Loading...
HomeMy WebLinkAboutAward Quote -542 N. Scott St. TIF Proj No 123-062A - Stahl Painting Co.1316 COUNTY -CITY BUILDING 227 W. JEFFERSON BOULEVARD SOUTH BEND, INDIANA 46601-1830 PHONE 574/235-9251 FAx 574/235-9171 CITY OF SOUTH BEND TAMES MUELLER, MAYOR BOARD OF PUBLIC WORKS November 14, 2023 Mr. Satori Stahl Stahl Painting Company 13645 McKinley Hwy, Unit F Mishawaka, IN 46545 jordan(kpropertybrosllc.com; stahlpaintingcompany(kgmail.com RE: Quotation Award — 542 N. Scott St. TIF Painting and Siding — Project No. 123-062A Dear Mr. Stahl: At its November 14, 2023 meeting, the Board of Public Works awarded the above referenced quotation to you in the amount of $11,000. Please forward the following documents in one submittal by November 28, 2023 to my attention for Board of Public Works approval at lhensley(ksouthbendin.gov : 1) One (1) signed original of the Contract (enclosed). If you have any further questions, please call this office at (574) 235-9251. Sincerely, /s/ Theresa Heffner Theresa Heffner, Clerk Enclosures TH/lh ELIZABETH A. MARADIK JOSEPH R. MOLNAR GARY A. GILOT ALEXANDRA DOLZ-LANE MURRAY L. MILLER �4,ouTH���d INTER -OFFICE MEMORANDUM y`A°L DEPARTMENT OF PUBLIC WORKS x ` k DIVISION OF ENGINEERING 1Sfi5 TO: Theresa Heffner, Clerk Board of Public Works FROM: Zach Hurst, PE, Sr. Project Engineer SUBJECT: Award Quote - Project No. 123-062A 542 N. Scott Street TIF Project: Painting & Siding DATE: 11 /06/2023 On October 24, 2023, the Board of Public Works opened and read quotes for the above projects. A total of five (5) quote requests were sent to three (3) different contractors all capable of performing the individual scopes of work. The scopes of work include painting and siding work, roof repairs, and window/door replacement at two separate properties: 542 N. Scott St., and 430 Cottage Grove Ave. The work is funded by the Redevelopment Commission. Quotes were solicited from TRCC LLC, a South Bend -based minority -owned business (non -certified); Stahl Painting Company, a Mishawaka -based minority -owned business (non -certified), and Spotlight Renovations, a small contractor based out of Elkhart. A summary of the quotes received is as follows: 123-062A: 123-062B: 542 123-062C: 542 123-062D: 430 123-062E: 430 542 N. Scott N. Scott St. — N. Scott St. — Cottage Grove Cottage Grove St. — Painting Roof Repairs Windows & Ave.— Roof Ave. — & Siding Doors Repairs Windows & Doors TRCC LLC No Quote $4,500 $6,000 $7,500 $4,500 Stahl Painting $11,000 No Quote No Quote No Quote No Quote Spotlight Reno. No Quote* No Quote* No Quote* No Quote* No Quote* *Spotlight Renovations responded to the quote request but neglected to include any attachments with their email. For Project 123-062A, Stahl Painting Company neglected to notarize their non -collusion affidavit. As Stahl Painting Company was the only respondent, no competitive advantage was received, and Stahl Painting Company has since completed and notarized their non -collusion affidavit. I recommend award of the quote for 123-062A 542 N. Scott St. TIF — Painting & Siding to Stahl Painting Company, in the amount of $11,000.00. Funding is available through PR-00028437. Page 1 of 1 Date: Address: 4 d I - CITY OF SOUTH BEND, INDIANA "FACE CONTRACTOR'S QUOTE FOR PUBLIC WORK x Y tsr PROJECT NAME: 542 N. Scott St. TIF Project— Painting and Siding PROJECT NO. 123-062A QUOTES DUE 9:00 A.M. (E.D.T.) on Tuesday, October 24, 2023 (Must be completed for all quotes. Please type or print) 10.1.23 Firm: Stahl Painting Company 13645 McKinley Hwy Unit F, City/State/Zip: Mishawaka, IN 46545 Telephone Number: (574 4)01 2570 Agent of Bidder (if Applicable): Pursuant to notices given, the undersigned offers to furnish labor and/or material necessary to complete the public works project of: 542 N. Scott St. TIF Project — Painting and Siding the City of South Bend, Indiana, in accordance with plans and specifications prepared by: The Citv of South Bend. Department of Public Works and dated 10/16/2023 11,000 for the sum of (enter the Total Quote as shown on the Proposal) (Enter Sum of Total Quote plus Alternates shown on Proposal) ($ 11,000 ) (Numerical) If alternative quotes apply, the undersigned submits a proposal for each in accordance with the notice. Any addendums attached will be specifically referenced at the applicable page. If additional units of material included in the contract are needed, the cost of units must be the same as that shown in the original contract if accepted by the City of South Bend. If the quote is to be awarded on a unit basis, the itemization of the units shall be shown on a separate attachment. The above quote is accepted this Subject to the following conditions: CITY OF SOUTH BEND, INDIANA BOARD OF PUBLIC WORKS Elizabeth A. Maradik, President Gary A. Gilot, Member �y�wy � 9z-t�iy By (Signature) Satori Stahl (Printed Name of Person Signing) ACCEPTANCE day of 20 Joseph R. Molnar, Vice President Alexandra Dolz-Lane, Member Murray L. Miller, Member Attest: Theresa M. Heffner, Clerk Date: November 14, 2023 BOARD OF PUBLIC WORKS CITY OF SOUTH BEND, INDIANA PUBLIC WORKS CONTRACT This Agreement is made and entered into this 26th Day of September, 2023, by and between Stahl Painting Co., Inc, (the "Contractor"), and the Board of Public Works (the "Board"). The Contractor covenants and agrees to make the following improvement, as fully set out in the Request for Quotations, Standard Specifications, Special Provisions, Plans, and Bid Proposals, all of which are set forth as a part of this Contract, for: PROJECT NO. 123-062A DESCRIPTION: 542 N. SCOTT ST. TIF PAINTING AND SIDING COMPLETION DATE: SEE SPECIFICATIONS AMOUNT: $11,000 FUNDING: PR-00028437 The unit prices for this improvement were those prices as received and accepted by the Board on the 24th Day of October, 2023. The Contractor further agrees to notify the assigned Engineer when this improvement is completed. This notification shall be in the form of a Project Completion Affidavit, signed by the Contractor. Upon final acceptance of the improvement by the Engineer, the Contractor's final estimate will be presented to the Board for final Payment with one (1) copy of the Project Completion Affidavit and one (1) copy of a Waiver of Lien. Each of the Parties, by signing below, represents and warrants to the other Party that he/she/it has the authority to bind the named person or entity to this Agreement. CITY OF SOUTH BEND, INDIANA BOARD OF PUBLIC WORKS Elizabeth A. Maradik, President Gary A. Gilot, Member Murray L. Miller, Member /// Joseph R. Molnar, Vice President Alexandra Dolz-Lane, Member r*1 Attest: Theresa M. Heffner, Clerk Date: November 14, 2023 STAHL PAINTING COMPANY Printed Name Signature When the prospective Contractor is unable to certify to any of the statements below, it shall attach an explanation to this Affidavit CONTRACTOR'S NON -COLLUSION AND NON -DEBARMENT AFFIDAVIT, CERTIFICATION REGARDING INVESTMENT WITH IRAN, EMPLOYMENT ELIGIBILITY VERIFICATION, NON-DISCRIMINATION COMMITMENT AND CERTIFICATION OF USE OF UNITED STATES STEEL PRODUCTS OR FOUNDRY PRODUCTS STATE OF (Must be completed for all quotes and bids. Please type or print) SS: COUNTY ) The undersigned Contractor, being duly sworn upon his/her/its oath, affirms under the penalties of perjury that: 1. Contractor has not, nor has any other member, representative, or agent of the firm, company, corporation or partnership represented by him, entered into any combination, collusion or agreement with any person relative to the price to be bid by anyone at such letting nor to prevent any person from bidding nor to induce anyone to refrain from bidding, and that this bid is made without reference to any other bid and without any agreement, understanding or combination with any other person in reference to such bidding. Contractor further says that no person or persons, firms, or corporation has, have or will receive directly or indirectly, any rebate, fee, gift, commission or thing of value on account of such sale; and 2. Contractor certifies by submission of this proposal that neither contractor nor any of its principals are presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any Federal department or agency; and 3. Contractor has not, nor has any successor to, nor an affiliate of, Contractor, engaged in investment activities in Iran. a. For purposes of this Certification, "Iran" means the government of Iran and any agency or instrumentality of Iran, or as otherwise defined at Ind. Code § 5-22-16.5-5, as amended from time -to -time. b. As provided by Ind. Code § 5-22-16.5-8, as amended from time -to -time, a Contractor is engaged in investment activities in Iran if either: i. Contractor, its successor or its affiliate, provides goods or services of twenty million dollars ($20,000,000) or more in value in the energy sector of Iran; or ii. Contractor, its successor or its affiliate, is a financial institution that extends twenty million dollars ($20,000,000) or more in credit to another person for forty-five (45) days or more, if that person will (i) use the credit to provides goods and services in the energy sector in Iran; and (ii) at the time the financial institution extends credit, is a person identified on list published by the Indiana Department of Administration. 4. Contractor does not knowingly employ or contract with an unauthorized alien, nor retain any employee or contract with a person that the Contractor subsequently learns is an unauthorized Version 2/14/2020 Page - 3 Public Works Quote alien. Contractor agrees that he/she/it shall enroll in and verify the work eligibility status of all of Contractor's newly hired employees through the E-Verify Program as defined by I.C. 22-5-1.7-3. Contractor's documentation of enrollment and participation in the E-Verify Program is included and attached as part of this bid/quote; and 5. Contractor shall require his/her/its subcontractors performing work under this public contract to certify that the subcontractors do not knowingly employ or contract with an unauthorized alien, nor retain any employee or contract with a person that the subcontractor subsequently learns is an unauthorized alien, and that the subcontractor has enrolled in and is participating in the E-Verify Program. The Contractor agrees to maintain this certification throughout the term of the contract with the City of South Bend, and understands that the City may terminate the contract for default if the Contractor fails to cure a breach of this provision no later than thirty (30) days after being notified by the City. 6. Persons, partnerships, corporations, associations, or joint venturers awarded a contract by the City of South Bend through its agencies, boards, or commissions shall not discriminate against any employee or applicant for employment in the performance of a City contract with respect to hire, tenure, terms, conditions, or privileges of employment, or any matter directly or indirectly related to employment because of race, sex, religion, color, national origin, ancestry, age, gender expression, gender identity, sexual orientation or disability that does not affect that person's ability to perform the work. In awarding contracts for the purchase of work, labor, services, supplies, equipment, materials, or any combination of the foregoing including, but not limited to, public works contracts awarded under public bidding laws or other contracts in which public bids are not required by law, the City, its agencies, boards, or commissions may consider the Contractor's good faith efforts to obtain participation by those Contractors certified by the State of Indiana as a Minority Business ("MBE") or as a Women's Business Enterprise ("WBE") as a factor in determining the lowest, responsible, responsive bidder. In no event shall persons or entities seeking the award of a City contract be required to award a subcontract to an MBE/WBE; however, it may not unlawfully discriminate against said WBE/MBE. A finding of a discriminatory practice by the City's MBE/WBE Utilization Board shall prohibit that person or entity from being awarded a City contract for a period of one (1) year from the date of such determination, and such determination may also be grounds for terminating the contact for which the discriminatory practice or noncompliance pertains. 7. The undersigned contractor agrees that the following nondiscrimination commitment shall be made a part of any contract which it may henceforth enter into with the City of South Bend, Indiana or any of its agencies, boards or commissions. Contractor agrees not to discriminate against or intimidate any employee or applicant for employment in the performance of this contract with privileges of employment, or any matter directly or indirectly related to employment, because of race, religion, color, sex, gender expression, gender identity, sexual orientation, handicap, national origin or ancestry. Breach of this provision may be regarded as material breach of contract. I, the undersigned bidder or agent as contractor on a public works project, understand my statutory obligations to the use of steel products or foundry products made in the United States (I.C. 5-16- Version 2/14/2020 Page - 4 Public Works Quote 8-1). I hereby certify that I and all subcontractors employed by me for this project will use steel products or foundry products made in the United States on this project if awarded. I understand I have an affirmative duty to notify the City in my bid that my proposal does not include the use of steel products or foundry products made in the United States. I understand it is my sole obligation and responsibility to provide a justification to the City, subject to review and approval, why the cost of United States made steel or foundry products is unreasonable. Prior to award and upon submission of bid which does not use steel products or foundry products made in the United States, the City, through its director of public works, shall make a determination if the price of United States made steel or foundry is unreasonable. I understand that violations hereunder may result in forfeiture of contractual payments. I hereby affirm under the penalties of perjury that the facts and information contained in the foregoing bid for public works are true and correct. Dated this day of �C'W, 20a j - , &b 1 Contractor/Adder (Fyrrtl) or Its Agent Printed Name and Title Subscribed and sworn to before me this day of 20� My Commission Expires• ' J5��� �-� ��- r`9- Ndtar Public County of Residence SONIA PEREZ Notary Public - Seal St Joseph County - State of Indiana Commission Number NP0742766 My Commission Expires Aug 2, 2030 Version 2/14/2020 Page - 5 Public Works Quote BOARD OF PUBLIC WORKS AGENDA ITEM REVIEW REQUEST FORM Date 11/06/2023 Name Zach Hurst Department DPW BPW Date 11/14/2023 Phone Extension 3057 Review and Approval Required Prior to Submittal to Board Diversity Compliance ❑ Officer Name and Inclusion Officer BPW Attorney ❑ Attorney Name Dept. Attorney ❑ Attorney Name Purchasing ❑ Check the Appropriate Item Type — Required for All Submissions ❑ Professional Services Agreement ❑ Contract ❑ Proposal ❑ Open Market Contract ❑ Amendment/Addendum ❑ Special Purchase, QPA ❑ Bid Opening ❑ Bid Award ❑ Req. to Advertise ❑ Title Sheet ❑ Quote Opening ® Quote Award ❑ Reject Bids/Quotes ❑ Proposal Opening ❑ C/O & PCA No. ❑ PCA ❑ Chg. Order, No. ❑ Traffic Control ❑ Resolution n Other: n Ease./Encroach Company or Vendor Name New Vendor MBE/WBE Contractor Project Name Project Number Funding Source Account No. Amount Terms of Contract Purpose/Description Information Stahl Painting Comaan ® Yes ® If Yes, Approved by Purchasing ❑ No ❑ WBE Completed E-Verify Form Attached Yes ❑ No 542 N. Scott St. TIF Project — Painting and Siding 123-062A River West DA TIF PR-00028437 $11,000 Lump Sum Request to award quote to perform painting and siding work at 542 N. Scott Street For Change Orders Only Amount of ❑ Increase $ ❑ Decrease ($ ) Previous Amount $ Increase Current Percent of Change: Decrease New Amount $ Increase Total Percent of Change: Decrease Time Extension Amount: New Completion Date: