Loading...
HomeMy WebLinkAboutAmendment No. 2 to PSA - Four Winds Renovation Proj No 123-046 - Jones Petrie Rafinski ELIZABETH A. MARADIK JOSEPH R. MOLNAR GARY A. GILOT MURRAY L. MILLER BREANA N. MICOU 1316 COUNTY-CITY BUILDING 227 W. JEFFERSON BOULEVARD SOUTH BEND, INDIANA 46601-1830 PHONE 574/ 235-9251 FAX 574/ 235-9171 CITY OF SOUTH BEND JAMES MUELLER, MAYOR BOARD OF PUBLIC WORKS November 12, 2024 Mr. David M. Rafinski Jones Petrie Rafinski Corporation 325 S. Lafayette Blvd. South Bend, IN 46601 drafinski@jpr1source.com RE: Amendment No. 2 to Professional Services Agreement Dear Mr. Rafinksi: At its November 12, 2024 meeting, the Board of Public Works approved the above referenced amendment for additional design fee for construction phase services for Four Winds Renovation and Expansion, Project No. 123-046 in the amount of $788,545. Enclosed please find a copy of the agreement for your records. If you have any further questions, please call this office at (574) 235-9251. Sincerely, /s/ Theresa Heffner Theresa Heffner, Clerk Enclosures TH/hh Document G802® – 2017 Amendment to the Professional Services Agreement AIA Document G802 – 2017. Copyright © 2000, 2007 and 2017. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 16:10:51 ET on 11/05/2024 under Order No.2114444856 which expires on 01/27/2025, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (3B9ADA47) 1 PROJECT: (name and address)AGREEMENT INFORMATION:AMENDMENT INFORMATION: Four Winds Field Renovation & Expansion Date: June 30, 2023 Amendment Number: 002 501 West South Street South Bend, Indiana 46601 Date: November 5, 2024 OWNER: (name and address)ARCHITECT: (name and address) City of South Bend, Indiana Board of Public Works Jones Petrie Rafinski Corp. 325 S. Lafayette Boulevard 227 West Jefferson Boulevard South Bend, Indiana 46601 South Bend, Indiana 46601 The Owner and Architect amend the Agreement as follows: Add the following Articles: '§ 3.6 Construction Phase Services § 3.6.1 General § 3.6.1.1 The Architect shall provide administration of the Contract between the Owner and the Construction Manager as set forth below and in AIA Document A201™–2017, General Conditions of the Contract for Construction. If the Owner and Construction Manager modify AIA Document A201–2017, those modifications shall not affect the Architect’s services under this Agreement unless the Owner and the Architect amend this Agreement. The term “Contractor” as used in A201-2017 shall mean the Construction Manager. § 3.6.1.2 Subject to Section 4.2, the Architect’s responsibility to provide Construction Phase Services commences upon the Owner’s acceptance of the Construction Manager’s Guaranteed Maximum Price proposal, the Owner’s approval of the Construction Manager’s Control Estimate, or by a written agreement between the Owner and Construction Manager which sets forth a description of the Work to be performed by the Construction Manager prior to such acceptance or approval. Subject to Section 4.2, and except as provided in Section 3.6.6.5, the Architect’s responsibility to provide Construction Phase Services terminates on the date the Architect issues the final Certificate for Payment. § 3.6.1.3 The Architect shall advise and consult with the Owner and Construction Manager during the Construction Phase Services. The Architect shall have authority to act on behalf of the Owner only to the extent provided in this Agreement. The Architect shall not have control over, charge of, or responsibility for the construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, nor shall the Architect be responsible for the Construction Manager’s failure to perform the Work in accordance with the requirements of the Contract Documents. The Architect shall be responsible for the Architect’s negligent acts or omissions, but shall not have control over or charge of, and shall not be responsible for, acts or omissions of the Construction Manager or of any other persons or entities performing portions of the Work. § 3.6.2 Evaluations of the Work § 3.6.2.1 The Architect shall visit the site at intervals appropriate to the stage of construction, or as otherwise required in Section 4.2.3, to become generally familiar with the progress and quality of the portion of the Work completed, and to determine, in general, if the Work observed is being performed in a manner indicating that the Work, when fully completed, will be in accordance with the Contract Documents. However, the Architect shall not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. On the basis of the site visits, the Architect shall keep the Owner reasonably informed about the progress and quality of the portion of the Work completed, and promptly report to the Owner (1) known deviations from the Contract Documents, (2) known deviations from the most recent construction schedule submitted by the Construction Manager, and (3) defects and deficiencies observed in the Work. § 3.6.2.2 The Architect has the authority to reject Work that does not conform to the Contract Documents. Whenever the Architect considers it necessary or advisable, the Architect shall have the authority to require inspection or testing of the Work in accordance with the provisions of the Contract Documents, whether or not the Work is fabricated, installed or completed. However, neither this authority of the Architect nor a decision made in good faith either to exercise or not to exercise such AIA Document G802 – 2017. Copyright © 2000, 2007 and 2017. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 16:10:51 ET on 11/05/2024 under Order No.2114444856 which expires on 01/27/2025, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (3B9ADA47) 2 authority shall give rise to a duty or responsibility of the Architect to the Construction Manager, Subcontractors, suppliers, their agents or employees, or other persons or entities performing portions of the Work. § 3.6.2.3 The Architect shall interpret and decide matters concerning performance under, and requirements of, the Contract Documents on written request of either the Owner or Construction Manager. The Architect’s response to such requests shall be made in writing within any time limits agreed upon or otherwise with reasonable promptness. § 3.6.2.4 Interpretations and decisions of the Architect shall be consistent with the intent of, and reasonably inferable from, the Contract Documents and shall be in writing or in the form of drawings. When making such interpretations and decisions, the Architect shall endeavor to secure faithful performance by both Owner and Construction Manager, shall not show partiality to either, and shall not be liable for results of interpretations or decisions rendered in good faith. The Architect’s decisions on matters relating to aesthetic effect shall be final if consistent with the intent expressed in the Contract Documents. § 3.6.2.5 Unless the Owner and Construction Manager designate another person to serve as an Initial Decision Maker, as that term is defined in AIA Document A201–2017, the Architect shall render initial decisions on Claims between the Owner and Construction Manager as provided in the Contract Documents. § 3.6.3 Certificates for Payment to Construction Manager § 3.6.3.1 The Architect shall review and certify the amounts due the Construction Manager and shall issue certificates in such amounts. The Architect’s certification for payment shall constitute a representation to the Owner, based on the Architect’s evaluation of the Work as provided in Section 3.6.2 and on the data comprising the Construction Manager’s Application for Payment, that, to the best of the Architect’s knowledge, information and belief, the Work has progressed to the point indicated, the quality of the Work is in accordance with the Contract Documents, and that the Construction Manager is entitled to payment in the amount certified. The foregoing representations are subject to (1) an evaluation of the Work for conformance with the Contract Documents upon Substantial Completion, (2) results of subsequent tests and inspections, (3) correction of minor deviations from the Contract Documents prior to completion, and (4) specific qualifications expressed by the Architect. § 3.6.3.2 The issuance of a Certificate for Payment shall not be a representation that the Architect has (1) made exhaustive or continuous on-site inspections to check the quality or quantity of the Work, (2) reviewed construction means, methods, techniques, sequences or procedures, (3) reviewed copies of requisitions received from Subcontractors and suppliers and other data requested by the Owner to substantiate the Construction Manager’s right to payment, or (4) ascertained how or for what purpose the Construction Manager has used money previously paid on account of the Contract Sum. § 3.6.3.3 The Architect shall maintain a record of the Applications and Certificates for Payment. § 3.6.4 Submittals § 3.6.4.1 The Architect shall review the Construction Manager’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review. § 3.6.4.2 The Architect shall review and approve, or take other appropriate action upon, the Construction Manager’s submittals such as Shop Drawings, Product Data and Samples, but only for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents. Review of such submittals is not for the purpose of determining the accuracy and completeness of other information such as dimensions, quantities, and installation or performance of equipment or systems, which are the Construction Manager’s responsibility. The Architect’s review shall not constitute approval of safety precautions or construction means, methods, techniques, sequences or procedures. The Architect’s approval of a specific item shall not indicate approval of an assembly of which the item is a component. § 3.6.4.3 If the Contract Documents specifically require the Construction Manager to provide professional design services or certifications by a design professional related to systems, materials, or equipment, the Architect shall specify the appropriate performance and design criteria that such services must satisfy. The Architect shall review and take appropriate action on Shop Drawings and other submittals related to the Work designed or certified by the Construction Manager’s design professional, provided the submittals bear such professional’s seal and signature when submitted to the Architect. The Architect’s review shall be for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents. The Architect shall be entitled to rely upon, and shall not be responsible for, the adequacy and accuracy of the services, certifications, and approvals performed or provided by such design professionals. AIA Document G802 – 2017. Copyright © 2000, 2007 and 2017. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 16:10:51 ET on 11/05/2024 under Order No.2114444856 which expires on 01/27/2025, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (3B9ADA47) 3 § 3.6.4.4 Subject to Section 4.2, the Architect shall review and respond to requests for information about the Contract Documents. The Architect shall set forth, in the Contract Documents, the requirements for requests for information. Requests for information shall include, at a minimum, a detailed written statement that indicates the specific Drawings or Specifications in need of clarification and the nature of the clarification requested. The Architect’s response to such requests shall be made in writing within any time limits agreed upon, or otherwise with reasonable promptness. If appropriate, the Architect shall prepare and issue supplemental Drawings and Specifications in response to the requests for information. § 3.6.4.5 The Architect shall maintain a record of submittals and copies of submittals supplied by the Construction Manager in accordance with the requirements of the Contract Documents. § 3.6.5 Changes in the Work § 3.6.5.1 The Architect may order minor changes in the Work that are consistent with the intent of the Contract Documents and do not involve an adjustment in the Contract Sum or an extension of the Contract Time. Subject to Section 4.2, the Architect shall prepare Change Orders and Construction Change Directives for the Owner’s approval and execution in accordance with the Contract Documents. § 3.6.5.2 The Architect shall maintain records relative to changes in the Work. § 3.6.6 Project Completion § 3.6.6.1 The Architect shall: .1 conduct inspections to determine the date or dates of Substantial Completion and the date of final completion; .2 issue Certificates of Substantial Completion; .3 forward to the Owner, for the Owner’s review and records, written warranties and related documents required by the Contract Documents and received from the Construction Manager; and .4 issue a final Certificate for Payment based upon a final inspection indicating that, to the best of the Architect’s knowledge, information, and belief, the Work complies with the requirements of the Contract Documents. § 3.6.6.2 The Architect’s inspections shall be conducted with the Owner to (1) check conformance of the Work with the requirements of the Contract Documents and (2) verify the accuracy and completeness of the list submitted by the Construction Manager of Work to be completed or corrected. § 3.6.6.3 When Substantial Completion has been achieved, the Architect shall inform the Owner about the balance of the Contract Sum remaining to be paid the Construction Manager, including the amount to be retained from the Contract Sum, if any, for final completion or correction of the Work. § 3.6.6.4 The Architect shall forward to the Owner the following information received from the Construction Manager: (1) consent of surety or sureties, if any, to reduction in or partial release of retainage or the making of final payment; (2) affidavits, receipts, releases and waivers of liens, or bonds indemnifying the Owner against liens; and (3) any other documentation required of the Construction Manager under the Contract Documents. § 3.6.6.5 Upon request of the Owner, and prior to the expiration of one year from the date of Substantial Completion, the Architect shall, without additional compensation, conduct a meeting with the Owner to review the facility operations and performance.' The Architect shall also provide Additional Services as follows: The Architect will provide additional design services which include design changes for an alternate mechanical equipment package and its associated piping and connections and related structural and architectural modifications to the Phase 1 Upper Deck Construction Documents package. The alternate equipment description accepted by the Owner and Construction Manager include rooftop gas-fired/DX air handling equipment in lieu of the previously accepted boiler/chiller based system. The Architect’s compensation and schedule shall be adjusted as follows: Compensation Adjustment: Owner shall compensate the Architect an additional Seven Hundred and Thirteen Thousand, Five Hundred and Forty-Five Dollars ($713,545.00) for Construction Phase Services and an additional Seventy-Five Thousand Dollars ($75,000.00) for Additional Design Services associated with the Phase 1 Upper Deck HVAC re-design. AIA Document G802 – 2017. Copyright © 2000, 2007 and 2017. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 16:10:51 ET on 11/05/2024 under Order No.2114444856 which expires on 01/27/2025, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (3B9ADA47) 4 Schedule Adjustment: SIGNATURES: Jones Petrie Rafinski COSB Board of Public Works ARCHITECT (Firm name)OWNER (Firm name) SIGNATURE SIGNATURE David M. Rafinski - COO PRINTED NAME AND TITLE PRINTED NAME AND TITLE DATE DATE 11/5/2024 November 12, 2024 BOARD OF PUBLIC WORKS AGENDA ITEM REVIEW REQUEST FORM Date: 11/07/2024 Name: Patrick Sherman Department of Public Works – Engineering Division BPW Date: 11/12/2024 Phone Extension: 5601 Required Prior to Submittal to Board BPW Attorney X Attorney Name Michael Schmidt Dept. Attorney Attorney Name Michael Schmidt Purchasing Mickey Lovy Check the Appropriate Item Type – Required for All Submissions Professional Services Agreement Contract Proposal Open Market Contract Amendment/Addendum Special Purchase, QPA Bid Opening Bid Award Req. to Advertise Title Sheet Quote Opening Quote Award Reject Bids/Quotes Proposal Opening C/O & PCA No. PCA Chg. Order, No. Traffic Control Resolution Other: Ease./Encroach Required Information Company or Vendor Name Jones Petrie Rafinski Corp. New Vendor Yes If Yes, Approved by Purchasing No MBE/WBE Contractor MBE WBE Completed E-Verify Form Attached Yes No Project Name Four Winds Renovation and Expansion Project Number 123-046 Funding Source PO# 24886 Account No. 458-11-206-202-443001--PROJ00000454 Amount $788,545.00 Terms of Contract AIA G802 - 2017 Special Contract Provisions N/A Purpose/Description Additional design fee for construction phase services. For Change Orders Only Amount of Increase Decrease $ ($ ) Previous Amount $ Current Percent of Change: Increase Decrease ( %) New Amount $ Total Percent of Change: Increase Decrease ( %) Time Extension Amount: New Completion Date: