $ 63.09 Designer III $ 57.77 Chief Technology Officer $ 73.68 Designer 11 $ 52.12 IT Tech $ 34.40 Designer 1 $ 42.07 Multimedia Coordinator $ 58.47 Operations Specialist $ 51.31 Survey Manager $ 67.49 Surveyor $ 53.15 Project Surveyor $ 47.98 Field Technician $ 40.62 Environmental $ 62.19 Compliance Manager Compliance Specialist $ 34.81 Grants Manager $ 66.98 In order to arrive at the total billing rate, the above direct payroll rates shall be multiplied by factors of 56.4556% and 87.4236% to account for payroll and general overhead costs respectively. In addition, a 15% profit level is then added to arrive at total labor costs. This is a total multiplier factor of 3.3722 times direct payroll rates. Reimbursable Expenses 1. Travel: Starts at the office and shall be at the then approved rate by the U.S. Internal Revenue Service, plus 15% profit. 2. Subsistence and Lodging: Actual Cost, plus 15% profit. 3. Express Charges and Postage, other than first class mail: Actual Cost, plus 15% profit. 4. Paper Prints: $0.75 per square foot, plus 15% profit. 5. Special Tests and Services of Special Consultants: Actual Costs, plus 15% profit. It is agreed that the Owner will make payment of each invoice presented by Commonwealth within thirty (30) days from the date of the invoice. Payments received after this time shall be subject to an interest charge of 1 % per month. Page 2 Exhibit C - Appendix 2: Standard Hourly Rates Schedule EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright Oc 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 This is EXHIBIT E, consisting of 2 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated NOTICE OF ACCEPTABILITY OF WORK PROJECT: OWNER: CONTRACTOR: OWNER'S CONSTRUCTION CONTRACT IDENTIFICATION: EFFECTIVE DATE OF THE CONSTRUCTION CONTRACT: ENGINEER: NOTICE DATE: To: Owner And To: Contractor From: Engineer The Engineer hereby gives notice to the above Owner and Contractor that the completed Work furnished and performed by Contractor under the above Contract is acceptable, expressly subject to the provisions of the related Contract Documents, the Agreement between Owner and Engineer for Professional Services dated , and the terms and conditions set forth in this Notice. LE Title: Dated: Page 1 (Exhibit E — Notice of Acceptability of Work) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 CONDITIONS OF NOTICE OF ACCEPTABILITY OF WORK The Notice of Acceptability of Work ("Notice") is expressly made subject to the following terms and conditions to which all those who receive said Notice and rely thereon agree: 1. This Notice is given with the skill and care ordinarily used by members of the engineering profession practicing under similar conditions at the same time and in the same locality. 2. This Notice reflects and is an expression of the professional judgment of Engineer. 3. This Notice is given as to the best of Engineer's knowledge, information, and belief as of the Notice Date. 4. This Notice is based entirely on and expressly limited by the scope of services Engineer has been employed by Owner to perform or furnish during construction of the Project (including observation of the Contractor's work) under Engineer's Agreement with Owner and under the Construction Contract referred to in this Notice, and applies only to facts that are within Engineer's knowledge or could reasonably have been ascertained by Engineer as a result of carrying out the responsibilities specifically assigned to Engineer under such Agreement and Construction Contract. This Notice is not a guarantee or warranty of Contractor's performance under the Construction Contract referred to in this Notice, nor an assumption of responsibility for any failure of Contractor to furnish and perform the Work thereunder in accordance with the Contract Documents. Page 2 (Exhibit E — Notice of Acceptability of Work) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 This is EXHIBIT G, consisting of 2 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated Insurance Paragraph 6.04 of the Agreement is supplemented to include the following agreement of the parties. G6.04 Insurance A. The limits of liability for the insurance required by Paragraph 6.04.A and 6.04.13 of the Agreement are as follows: 1. By Engineer: a. Workers' Compensation: b. Employer's Liability -- 1) Each Accident: 2) Disease, Policy Limit: 3) Disease, Each Employee: c. General Liability -- 1) Each Occurrence (Bodily Injury and Property Damage): 2) General Aggregate: d. Excess or Umbrella Liability -- 1) Each Occurrence: 2) General Aggregate: Statutory $1,000,000 $1,000,000 $1,000,000 $1,000,000 $2,000,000 $1,000,000 $1,000,000 e. Automobile Liability --Combined Single Limit (Bodily Injury and Property Damage): Each Accident f. Professional Liability — 1) Each Claim Made 2) Annual Aggregate g. Other (specify): 2. By Owner: $1,000,000 $1,000,000 $1,000,000 Page 1 (Exhibit G - Insurance) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 a. The City of South Bend is a municipal corporation organized under the laws of the State of Indiana, and is self -insured under provisions of Indiana statutes and local ordinance. Specifically, the City of South Bend maintains blanket insurance coverage over real and personal property, and is covered by a non -reverting insurance premium and liability reserve fund created by the City of South Bend, Ordinance #6657-79, pursuant to Indiana Code 34-13-3-4, as amended from time to time. Under said statute, the City's liability is limited to: 1) Seven hundred thousand dollars ($700,000) for a cause of action that accrues on or after January 1, 2008; and 2) Five million dollars ($5,000,000) for injury to or death of all persons in that occurrence,; and 3) A governmental entity or an employee of a governmental entity acting within the scope of employment is not liable for punitive damages. B. Additional Insureds: 11111111113111 IN K Engineer's GensI E ram 3. The Owner shall be listed on Engineer's general liability policy as provided in Paragraph 6.04.A. Page 2 (Exhibit G - Insurance) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 This is EXHIBIT I, consisting of 1 page, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated Limitations of Liability Paragraph 6.10 of the Agreement is supplemented to include the following agreement of the parties: A. Limitation of Engineer's Liability 1. Engineer's Liability Limited to Amount of Insurance Proceeds: Engineer shall procure and maintain insurance as required by and set forth in Exhibit G to this Agreement. Notwithstanding any other provision of this Agreement, and to the fullest extent permitted by law, the total liability, in the aggregate, of Engineer and Engineer's officers, directors, members, partners, agents, employees, and Consultants to Owner and anyone claiming by, through, or under Owner for any and all claims, losses, costs, or damages whatsoever arising out of, resulting from, or in any way related to the Project or the Agreement from any cause or causes, including but not limited to the negligence, professional errors or omissions, strict liability, breach of contract, indemnity obligations, or warranty express or implied, of Engineer or Engineer's officers, directors, members, partners, agents, employees, or Consultants (hereafter "Owner's Claims"), shall not exceed the total insurance proceeds paid on behalf of or to Engineer by Engineer's insurers in settlement or satisfaction of Owner's Claims under the terms and conditions of Engineer's insurance policies applicable thereto (excluding fees, costs and expenses of investigation, claims adjustment, defense, and appeal). if „e s,,e i liability,. rr-evided with r-espeet to Ow-nef's Claims, then the total in the aggregate, Gensukants to Ov�%er- and anyone elaiming by, thfough, or- undef- Owner- for- any and all stieh uninsufedi}e+'s Claims shall at exee B. Indemnification by Owner: To the fullest extent permitted by law, Owner shall indemnify and hold harmless Engineer and its officers, directors, members, partners, agents, employees, and Consultants from and against any and all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals, and all court, arbitration, or other dispute resolution costs) arising out of or relating to the Project, provided that any such claim, cost, loss, or damage is attributable to bodily injury, sickness, disease, or death or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom, but only to the extent caused by any negligent act or omission of Owner or Owner's officers, directors, members, partners, agents, employees, consultants, or others retained by or under contract to the Owner with respect to this Agreement or to the Project. Page 1 (Exhibit I - Limitations on Liability) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 This is EXHIBIT J, consisting of 1 page, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated Special Provisions Paragraph(s) * of the Agreement is/are amended to include the following agreement(s) of the parties: * Please note that anv modifications to the original EJCDC document are identified by either a strike out of a given word, sentence or par�ph or are underlined to reflect any insertions. A. Exhibit A — Paragraph A.1.02.A.02 As a basis for this contract, it is assumed that the utilities will provide the required project information and/or their as-builts at no charge to the Owner and/or Engineer during the preliminary design phase. The Owner and/or Engineer, therefore, assume no liability in o consequences of the provided locations of these utilities or the lack thereof. Also, it is assumed that if conflicts with said utilities occur, no matter how minor, the costs to cure and conflict shall be borne by the utility or paid for as a part of the project cost by the Owner and/or others. Any required engineering design and/or other services direct to or incidental thereof, to remedy said utility conflicts, necessary for said relocation, shall be provided by others or as negotiated and Mon mutual written agreement by the Owner and Engineer for these services, and thereby be provided as an additional service within a future contract amendment. B. Paragraph A2.01 - Exhibit A — Additional Services At the time of the execution of this Agreement, the only known additional services to be performed by the Engineer are as follows: 1. Well Hydrogeological Design & Permitting Coordination The Owner will contract with Peerless Midwest to perform Well Hydrogeological Design and Permitting. The Engineer will coordinate with Peerless Midwest to obtain the location of the new wells, IDEM approval for new well site, report from testing drilling and water quali . analysis, Pinhook Well Relocation Plan, and IDEM Construction Permit Attachment B. The Engineer shall perform the above referenced services in accordance with Paragraph C2.05 of Exhibit C, Compensation Packet AS-1, with an estimated fee of $6,935. Geotechnical Field Work Conduct geotechnical field work at each site (further described in the attached Project Description, Scope of Services, and Schedule). Page 1 (Exhibit J - Special Provisions) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 The Engineer shall perform the above referenced services in accordance with Paragraph C2.O5 of Exhibit C, Compensation Packet AS-1, with an estimated fee of $11,748. Permits Prepare and submit IDEM Construction Permit application. The Engineer shall perform the above referenced services in accordance with Paragraph C2.O5 of Exhibit C, Compensation Packet AS-1, with an estimated fee of $5,365. Page 2 (Exhibit J - Special Provisions) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 PART 1 Project Description, Scope of Services, and Schedule Water Wall Replacement Project City of South Bend, Indiana GENERAL: Commonwealth Engineers, Inc. (ENGINEER) shall provide the City of South Bend, Indiana (CITY) with professional engineering services to which this scope of services applies. These services include serving as the CITY's professional representative for the Project, providing professional engineering consultation and advice, furnishing civil engineering services, and other customary services incidental thereto. PROJECT DESCRIPTION: The CITY has two wells that are aging and in need of replacement. The two well replacements are at two sites further described below. The CITY plans to fund this project with local funds. Cleveland South At the Cleveland South well site, the existing well needing replacement, Well #1, is located inside the existing chemical building. This well was constructed in 1984, with the well cleaned and pump and motor last overhauled in 2018. After cleaning/overhauling, the well's lower screen was still 50% plugged and the pump was only expected to operate for another 5 years. A new well onsite is desired to replace Well #1 with the new raw water line routed to the existing chemical building for chemical dosing. The new well will be housed in a new well building, which will be expandable to house future relocated chemical equipment. Backup power already exists at the site, but the CITY would like to evaluate moving the switchgear inside. Remote level monitoring and air line for manual level measurement will be added to the new well. Due to limited available budget, the CITY desires the option to eliminate the well building from the scope. Pinhook The Pinhook well site has five existing wells, with Wells 1-4 located along Pinhook Lake constructed in 1961, and Well 5 located inland constructed in 2004. The 12-inch raw water lines from each well converge into a 24-inch raw water line which is routed to the existing Pinhook Water Treatment Plant. The four wells located along the lake contain elevated PFAS levels, are located outdoors (prone to freezing), and are aging, while the inland well has lower PFAS levels and is housed in a well house. The second well from west, Well 3, is the targeted well to decommission and relocate, while the CITY desires a plan for relocation of the other three wells (1, 2, and 4). The new well will be housed in a new well building and will have provisions for remote level monitoring, air line for manual level measurement, and receptacle for connection to a portable backup generator. Due to limited available budget, the CITY desires the option to eliminate the well building from the scope. 6/30/2025 Commonwealth Engineers Inc. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 The project consists of the following: • Cleveland South: The new well location will be identified and reviewed with the CITY prior to completing the new well site survey permitting process. Test drilling, test well development, and well sampling for IDEM water quality parameters will be conducted near the proposed new well location. Concurrently with well site survey and testing, design will be conducted for a new well, well house (masonry with brick veneers), raw water site piping, and decommissioning of the old well. A mandatory deductive alternate will be included in the bid for eliminating the new well building. • Pinhook: The scope for this site is the same as Cleveland South, but at this location, a study will also be conducted to suggest locations for Wells 1, 2, and 4. SCOPE OF SERVICES: 1.0 TASK 1: Meetings, Project Management and Quality Assurance / Quality Control 1.1 Kickoff Meeting: Prepare for and hold kickoff meeting with the CITY to confirm scope, work plan, lines of communication, and schedule. Prepare and distribute meeting notes. 1.2 50% Design Meeting: Prepare for and conduct the 50% Design Meeting with the CITY. Prepare and distribute meeting notes. Perform a field verification review after the 50% submittal to make sure field items are properly shown on the drawings. 1.3 90% Design Meeting: Prepare for and conduct the 90% Design Meeting with the CITY. Prepare and distribute meeting notes. Perform a field verification review after the 90% submittal to make sure field items are properly shown on the drawings or included in the specifications. 1.4 Proiect Management: Project management including general correspondence, general coordination with the design / field work / subconsultant team, invoicing, scheduling, and budget maintenance. 1.5 50% Submittal QA/QC: Perform QA/QC on 50% submittal. 1.6 90% Submittal QA/QC: Perform QA/QC on 90% submittal. 1.7 Final Submittal QA/QC: Perform QA/QC on Final submittal. In the Agreement, Task 1 is split equally between Preliminary Design and Final Design phases. 2.0 TASK 2: Well Hydrogeological Design and Permitting Coordination The CITY will contract with Peerless Midwest to perform Well Hydrogeological Design and Permitting. The ENGINEER will coordinate with Peerless Midwest to obtain the location of the new wells, IDEM approval for new well site, report from testing drilling and water quality analysis, Pinhook Well Relocation Plan, and IDEM Construction Permit Attachment B. In the Agreement, Task 2 is included in Additional Services. 6/30/2025 Commonwealth Engineers Inc. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 3.0 TASK 3: 50% Design 3.1 Well Pump Design Calculations: Perform hydraulic calculations for each well site. 3.2 50% Drawings: Prepare 50% design drawings. See below draft listing of sheets. Sheet Well Replacement Plans # of sheets 1 Trie Shee' 1 2 Drawing Index 1 3 General Location Map 1 4 General Ah4reviationG. S mh ilc.. er ehds, and Not9F 1 5 Survey Control 1 6-9 IErosiGrk (;ontrol and Demolition Plan 10-11 Site Improvement,.; 2 12-13 New Well Constriction Delails 2 14-15 New Buildings ! Well Piping Plan and Section Vlews 2 16 Mechanical Legends and Schedules 1 11-18 Pinhook)Cleveland New Well Building Mechanical Pla^s 2 19 IMechanical Details 1 20 Plumbing Plan (both sites) 1 21 Elecincal Legends and Schedules I 22 Pinhook Oneline and Riser Diagrams 1 23 Cleveland Road Oneline and Riser Diagrams 1 24 Pinhook Electrical Site Demo Plan 1 25 Pinhook Electrical Sile Improvemenis Plan 1 26 Pinhook Well Building Power Plan 1 27 Pinhook Well Building Lighfing Plan 1 28 Cleveland Road Electrical Site Demo Plan 1 29 Cleveland Road Electrical Site Irnprovernents Plan I 30 Cleveland Road Well Budding Power PIN- I 31-32 Electrical Details r 33-35 lMiWellEineOUS Details 36 General Structural Notes 37 well Building 1 - Foundation & Rool'Framing Pla• I 3y well Building 2 - Foundation & Roof Framing P 3- 1 39 Foundalion Sections & entails 1 40 Masonry Sections 8 Details' 1 411.1 TOTAL 141 'Eliminale these sheels it opt for wood post irarne buildings 3.3 50% Contract Book: Prepare 50% contract book, which includes technical specifications. 3.4 50% Bid Form and Cost Estimate: Prepare a bid form and 50% design cost estimate. 3.5 50% Submittal Assembly: Submit the following to CITY: • 50% Full -Size 22"x34" and Half Size 11"x17" Drawings (PDF and 1 full-size and 4 half-size hard copies) • 50% Bid Form and Cost Estimate (PDF and 4 hard copies) In the Agreement, Task 3 is included in Preliminary Design phase. 4.0 TASK 4: 90% Design 4.1 Surveying Field Work: Site survey will include full topographic survey in support of the proposed improvements. Tie proposed project layout into existing coordinate systems and vertical monuments. This survey, together with existing record drawings will be 6/30/2025 Commonwealth Engineers Inc. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 utilized as the basis for construction plans. No specific survey data deliverable is expected. This work will commence following the selection of new well sites. 4.2 90% Drawings: Prepare 90% design drawings. 4.3 90% Contract Book: Prepare 90% contract book, which includes technical specifications. 4.4 90% Bid Form and Cost Estimate: Prepare a bid form and 90% design cost estimate. 4.5 90% Submittal Assembly: Submit the following to CITY: • Geotechnical Report (PDF and 4 hard copies) • 90% Full -Size 22"x34" and Half Size 11"x17" Drawings (PDF and 1 full-size and 4 half-size hard copies) • 90% Contract Book (PDF and 4 hard copies) • 90% Bid Form and Cost Estimate (PDF and 4 hard copies) In the Agreement, Task 4 is included in Preliminary Design phase. 5.0 TASK 5: Final Design 5.1 Final Drawings: Prepare Final design drawings. 5.2 Final Contract Book: Prepare Final contract book, which includes technical specifications. 5.3 Final Bid Form and Cost Estimate: Prepare a bid form and Final design cost estimate. 5.4 Final Submittal Assembly: Finalize the drawings for bidding. The final bidding documents will be signed and sealed by the registered Professional Engineer in the State of Indiana. Final deliverable includes the following: • Final Certified Full -Size 22"x34" and Half Size 11 "x17" Drawings (PDF and 1 full-size and 4 half-size hard copies) • Final Certified Contract Book (PDF and 4 hard copies) 6.0 TASK 6: Geotechnical Field Work Description 6.1 Geotechnical Field Work: Perform geotechnical investigation and assemble report for the water improvements. After well sites are identified/confirmed, it is anticipated that 2 bores will be performed at a depth of approximately 15-feet each. This work will commence following the selection of new well sites. In the Agreement, Task 6 is included in Additional Services. 7.0 TASK 7: Permits 7.1 IDEM Construction Permit: Prepare and submit IDEM Construction Permit Application. In the Agreement, Task 7 is included in Additional Services. 6/30/2025 Commonwealth Engineers Inc. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 8.0 TASK 8: Bidding & Negotiating 8.1 Pre -Bid Meeting: Prepare and lead a pre -bid meeting and prepare meeting notes. 8.2 Contractor Questions and Addenda: Respond to Contractors' questions and prepare and certify addendums. 8.3 Certified Bid Tabulation: Review and evaluate the bids and certify the bid tabulation. 9.0 TASK 9: Construction Services 9.1 Pre -Construction Meeting: Prepare for and attend pre -construction meeting prior to commencement of Work. 9.2 Construction Engineering Assistance: Provide clarifications and interpretations to project plans and specifications, prepare change orders and work directives, review shop drawings and samples, review project schedule, evaluate substitutes, review contractor's applications for payment and provide recommendation. 9.3 Meetings and Site Visits: Prepare for and attend up to four (4) progress meetings, and perform site visits the same day. ESTIMATED SCHEDULE: The Project will be completed under the tentative milestones shown below. This tentative schedule is based on receiving a Notice to Proceed prior to the end of July 2025, and receiving prompt review and approvals from the CITY. ITEM Kickoff Workshop New Well Site Location Selection* New Well Site Survey* 50% Design Services 50% Design Workshop Test Well & Sampling* Field Work (Geotech & Survey) 90% Design Services 90% Design Review Workshop Final Detailed Design Services and Permitting* Bidding Phase Construction Phase TENTATIVE DATE August 2025 August 2025 September - October 2025 October 2025 October 2025 November 2025 November 2025 December 2025 December 2025 January — March 2026 March — April 2026 May 2026 — January 2027 *Schedule of these items dependent on Peerless Midwest, Results from Well Testing, and IDEM review timeline. 6/30/2025 Commonwealth Engineers Inc. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 OPTIONAL ADDITIONAL SERVICES (Not included in proposed fee): Upon separate written authorization by CITY and after approval of negotiated fees, ENGINEER can provide additional service such as those listed below. • Additional test drilling • Sampling for PFAS, ammonia, and other analytes not on IDEM list • Additional field work & design if site location changes • Conformed to Contract Drawings and Specifications • Issuing the project in multiple phases. • Resident Project Representative (i.e. Inspection) • Record Drawings • AIS or BABA Compliance Assistance • Labor Standards Administration • Additional permitting beyond the scoped permits. • Additional workshops, meetings, site visits, bidding and construction engineering beyond the hourly budget. • Additional soil borings and / or pavement cores. • Contaminated soil testing and / or groundwater monitoring. • Subsurface utility engineering. • Wetland mitigation and/or restoration plans. / Phase I environmental assessment. • Post construction monitoring. • Green / sustainable infrastructure design. • Regulatory coordination beyond the scope, such as coordination with IDEM. • Archaeological investigation and monitoring. 6/30/2025 Commonwealth Engineers Inc. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 PART 2 Fee Summary and Clarifications Water Well Replacement Project City of South Bend, Indiana FEE SUMMARY: TASK FEE Meetings, Project Mgmt., QA/QC (Task 1) $ 14,914 (Hourly) Well Hydrogeological Design & Permitting (Task 2) $ 6,935 (Lump Sum) 50% Design (Task 3) $ 63,079 (Lump Sum) 90% Design (Task 4) $ 32,353 (Lump Sum) Final Design (Task 5) $ 15,245 (Lump Sum) Geotechnical Field Work (Task 6) $ 11,748 (Hourly) Permits (Task 7) $ 5,365 (Hourly) Bidding & Negotiating (Task 8) $ 13,225 (Hourly) Construction Services (Task 9) $ 44,437 (Hourly) Total $ 207,301 6/30/2025 Commonwealth Engineers Inc. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 FEE CLARIFICATIONS: The following clarifications pertain to the fee structure (i.e. lump sum or hourly) for scope items described above in Part 1. 1.0 Lump Sum - Clarifications 1.1 ENGINEER may alter the distribution of compensation between individual tasks noted herein to be consistent with services actually rendered but shall not exceed the total Lump Sum amount unless approved in writing by the CITY. 1.2 The Lump Sum includes compensation for ENGINEER's services and services of ENGINEER's Sub -Consultants, if any. Appropriate amounts have been incorporated in the Lump Sum to account for labor, overhead, profit, and Reimbursable Expenses. 1.3 The portion of the Lump Sum amount billed for ENGINEER's services will be based upon ENGINEER's estimate of the percentage of the total services actually completed during the billing period. 2.0 Standard Hourly Rates - Clarifications 2.1 ENGINEER may alter the distribution of compensation between individual tasks of the work noted herein to be consistent with services actually rendered but shall not exceed the total estimated compensation amount unless approved in writing by CITY. 2.2 The total estimated compensation for ENGINEER's services included in the breakdown by tasks incorporates all labor, overhead, profit, Reimbursable Expenses and ENGINEER's Sub -Consultants' charges. 2.3 The amounts billed for ENGINEER's services will be based on the cumulative hours charged to the Project during the billing period by each class of ENGINEER's employees times Standard Hourly Rates for each applicable billing class, plus Reimbursable Expenses and ENGINEER's Sub -Consultants' charges. Standard Hourly Rates are subject to change on July 1 of each year. 3.0 Additional Services - Clarifications 3.1 Additional service provided by ENGINEER can be provided based on the Standard Hourly Rates listed in Part 2, 4.0. Standard Hourly Rates are subject to change on July 1 of each year. 6/30/2025 Commonwealth Engineers Inc. Docusign Envelope ID: D6C53305-7513-4331-95AB-7279605F17A9 4.0 Employee Billing Rate Schedule COMMONWEALTH ENGINEERS, INC. STANDAR❑ HOURLY RATES AND REIMBURSABLE EXPENSES SCHEDULE July 1, 2025 - June 30, 2026 Billing Class Rate Per Hour Billing Class Rate Per Hour Principal III $ 126.20 Environmental Scientist 11 $ 38.64 Principal 11 $ 115.80 Environmental Scientist 1 $ 34.81 Principal $ 105.85 Construction Manager $ 66-23 Project Manager IV $ 104.76 Project Manager III $ 96.01 Resident Project Representative IV $ 52.52 Project Manager II $ 79.93 Resident Project Representative III $ 43-67 Project Manager 1 $ 71.96 Resident Project Representative II $ 39-42 Resident Project Representative 1 $ 35-15 Senior Electrical Engineer $ 96.01 Clerical III $ 43.66 Senior Process Engineer $ 86.70 Clerical II $ 32.87 Clerical $ 24.11 Project Engineer IV $ 81.37 Project Engineer III $ 65.27 Reproduction Processor $ 30-14 Project Engineer 11 $ 61.47 Project Engineer 1 $ 56.99 Trainee $ 23.42 Engineering Intern III $ 5D.66 CADD Specialist IV $ 49.56 Engineering Intern II $ 47.64 CADD Specialist III $ 45.03 Engineering Intern I $ 42.W CADD Specialist 11 $ 38.51 CADD Specialist 1 $ 30.84 Designer IV $ 63.09 Designer III $ 57.77 Chief Technology Officer $ 73.66 Designer 11 $ 52.12 IT Tech $ 34.41) Designer 1 $ 42.07 Multimedia Coordinator $ 58.47 Operations Specialist $ 51-31 Survey Manager $ 67.49 Surveyor $ 53-15 Project Surveyor $ 47.98 Field Technician $ 40.62 Environmental $ 62.19 Compliance Manager Compliance Specialist $ 34-81 Grants Manager $ 66.98 In order to arrive at the total billing rate, the above direct payroll rates shall be muftiplied by factors of 56.4556% and 87.4236% to account for payroll and general overhead costs respectively- In addition, a 15% profit level is then added to arrive at total labor costs. This is a total multiplier factor of 3.3722 times direct payroll rates - Reimbursable Expenses 1. Travel: Starts at the office and shall be at the then approved rate by the U.S. Intemal Revenue Service, plus 15% profit. 2. Subsistence and Lodging: Actual Cost, plus 15% profit- 3. Express Charges and Postage, other than first class mail: Actual Cost, plus 15% profit. 4. Paper Prints: $0-75 per square foot, plus 15% profd. 5. Special Tests and Services of Special Consultants- Actual Costs, plus 15°lo profit - It is agreed that the Owner will make payment of each invoice presented by Commonwealth within thirty (30) days from the date of the invoice. Payments received after this time shall be subject to an interest charge of 1 % per month. 6/30/2025 Commonwealth Engineers Inc. COMMONWEALTH - ENGINEERS, INC. AwVY, 01 r.WaMY OC mubr.OYMW Y.LL ENGINEERING FEE ESTIMATION PROJECT NAME/DESCRIPTION: ESTIMATE DATE: Water Utility Impro 6/30/2025 PROJECT MANAGER: Jeremy Hardy RATE YEAR WORK WILL BE COMPLETED: July 1, 2025 - June 30, 2026 START DATE: 7/7/2025 DURATION (MONTHS): Design/Permit (7 months) ; Bidding/Award (2 months); Construction Eng (8 months) TASK\HOUR SUMMARY Total EMPLOYEE NAME TASK Project Manager III Project Manager II Sr Electrical Engineer Project Engineer II Engineer Intern II Engineer Intern I Designer Grade IV Designer Grade III Designer Grade II CADD Specialist II Clerical Grade II Reproduct. Project Surveyor Total Hours Direct Labor Sub- Consultant Expenses Cost w. Multiplier Wetzel Hardy Miranda Mendoza Wisman/Dill Girdham / Salazar Dugan Waterman Means Higbie Dustman Marsh Chris TASK 1 - MEETINGS, PM, & QA / QC --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- 1.1 Kickoff Meeting 2 3 4 9 $494 $25 $1,677 1.2 50% Design Meeting 2 3 4 9 $494 $25 $1,677 1.3 90% Design Meeting 2 3 4 9 $494 $25 $1,677 1.4 Project Management 16 16 $1,224 $4,083 1.5 50% Submittal QA/QC 4 1 2 7 $580 $1,934 1.6 90% Submittal QA/QC 4 1 2 7 $580 $1,934 1.7 Final _Submittal QA/QC --Task1 Sub-total------------------------------------------------------------ 4 -------12 ------- 22 1 ---------3 _ -------- 9 2 ---------0 _7 -------64 $580 ------- $� -------$75------- $1,934 $14,914 0 12 0 6 0 0 0 0 $4,444 TASK 3 - 50% DESIGN --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- 2.1 50% Drawings 0 $0 $0 Sheets 1-4 General Sheets 1 1 2 2 21 4 1 11 $534 $1,783 Sheets 5-6 Erosion Control and Demolition Sheets 2 4 4 2 12 24 $1,1061 $3,689 Sheets 7-11 New Well Construction, Details, and Piping/Site Improvements 2 10 101 6 16 44 $2,074 $6,919 Sheets 12-16 New Well Building Mechanical & Plumbing Sheets 2 2 2 4 4 2 8 2 26 $1,351 $4,508 Sheets 17-28 Electrical Plans 21 2 2 32 4 2 6 2 52 $2,499 $8,338 Sheets 29-31 Miscellaneous Details 1 2 2 2 4 11 $534 $1,783 Sheets 32-37 Structural Plans (CE Solutions) 2 2 2 2 2 10 $537 $12,000 $15,592 2.2 Well Pump Design Calculations 1 8 8 17 $8761 $2,923 2.3 50% Contract Book 4 16 2 24 2 8 56 $2,697 $9,000 2.4 50% Bid Form & Cost Estimate 1 4 8 13 $641 $2,138 2.5 50% Submittal Assembly 1 1 2 1 1 2 8 $373 $1,243 Archite_ctu_ral Peer Review --Task 2 Sub-total------------------------------------------------------------ --------0 1 ------- 20 --------- 2 2 ------- 55 4 --------47 7 $342 $3,500 $5,165 4 98 10 19 14 10 0 0 279 $13,563 $15,500 $0 $63,079 TASK 4 - 90% DESIGN --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- I --- --- --- 3.1 90% Drawings 1 0 $0 $0 Sheets 1-4 General Sheets 1 1 1 1 1 5 $269 $896 Sheets 5-6 Erosion Control and Demolition Sheets 1 2 2 4 8 17 $792 $2,643 Sheets 7-11 New Well Construction, Details, and Piping/Site Improvements 2 5 5 4 12 28 $1,316 $4,391 Sheets 12-16 New Well Building Mechanical & Plumbing Sheets 2 2 2 2 2 2 4 2 18 $949 $3,165 Sheets 17-28 Electrical Plans 2 2 2 8 2 2 4 4 26 $1,365 $4,556 Sheets 29-31 Miscellaneous Details 1 2 21 2 4 11 $534 $1,783 Sheets 32-37 Structural Plans (CE Solutions) 2 2 2 2 21 10 $537 $1,792 3.2 90% Contract Book 2 8 12 2 4 28 $1,364 $4,549 3.3 90% Bid Form & Cost Estimate 1 3 6 10 $500 $1,667 3.4 90% Submittal Assembly I 1 1 1 1 2 1 1 2 8 $373 $1,243 3.5 Field Work -Surveying Task 3 Sub -total 0 0.5 15.51 2 1 29 1 1 341 36.5 $1,692 $20 $51667 21 431 6 181 8 34 6 0 1 34 1 197.5 $9,690 $0 $20 1 $32,353 COMMONWEALTH - ENGINEERS, INC. AwVY, 01 rM'aMY OC mubr.OYMW Y.LL ENGINEERING FEE ESTIMATION PROJECT NAME/DESCRIPTION: ESTIMATE DATE: Water Utility Impro 6/30/2025 PROJECT MANAGER: Jeremy Hardy RATE YEAR WORK WILL BE COMPLETED: July 1, 2025 - June 30, 2026 START DATE: 7/7/2025 DURATION (MONTHS): Design/Permit (7 months) ; Bidding/Award (2 months); Construction Eng (8 months) TASK\HOUR SUMMARY Total EMPLOYEE NAME TASK 5 - FINAL DESIGN Project Manager III Project Manager II Sr Electrical Engineer Project Engineer II Engineer Intern II Engineer Intern I Designer Grade IV Designer Grade III Designer Grade II CADD Specialist II Clerical Grade II Reproduct. Project Surveyor Total Hours --- Direct Labor --- Sub- Consultant --- Expenses --- Cost w. Multiplier --- Wetzel Hardy Miranda Mendoza Wisman/Dill Girdham / Salazar Dugan Waterman Means Higbie Dustman Marsh Chris --- --- --- --- --- --- --- --- --- --- --- --- --- 4.1 Final Drawings I I I 1 0 $0 $0 Sheets 1-4 General Sheets 0.5 0.5 0.5 0.5 1 3 $153 $510 Sheets 5-6 Erosion Control and Demolition Sheets 0.5 1 1 1 2 5.5 $267 $891 Sheets 7-11 New Well Construction, Details, and Piping/Site Improvements 1 2 2 2 4 11 $534 $1,783 Sheets 12-16 New Well Building Mechanical & Plumbing Sheets 1 2 1 2 2 1 4 1 14 $734 $2,450 Sheets 17-28 Electrical Plans 1 1 1 41 2 1 4 1 15 $8061 $2,689 Sheets 29-31 Miscellaneous Details 1 1 1 1 1 1 5 $269 $896 Sheets 32-37 Structural Plans (CE Solutions) 1 1 1 1 0 1 5 $269 $896 4.2 Final Contract Book 1 4 1 6 4 16 $730 $2,435 4.3 Final Bid Form & Cost Estimate 2 2 4 8 $435 $1,452 4.4 Final Submittal Assembly 4 TSub-total 0 1 10 1 1 15.5 2 1 1 2 8 $373 $1,243ask 2 23.5 4 8.5 8 12 6 0 0 90.5 $4,569 $0 $0 $15,245 TASK 6 - GEOTECHNICAL FIELD WORK --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- 5.1 Geote_ch_nic_al Field Work (SME) -Task5Sub-total ------------------------------ ----0 0.5 -----0.5 -----0------0.5 0.5 1 2 $109 $9,900 $11,748 0 1 0 0 0------0 0 0 0 2 $109 $9,900 $0 $11,748 TASK 7 - PERMITS --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- 6.1 IDEM Construction Permit 0 3 3 0 8 8 12 1 4 4 4 32 $1,522 $250 $5,365 Task 6 Sub -total 0 12 0 1 0 4 0 0 32 $1,522 $0 $2501 $5,365 TASK 8 - BIDDING & NEGOTIATING --- --- --- --- --- --- --- --- --- --- --- --- --- --- -- 7.1 Pre -Bid Meeting 2 3 3 8 $453 $20 $1,534 7.2 Contractor Questions and Addenda 2 6 2 12 4 2 2 8 4 12 54 $2,309 $2,200 $10,234 7.3 Certified Bid Tabulation -Task 7 Sub -total - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - -0 1 - - - - 5 - - - - 0 2 ----- - 11 2 ---- - - 8 4 9 $402 $100 $1,457 2 17 4 2 2 8 12 0 71 $3,164 $2,200 $120 $13,225 TASK 9 - CONSTRUCTION SERVICES --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- 8.1-3 Construction Engineering -Task8Sub-total------------------------------ 2 ----2 16 --- 16 -----0-----40 40 6 80 12 156 ---156 $8,052 $15,000 $280 -- $280 $442437 --- $44,437 6 80 12 0 0------0 0 0 0 $8,052 $15,000 TASK 2 - WELL HYDROGEOLOGICAL DESIGN AND PERMITTING COORDINATION --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- --- 2.1 New Well Site Survey Permitting 2 4 6 2 14 $709 $2,365 2.2 Test Drilling Field Work and Water Quality Analysis 1 6 6 13 $676 $2,256 2.3 Pinhook Wells 1, 2, and 4 Relocation Plan 1 2 6 2 11 $515 $1,717 2.4 IDEM Construction Permit Attachment B 0 0.5 4.5 0 1 13 0 2 20 0 0 0 4 3.5 $179 $598 Task 2 Sub -total 0 0 0 41.5 $2,079 $0 $0 $6,935 GRAND TOTAL 14 96.5 8 181 16 306.5 36 54.5 32 109 34 12 34 933.5 $47,192 $42,600 $745 $207,301 BOARD OF PUBLIC WORKS AGENDA ITEM REVIEW REQUEST FORM Date 7/12/2025 Name Gemma Stanton Department DPW BPW Date 7/22/2025 Phone Extension 9083 Review and Approval Required Prior to Submittal to Board Diversity Compliance ❑ Officer Name and Inclusion Officer BPW Attorney ❑ Attorney Name Dept. Attorney ❑ Attorney Name Purchasing ❑ Check the Appropriate Item I Professional Services Agreement ❑ Contract ❑ Open Market Contract ❑ Bid Opening ❑ Quote Opening ❑ Proposal Opening ❑ Chg. Order, No. I-1 Other: Company or Vendor Name New Vendor MBE/WBE Contractor Project Name Project Number Funding Source Account No. Amount Terms of Contract Purpose/Description ❑ Amendment/Addendum ❑ Bid Award ❑ Quote Award ❑ C/O & PCA No. ❑ Traffic Control Information Commonwealth All Submissions U Proposal ❑ Special Purchase, QPA ❑ Req. to Advertise ❑ Reject Bids/Quotes ❑ PCA ❑ Resolution Ease./Encroach Yes U If Yes, Approved by Purchasing ❑ Title Sheet ❑ No ❑❑ MBE Completed E-Verify Form Attached ❑ Yes No Cleveland and Pinhook Well Replacements 125-033 PR-42116 622-442005 $207,301 Lump sum Design services for well replacements at Cleveland and Pinhook Water Treatment Plants For Change Orders Only Amount of ❑ Increase $ ❑ Decrease ($ ) Previous Amount Current Percent of Change New Amount Total Percent of Change: Time Extension Amount: Increase Decrease Increase Decrease New Completion Date: