The URL can be used to link to this page

Home My WebLink AboutPSA - Fire Station 8 Site Floor Plan Proj No. 122-034 - Shive-Hattery Architecture Engineering Signed 7-8-22 ELIZABETH A. MARADIK JOSEPH R. MOLNAR GARY A. GILOT JORDAN V. GATHERS MURRAY L. MILLER 1316 COUNTY-CITY BUILDING 227 W. JEFFERSON BOULEVARD SOUTH BEND, INDIANA 46601-1830 PHONE 574/ 235-9251 FAX 574/ 235-9171 CITY OF SOUTH BEND JAMES MUELLER, MAYOR BOARD OF PUBLIC WORKS July 12, 2022 Mr. Kyle Copelin, R.A. Shive-Hattery Architecture + Engineering 321 S. Main St. South Bend, IN 46601 KCopelin@shive-hattery.com RE: Professional Services Agreement Dear Mr. Copelin: At its July 12, 2022 meeting, the Board of Public Works approved the above referenced agreement for design services for the programming and schematic to develop a site and floor plan for the new Fire Station No. 8, Project No. 122-034 in the amount of $62,341. Enclosed please find a copy of the agreement for your records. If you have any further questions, please call this office at (574) 235-9251. Sincerely, /s/ Theresa Heffner Theresa Heffner, Clerk Enclosures TH/lh EJCDC E-500 Standard Form of Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. AGREEMENT BETWEEN OWNER AND ENGINEER FOR PROFESSIONAL SERVICES Prepared by ENGINEERS JOINT CONTRACT DOCUMENTS COMMITTEE and Issued and Published Jointly by AMERICAN COUNCIL OF ENGINEERING COMPANIES ______________________ ASSOCIATED GENERAL CONTRACTORS OF AMERICA ______________________ AMERICAN SOCIETY OF CIVIL ENGINEERS _______________________ PROFESSIONAL ENGINEERS IN PRIVATE PRACTICE A Practice Division of the NATIONAL SOCIETY OF PROFESSIONAL ENGINEERS This document has important legal consequences; consultation with an attorney is encouraged with respect to its use or modification. This document should be adapted to the particular circumstances of the contemplated Project and the Controlling Laws and Regulations. EJCDC E-500 Standard Form of Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Copyright © 2008 National Society of Professional Engineers 1420 King Street, Alexandria, VA 22314-2794 (703) 684-2882 www.nspe.org American Council of Engineering Companies 1015 15th Street N.W., Washington, DC 20005 (202) 347-7474 www.acec.org American Society of Civil Engineers 1801 Alexander Bell Drive, Reston, VA 20191-4400 (800) 548-2723 www.asce.org Associated General Contractors of America 2300 Wilson Boulevard, Suite 400, Arlington, VA 22201-3308 (703) 548-3118 www.agc.org The copyright for this EJCDC document is owned jointly by the four EJCDC sponsoring organizations and held in trust for their benefit by NSPE. This Agreement has been prepared for use with the Standard General Conditions of the Construction Contract (EJCDC C-700, 2007 Edition). Their provisions are interrelated, and a change in one may necessitate a change in the other. For guidance on the completion and use of this Agreement, see EJCDC User’s Guide to the Owner-Engineer Agreement, EJCDC E-001, 2009 Edition. TABLE OF CONTENTS Page ARTICLE 1 – SERVICES OF ENGINEER .................................................................................................... 1 1.01 Scope ............................................................................................................................................. 1 ARTICLE 2 – OWNER’S RESPONSIBILITIES............................................................................................ 1 2.01 General .......................................................................................................................................... 1 ARTICLE 3 – SCHEDULE FOR RENDERING SERVICES ........................................................................ 2 3.01 Commencement ............................................................................................................................ 2 3.02 Time for Completion .................................................................................................................... 2 ARTICLE 4 – INVOICES AND PAYMENTS ............................................................................................... 2 4.01 Invoices ......................................................................................................................................... 2 4.02 Payments ....................................................................................................................................... 2 ARTICLE 5 – OPINIONS OF COST .............................................................................................................. 3 5.01 Opinions of Probable Construction Cost ..................................................................................... 3 5.02 Designing to Construction Cost Limit ......................................................................................... 3 5.03 Opinions of Total Project Costs ................................................................................................... 3 ARTICLE 6 – GENERAL CONSIDERATIONS ........................................................................................... 3 6.01 Standards of Performance ............................................................................................................ 3 6.02 Design Without Construction Phase Services ............................................................................. 5 6.03 Use of Documents ........................................................................................................................ 5 6.04 Insurance ....................................................................................................................................... 7 6.05 Suspension and Termination ........................................................................................................ 7 6.06 Controlling Law ............................................................................................................................ 9 6.07 Successors, Assigns, and Beneficiaries ........................................................................................ 9 6.08 Dispute Resolution........................................................................................................................ 9 6.09 Environmental Condition of Site................................................................................................ 10 6.10 Indemnification and Mutual Waiver .......................................................................................... 10 6.11 Miscellaneous Provisions ........................................................................................................... 11 ARTICLE 7 – DEFINITIONS ........................................................................................................................ 12 7.01 Defined Terms ............................................................................................................................ 12 ARTICLE 8 – EXHIBITS AND SPECIAL PROVISIONS .......................................................................... 15 8.01 Exhibits Included ........................................................................................................................ 15 8.02 Total Agreement ......................................................................................................................... 15 8.03 Designated Representatives ........................................................................................................ 16 8.04 Engineer's Certifications ............................................................................................................. 16 Page 1 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. AGREEMENT BETWEEN OWNER AND ENGINEER FOR PROFESSIONAL SERVICES Owner and Engineer further agree as follows: ARTICLE 1 – SERVICES OF ENGINEER 1.01 Scope A.Engineer shall provide, or cause to be provided, the services set forth herein and in Exhibit A. ARTICLE 2 – OWNER’S RESPONSIBILITIES 2.01 General A.Owner shall have the responsibilities set forth herein and in Exhibit B. B.Owner shall pay Engineer as set forth in Exhibit C. C.Owner shall be responsible for, and Engineer may rely upon, the accuracy and completeness of all requirements, programs, instructions, reports, data, and other information furnished by Owner to Engineer pursuant to this Agreement. Engineer may use such requirements, programs, THIS IS AN AGREEMENT effective as of May 27 , 2022 (“Effective Date”) between Board of Public Works, City of South Bend, Indiana (“Owner”) and Shive-Hattery Architecture + Engineering (“Engineer”). Owner's Project, of which Engineer's services under this Agreement are a part, is generally identified as follows: New Fire Station 8 ("Project"). Engineer's services under this Agreement are generally identified as follows: Page 2 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. instructions, reports, data, and information in performing or furnishing services under this Agreement. ARTICLE 3 – SCHEDULE FOR RENDERING SERVICES 3.01 Commencement A.Engineer is authorized to begin rendering services as of the Effective Date. 3.02 Time for Completion A.Engineer shall complete its obligations within a reasonable time. Specific periods of time for rendering services are set forth or specific dates by which services are to be completed are provided in Exhibit A, and are hereby agreed to be reasonable. B.If, through no fault of Engineer, such periods of time or dates are changed, or the orderly and continuous progress of Engineer’s services is impaired, or Engineer’s services are delayed or suspended, then the time for completion of Engineer’s services, and the rates and amounts of Engineer’s compensation, shall be adjusted equitably. C.If Owner authorizes changes in the scope, extent, or character of the Project, then the time for completion of Engineer’s services, and the rates and amounts of Engineer’s compensation, shall be adjusted equitably. D.Owner shall make decisions and carry out its other responsibilities in a timely manner so as not to delay the Engineer’s performance of its services. E.If Engineer fails, through its own fault, to complete the performance required in this Agreement within the time set forth, as duly adjusted, then Owner shall be entitled, as its sole remedy, to the recovery of direct damages, if any, resulting from such failure. ARTICLE 4 – INVOICES AND PAYMENTS 4.01 Invoices A.Preparation and Submittal of Invoices: Engineer shall prepare invoices in accordance with its standard invoicing practices and the terms of Exhibit C. Engineer shall submit its invoices to Owner on a monthly basis. Invoices are due and payable within 35 days of receipt. 4.02 Payments A.Application to Interest and Principal: Payment will be credited first to any interest owed to Engineer and then to principal. B.Failure to Pay: If Owner fails to make any payment due Engineer for services and expenses within 30 days after receipt of Engineer’s invoice, then: 1.amounts due Engineer will be increased at the rate of 1.0% per month (or the maximum rate of interest permitted by law, if less) from said thirtieth day; and Page 3 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. 2.Engineer may, after giving seven days written notice to Owner, suspend services under this Agreement until Owner has paid in full all non-disputed amounts due for services, expenses, and other related charges. Owner waives any and all claims against Engineer for any such suspension. C.Disputed Invoices: If Owner contests an invoice, Owner shall promptly advise Engineer of the specific basis for doing so, may withhold only that portion so contested, and must pay the undisputed portion. D.Legislative Actions: If after the Effective Date any governmental entity takes a legislative action that imposes taxes, fees, or charges on Engineer’s services or compensation under this Agreement, then the Engineer may invoice such new taxes, fees, or charges as a Reimbursable Expense to which a factor of 1.0 shall be applied. Owner shall reimburse Engineer for the cost of such invoiced new taxes, fees, and charges; such reimbursement shall be in addition to the compensation to which Engineer is entitled under the terms of Exhibit C. ARTICLE 5 – OPINIONS OF COST 5.01 Opinions of Probable Construction Cost A.Engineer’s opinions of probable Construction Cost are to be made on the basis of Engineer’s experience and qualifications and represent Engineer’s best judgment as an experienced and qualified professional generally familiar with the construction industry. However, because Engineer has no control over the cost of labor, materials, equipment, or services furnished by others, or over contractors’ methods of determining prices, or over competitive bidding or market conditions, Engineer cannot and does not guarantee that proposals, bids, or actual Construction Cost will not vary from opinions of probable Construction Cost prepared by Engineer. If Owner requires greater assurance as to probable Construction Cost, Owner must employ an independent cost estimator as provided in Exhibit B. 5.02 Designing to Construction Cost Limit A.If a Construction Cost limit is established between Owner and Engineer, such Construction Cost limit and a statement of Engineer’s rights and responsibilities with respect thereto will be specifically set forth in Exhibit F, “Construction Cost Limit,” to this Agreement. 5.03 Opinions of Total Project Costs A.The services, if any, of Engineer with respect to Total Project Costs shall be limited to assisting the Owner in collating the various cost categories which comprise Total Project Costs. Engineer assumes no responsibility for the accuracy of any opinions of Total Project Costs. ARTICLE 6 – GENERAL CONSIDERATIONS 6.01 Standards of Performance A.Standard of Care: The standard of care for all professional engineering and related services performed or furnished by Engineer under this Agreement will be the care and skill ordinarily used by members of the subject profession practicing under similar circumstances at the same Page 4 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. time and in the same locality. Engineer makes no warranties, express or implied, under this Agreement or otherwise, in connection with Engineer’s services. B.Technical Accuracy: Owner shall not be responsible for discovering deficiencies in the technical accuracy of Engineer’s services. Engineer shall correct deficiencies in technical accuracy without additional compensation, unless such corrective action is directly attributable to deficiencies in Owner-furnished information. C.Consultants: Engineer may employ such Consultants as Engineer deems necessary to assist in the performance or furnishing of the services, subject to reasonable, timely, and substantive objections by Owner. D.Reliance on Others: Subject to the standard of care set forth in Paragraph 6.01.A, Engineer and its Consultants may use or rely upon design elements and information ordinarily or customarily furnished by others, including, but not limited to, specialty contractors, manufacturers, suppliers, and the publishers of technical standards. E.Compliance with Laws and Regulations, and Policies and Procedures: 1.Engineer and Owner shall comply with applicable Laws and regulations. 2.Prior to the Effective Date, Owner provided to Engineer in writing any and all policies and procedures of Owner applicable to Engineer's performance of services under this Agreement. provided to Engineer in writing. Engineer shall comply with such policies and procedures, subject to the standard of care set forth in Paragraph 6.01.A, and to the extent compliance is not inconsistent with professional practice requirements. 3.This Agreement is based on Laws and Regulations and Owner -provided written policies and procedures as of the Effective Date. Changes after the Effective Date to these Laws and Regulations, or to Owner-provided written policies and procedures, may be the basis for modifications to Owner’s responsibilities or to Engineer’s scope of services, times of performance, or compensation. F.Engineer shall not be required to sign any documents, no matter by whom requested, that would result in the Engineer having to certify, guarantee, or warrant the existence of conditions whose existence the Engineer cannot ascertain. Owner agrees not to make resolution of any dispute with the Engineer or payment of any amount due to the Engineer in any way contingent upon the Engineer signing any such documents. G.The general conditions for any construction contract documents prepared hereunder are to be the “Standard General Conditions of the Construction Contract” as prepared by the Engineers Joint Contract Documents Committee (EJCDC C-700, 2007 Edition) unless both parties mutually agree to use other general conditions by specific reference in Exhibit J. H.Engineer shall not at any time supervise, direct, control, or have authority over any contractor work, nor shall Engineer have authority over or be responsible for the means, methods, techniques, sequences, or procedures of construction selected or used by any contractor, or the safety precautions and programs incident thereto, for security or safety at the Site, nor for any Page 5 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. failure of a contractor to comply with Laws and Regulations applicable to such contractor’s furnishing and performing of its work. I.Engineer neither guarantees the performance of any Contractor nor assumes responsibility for any Contractor’s failure to furnish and perform the Work in accordance with the Contract Documents. J.Engineer shall not provide or have any responsibility for surety bonding or insurance-related advice, recommendations, counseling, or research, or enforcement of construction insurance or surety bonding requirements. K.Engineer shall not be responsible for the acts or omissions of any Contractor, Subcontractor, or Supplier, or of any of their agents or employees or of any other persons (except Engineer’s own agents, employees, and Consultants) at the Site or otherwise furnishing or performing any Work; or for any decision made regarding the Contract Documents, or any application, interpretation, or clarification, of the Contract Documents, other than those made by Engineer. L.While at the Site, Engineer's employees and representatives shall comply with the specific applicable requirements of Contractor's and Owner's safety programs of which Engineer has been informed in writing. 6.02 Design Without Construction Phase Services A.Engineer shall be responsible only for those Construction Phase services expressly required of Engineer in Exhibit A, Paragraph A1.05. With the exception of such expressly required services, Engineer shall have no design, Shop Drawing review, or other obligations during construction and Owner assumes all responsibility for the application and interpretation of the Contract Documents, review and response to Contractor claims, contract administration, processing Change Orders, revisions to the Contract Documents during construction, construction surety bonding and insurance requirements, construction observation and review, review of payment applications, and all other necessary Construction Phase engineering and professional services. Owner waives all claims against the Engineer that may be connected in any way to Construction Phase engineering or professional services except for those services that are expressly required of Engineer in Exhibit A, Paragraph A1.05. 6.03 Use of Documents A.The Owner acknowledges the Engineer’s construction documents, including all electronic files, as instruments of professional services. Nevertheless, the final construction documents, including all electronic files, prepared under this agreement shall become the property of the Owner upon completion of services and payment in full of all monies due to the Engineer. The Owner shall not reuse or make any modification to the construction documents without the prior written authorization of the Engineer. All Documents are instruments of service in respect to this Project, and Engineer shall retain an ownership and property interest therein (including the copyright and the right of reuse at the discretion of the Engineer) whether or not the Project is completed. Owner shall not rely in any way on any Document unless it is in printed form, signed or sealed by the Engineer or one of its Consultants. B.Either party to this Agreement may rely that data or information set forth on paper (also known as hard copies) that the party receives from the other party by mail, hand delivery, or facsimile, are Page 6 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. the items that the other party intended to send. Files in electronic media format of text, data, graphics, or other types that are furnished by one party to the other are furnished only for convenience, not reliance by the receiving party. Any conclusion or information obtained or derived from such electronic files will be at the user’s sole risk. If there is a discrepancy between the electronic files and the hard copies, the hard copies govern. If the parties agree to other electronic transmittal procedures, such are set forth in Exhibit J. C.Because data stored in electronic media format can deteriorate or be modified inadvertently or otherwise without authorization of the data’s creator, the party receiving electronic files agrees that it will perform acceptance tests or procedures within 60 days, after which the receiving party shall be deemed to have accepted the data thus transferred. Any transmittal errors detected within the 60-day acceptance period will be corrected by the party delivering the electronic files. D.When transferring documents in electronic media format, the transferring party makes no representations as to long-term compatibility, usability, or readability of such documents resulting from the use of software application packages, operating systems, or computer hardware differing from those used by the documents’ creator. E.Owner may make and retain copies of Documents for information and reference in connection with use on the Project by Owner. Engineer grants Owner a limited license to use the Documents on the Project, extensions of the Project, and for related uses of the Owner, subject to receipt by Engineer of full payment for all services relating to preparation of the Documents and subject to the following limitations: (1) Owner acknowledges that such Documents are not intended or represented to be suitable for use on the Project unless completed by Engineer, or for use or reuse by Owner or others on extensions of the Project, on any other project, or for any other use or purpose, without written verification or adaptation by Engineer; (2) any such use or reuse, or any modification of the Documents, without written verification, completion, or adaptation by Engineer, as appropriate for the specific purpose intended, will be at Owner’s sole risk and without liability or legal exposure to Engineer or to its officers, directors, members, partners, agents, employees, and Consultants; (3) Owner shall indemnify and hold harmless Engineer and its officers, directors, members, partners, agents, employees, and Consultants from all claims, damages, losses, and expenses, including attorneys’ fees, arising out of or resulting from any use, reuse, or modification of the Documents without written verification, completion, or adaptation by Engineer; and (4) such limited license to Owner shall not create any rights in third parties. F.If Engineer at Owner’s request verifies the suitability of the Documents, completes them, or adapts them for extensions of the Project or for any other purpose, then Owner shall compensate Engineer at rates or in an amount to be agreed upon by Owner and Engineer. G.At completion of any survey services and upon payment of monies due the Engineer for those services, the Engineer shall provide the owner with all survey data and drawings, upon which it will become the property of the Owner. H.At completion of any traffic study services and upon payment of monies due the Engineer for those services, the Engineer shall provide the owner with all data and models, upon which it will become the property of the Owner. Page 7 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. I.At completion of any geotechnical or material investigation services and upon payment of monies due the Engineer for those services, the Engineer shall provide the owner with all data, upon which it will become the property of the Owner. 6.04 Insurance A.Engineer shall procure and maintain insurance as set forth in Exhibit G, “Insurance.” Engineer shall cause Owner to be listed as an additional insured on any applicable general liability insurance policy carried by Engineer. B.Owner shall procure and maintain insurance as set forth in Exhibit G, “Insurance.” Owner shall cause Engineer and its Consultants to be listed as additional insureds on any general liability policies and as loss payees on any property insurance policies carried by Owner which are applicable to the Project. C.Owner shall require Contractor to purchase and maintain policies of insurance covering workers' compensation, general liability, property damage (other than to the Work itself), motor vehicle damage and injuries, and other insurance necessary to protect Owner's and Engineer's interests in the Project. Owner shall require Contractor to cause Engineer and its Consultants to be listed as additional insureds with respect to such liability and other insurance purchased and maintained by Contractor for the Project. D.Owner and Engineer shall each deliver to the Owner other certificates of insurance evidencing the coverages indicated in Exhibit G. Such certificates shall be furnished prior to commencement of Engineer’s services and at renewals thereafter during the life of the Agreement. E.All policies of property insurance relating to the Project shall contain provisions to the effect that Engineer’s and its Consultants’ interests are covered and that in the event of payment of any loss or damage the insurers will have no rights of recovery against Engineer or its Consultants, or any insureds, additional insureds, or loss payees thereunder. F.All policies of insurance shall contain a provision or endorsement that the coverage afforded will not be canceled or reduced in limits by endorsement, and that renewal will not be refused, until at least 30 days prior written notice has been given to Owner and Engineer and to each other additional insured (if any) to which a certificate of insurance has been issued. G.At any time, Owner may request that Engineer or its Consultants, at Owner’s sole expense, provide additional insurance coverage, increased limits, or revised deductibles that are more protective than those specified in Exhibit G. If so requested by Owner, and if commercially available, Engineer shall obtain and shall require its Consultants to obtain such additional insurance coverage, different limits, or revised deductibles for such periods of time as requested by Owner, and Exhibit G will be supplemented to incorporate these requirements. 6.05 Suspension and Termination A.Suspension: 1.By Owner: Owner may suspend the Project for up to 90 days upon seven days written notice to Engineer. Page 8 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. 2.By Engineer: Engineer may, after giving seven days written notice to Owner, suspend services under this Agreement if Engineer's performance has been substantially delayed through no fault of Engineer. B.Termination: The obligation to provide further services under this Agreement may be terminated: 1.For cause, a.By either party upon 30 days written notice in the event of substantial failure by the other party to perform in accordance with the terms hereof through no fault of the terminating party. b.By Engineer: 1)upon seven days written notice if Owner demands that Engineer furnish or perform services contrary to Engineer’s responsibilities as a licensed professional; or 2)upon seven days written notice if the Engineer’s services for the Project are delayed or suspended for more than 90 days for reasons beyond Engineer’s control. 3)Engineer shall have no liability to Owner on account of such termination. c.Notwithstanding the foregoing, this Agreement will not terminate under Paragraph 6.05.B.1.a if the party receiving such notice begins, within seven days of receipt of such notice, to correct its substantial failure to perform and proceeds diligently to cure such failure within no more than 30 days of receipt thereof; provided, however, that if and to the extent such substantial failure cannot be reasonably cured within such 30 day period, and if such party has diligently attempted to cure the same and thereafter continues diligently to cure the same, then the cure period provided for herein shall extend up to, but in no case more than, 60 days after the date of receipt of the notice. 2.For convenience, a.By Owner effective upon Engineer’s receipt of notice from Owner. C.Effective Date of Termination: The terminating party under Paragraph 6.05.B may set the effective date of termination at a time up to 30 days later than otherwise provided to allow Engineer to demobilize personnel and equipment from the Site, to complete tasks whose value would otherwise be lost, to prepare notes as to the status of completed and uncompleted tasks, and to assemble Project materials in orderly files. D.Payments Upon Termination: 1.In the event of any termination under Paragraph 6.05, Engineer will be entitled to invoice Owner and to receive full payment for all services performed or furnished in accordance with Page 9 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. this Agreement and all Reimbursable Expenses incurred through the effective date of termination. Upon making such payment, Owner shall have the limited right to the use of Documents, at Owner’s sole risk, subject to the provisions of Paragraph 6.03.E. 2.In the event of termination by Owner for convenience or by Engineer for cause, Engineer shall be entitled, in addition to invoicing for those items identified in Paragraph 6.05.D.1, to invoice Owner and to payment of a reasonable amount for services and expenses directly attributable to termination, both before and after the effective date of termination, such as reassignment of personnel, costs of terminating contracts with Engineer’s Consultants, and other related close-out costs, using methods and rates for Additional Services as set forth in Exhibit C. 6.06 Controlling Law A.This Agreement is to be governed by the law of the state or jurisdiction in which the Project is located. 6.07 Successors, Assigns, and Beneficiaries A.Owner and Engineer are hereby bound and the successors, executors, administrators, and legal representatives of Owner and Engineer (and to the extent permitted by Paragraph 6.07.B the assigns of Owner and Engineer) are hereby bound to the other party to this Agreement and to the successors, executors, administrators and legal representatives (and said assigns) of such other party, in respect of all covenants, agreements, and obligations of this Agreement. B.Neither Owner nor Engineer may assign, sublet, or transfer any rights under or interest (including, but without limitation, moneys that are due or may become due) in this Agreement without the written consent of the other, except to the extent that any assignment, subletting, or transfer is mandated or restricted by law. Unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under this Agreement. C.Unless expressly provided otherwise in this Agreement: 1.Nothing in this Agreement shall be construed to create, impose, or give rise to any duty owed by Owner or Engineer to any Contractor, Subcontractor, Supplier, other individual or entity, or to any surety for or employee of any of them. 2.All duties and responsibilities undertaken pursuant to this Agreement will be for the sole and exclusive benefit of Owner and Engineer and not for the benefit of any other party. 3.Owner agrees that the substance of the provisions of this Paragraph 6.07.C shall appear in the Contract Documents. 6.08 Dispute Resolution A.Owner and Engineer agree to negotiate all disputes between them in good faith for a period of 30 days from the date of notice prior to invoking the procedures of Exhibit H or other provisions of this Agreement, or exercising their rights under law. Page 10 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. B.If the parties fail to resolve a dispute through negotiation under Paragraph 6.08.A, then either or both may invoke the procedures of Exhibit H. If Exhibit H is not included, or if no dispute resolution method is specified in Exhibit H, then the parties may exercise their rights under law. 6.09 Environmental Condition of Site A.Owner has disclosed to Engineer in writing the existence of all known and suspected Asbestos, PCBs, Petroleum, Hazardous Waste, Radioactive Material, hazardous substances, and other Constituents of Concern located at or near the Site, including type, quantity, and location. B.Owner represents to Engineer that to the best of its knowledge no Constituents of Concern, other than those disclosed in writing to Engineer, exist at the Site. C.If Engineer encounters or learns of an undisclosed Constituent of Concern at the Site, then Engineer shall notify (1) Owner and (2) appropriate governmental officials if Engineer reasonably concludes that doing so is required by applicable Laws or Regulations. D.It is acknowledged by both parties that Engineer’s scope of services does not include any services related to Constituents of Concern. If Engineer or any other party encounters an undisclosed Constituent of Concern, or if investigative or remedial action, or other professional services, are necessary with respect to disclosed or undisclosed Constituents of Concern, then Engineer may, at its option and without liability for consequential or any other damages, suspend performance of services on the portion of the Project affected thereby until Owner: (1) retains appropriate specialist consultants or contractors to identify and, as appropriate, abate, remediate, or remove the Constituents of Concern; and (2) warrants that the Site is in full compliance with applicable Laws and Regulations. E.If the presence at the Site of undisclosed Constituents of Concern adversely affects the performance of Engineer’s services under this Agreement, then the Engineer shall have the option of (1) accepting an equitable adjustment in its compensation or in the time of completion, or both; or (2) terminating this Agreement for cause on 30 days notice. F.Owner acknowledges that Engineer is performing professional services for Owner and that Engineer is not and shall not be required to become an "owner" “arranger,” “operator,” “generator,” or “transporter” of hazardous substances, as defined in the Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA), as amended, which are or may be encountered at or near the Site in connection with Engineer’s activities under this Agreement. 6.10 Indemnification and Mutual Waiver A.Indemnification by Engineer: To the fullest extent permitted by law, Engineer shall indemnify and hold harmless Owner, and Owner’s officers, directors, members, partners, agents, consultants, and employees from reasonable claims, costs, losses, and damages arising out of or relating to the Project, provided that any such claim, cost, loss, or damage is attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom, but only to the extent caused by any negligent act or omission of Engineer or Engineer’s officers, directors, members, partners, agents, Page 11 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. employees, or Consultants. This indemnification provision is subject to and limited by the provisions, if any, agreed to by Owner and Engineer in Exhibit I, “Limitations of Liability." B.Indemnification by Owner: Owner shall indemnify and hold harmless Engineer and its officers, directors, members, partners, agents, employees, and Consultants as required by Laws and Regulations and to the extent (if any) required in Exhibit I, Limitations of Liability. C.Environmental Indemnification: To the fullest extent permitted by law, Owner shall indemnify and hold harmless Engineer and its officers, directors, members, partners, agents, employees, and Consultants from and against any and all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys and other professionals, and all court, arbitration, or other dispute resolution costs) caused by, arising out of, relating to, or resulting from a Constituent of Concern at, on, or under the Site, provided that (1) any such claim, cost, loss, or damage is attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom, and (2) nothing in this paragraph shall obligate Owner to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence or willful misconduct. D.Percentage Share of Negligence: To the fullest extent permitted by law, a party’s total liability to the other party and anyone claiming by, through, or under the other party for any cost, loss, or damages caused in part by the negligence of the party and in part by the negligence of the other party or any other negligent entity or individual, shall not exceed the percentage share that the party’s negligence bears to the total negligence of Owner, Engineer, and all other negligent entities and individuals. E.Mutual Waiver: To the fullest extent permitted by law, Owner and Engineer waive against each other, and the other’s employees, officers, directors, members, agents, insurers, partners, and consultants, any and all claims for or entitlement to special, incidental, indirect, or consequential damages arising out of, resulting from, or in any way related to the Project. 6.11 Miscellaneous Provisions A.Notices: Any notice required under this Agreement will be in writing, addressed to the appropriate party at its address on the signature page and given personally, by facsimile, by registered or certified mail postage prepaid, or by a commercial courier service. All notices shall be effective upon the date of receipt. B.Survival: All express representations, waivers, indemnifications, and limitations of liability included in this Agreement will survive its completion or termination for any reason. C.Severability: Any provision or part of the Agreement held to be void or unenforceable under any Laws or Regulations shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon Owner and Engineer, which agree that the Agreement shall be reformed to replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provision. Page 12 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. D.Waiver: A party’s non-enforcement of any provision shall not constitute a waiver of that provision, nor shall it affect the enforceability of that provision or of the remainder of this Agreement. E.Accrual of Claims: To the fullest extent permitted by law, all causes of action arising under this Agreement shall be deemed to have accrued, and all statutory periods of limitation shall commence, no later than the date of Substantial Completion. ARTICLE 7 – DEFINITIONS 7.01 Defined Terms A.Wherever used in this Agreement (including the Exhibits hereto) terms (including the singular and plural forms) printed with initial capital letters have the meanings indicated in the text above, in the exhibits, or in the following provisions: 1.Additional Services – The services to be performed for or furnished to Owner by Engineer in accordance with Part 2 of Exhibit A of this Agreement. 2.Agreement – This written contract for professional services between Owner and Engineer, including all exhibits identified in Paragraph 8.01 and any duly executed amendments. 3.Asbestos – Any material that contains more than one percent asbestos and is friable or is releasing asbestos fibers into the air above current action levels established by the United States Occupational Safety and Health Administration. 4.Basic Services – The services to be performed for or furnished to Owner by Engineer in accordance with Part 1 of Exhibit A of this Agreement. 5.Construction Contract – The entire and integrated written agreement between Owner and Contractor concerning the Work. 6.Construction Cost – The cost to Owner of those portions of the entire Project designed or specified by Engineer. Construction Cost does not include costs of services of Engineer or other design professionals and consultants; cost of land or rights-of-way, or compensation for damages to properties; Owner’s costs for legal, accounting, insurance counseling or auditing services; interest or financing charges incurred in connection with the Project; or the cost of other services to be provided by others to Owner pursuant to Exhibit B of this Agreement. Construction Cost is one of the items comprising Total Project Costs. 7.Constituent of Concern – Any substance, product, waste, or other material of any nature whatsoever (including, but not limited to, Asbestos, Petroleum, Radioactive Material, and PCBs) which is or becomes listed, regulated, or addressed pursuant to (a) the Comprehensive Environmental Response, Compensation and Liability Act, 42 U.S.C. §§9601 et seq. (“CERCLA”); (b) the Hazardous Materials Transportation Act, 49 U.S.C. §§1801 et seq.; (c) the Resource Conservation and Recovery Act, 42 U.S.C. §§6901 et seq. (“RCRA”); (d) the Toxic Substances Control Act, 15 U.S.C. §§2601 et seq.; (e) the Clean Water Act, 33 U.S.C. §§1251 et seq.; (f) the Clean Air Act, 42 U.S.C. §§7401 et Page 13 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. seq.; and (g) any other federal, state, or local statute, law, rule, regulation, ordinance, resolution, code, order, or decree regulating, relating to, or imposing liability or standards of conduct concerning, any hazardous, toxic, or dangerous waste, substance, or material. 8.Consultants – Individuals or entities having a contract with Engineer to furnish services with respect to this Project as Engineer’s independent professional associates and consultants; subcontractors; or vendors. 9.Contract Documents – Those items so designated in the Construction Contract, including the Drawings, Specifications, construction agreement, and general and supplementary conditions. Only printed or hard copies of the items listed in the Construction Contract are Contract Documents. Approved Shop Drawings, other Contractor submittals, and the reports and drawings of subsurface and physical conditions are not Contract Documents. 10.Contractor – The entity or individual with which Owner has entered into a Construction Contract. 11.Documents – Data, reports, Drawings, Specifications, Record Drawings, and other deliverables, whether in printed or electronic media format, provided or furnished in appropriate phases by Engineer to Owner pursuant to this Agreement. 12.Drawings – That part of the Contract Documents prepared or approved by Engineer which graphically shows the scope, extent, and character of the Work to be performed by Contractor. Shop Drawings are not Drawings as so defined. 13.Effective Date – The date indicated in this Agreement on which it becomes effective, but if no such date is indicated, the date on which this Agreement is signed and delivered by the last of the parties to sign and deliver. 14.Engineer – The individual or entity named as such in this Agreement. 15.Hazardous Waste – The term Hazardous Waste shall have the meaning provided in Section 1004 of the Solid Waste Disposal Act (42 USC Section 6903) as amended from time to time. 16.Laws and Regulations; Laws or Regulations – Any and all applicable laws, rules, regulations, ordinances, codes, and orders of any and all governmental bodies, agencies, authorities, and courts having jurisdiction. 17.Owner – The individual or entity with which Engineer has entered into this Agreement and for which the Engineer's services are to be performed. Unless indicated otherwise, this is the same individual or entity that will enter into any Construction Contracts concerning the Project. 18.PCBs – Polychlorinated biphenyls. 19.Petroleum – Petroleum, including crude oil or any fraction thereof which is liquid at standard conditions of temperature and pressure (60 degrees Fahrenheit and 14.7 pounds per square inch absolute), such as oil, petroleum, fuel oil, oil sludge, oil refuse, gasoline, kerosene, and oil mixed with other non-hazardous waste and crude oils. Page 14 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. 20.Project – The total construction of which the Work to be performed under the Contract Documents may be the whole, or a part. 21.Radioactive Material – Source, special nuclear, or byproduct material as defined by the Atomic Energy Act of 1954 (42 USC Section 2011 et seq.) as amended from time to time. 22.Record Drawings – Drawings depicting the completed Project, prepared by Engineer as an Additional Service and based solely on Contractor's record copy of all Drawings, Specifications, addenda, change orders, work change directives, field orders, and written interpretations and clarifications, as delivered to Engineer and annotated by Contractor to show changes made during construction. 23.Reimbursable Expenses – The expenses incurred directly by Engineer in connection with the performing or furnishing of Basic and Additional Services for the Project. 24.Resident Project Representative – The authorized representative of Engineer assigned to assist Engineer at the Site during the Construction Phase. As used herein, the term Resident Project Representative or "RPR" includes any assistants or field staff of Resident Project Representative agreed to by Owner. The duties and responsibilities of the Resident Project Representative, if any, are as set forth in Exhibit D. 25.Samples – Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and which establish the standards by which such portion of the Work will be judged. 26.Shop Drawings – All drawings, diagrams, illustrations, schedules, and other data or information which are specifically prepared or assembled by or for Contractor and submitted by Contractor to illustrate some portion of the Work. 27.Site – Lands or areas to be indicated in the Contract Documents as being furnished by Owner upon which the Work is to be performed, including rights-of-way and easements for access thereto, and such other lands furnished by Owner which are designated for the use of Contractor. 28.Specifications – That part of the Contract Documents consisting of written technical descriptions of materials, equipment, systems, standards, and workmanship as applied to the Work and certain administrative details applicable thereto. 29.Subcontractor – An individual or entity having a direct contract with Contractor or with any other Subcontractor for the performance of a part of the Work at the Site. 30.Substantial Completion – The time at which the Work (or a specified part thereof) has progressed to the point where, in the opinion of Engineer, the Work (or a specified part thereof) is sufficiently complete, in accordance with the Contract Documents, so that the Work (or a specified part thereof) can be utilized for the purposes for which it is intended. The terms “substantially complete” and “substantially completed” as applied to all or part of the Work refer to Substantial Completion thereof. Page 15 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. 31.Supplier – A manufacturer, fabricator, supplier, distributor, materialman, or vendor having a direct contract with Contractor or with any Subcontractor to furnish materials or equipment to be incorporated in the Work by Contractor or Subcontractor. 32.Total Project Costs – The sum of the Construction Cost, allowances for contingencies, and the total costs of services of Engineer or other design professionals and consultants, together with such other Project-related costs that Owner furnishes for inclusion, including but not limited to cost of land, rights-of-way, compensation for damages to properties, Owner’s costs for legal, accounting, insurance counseling and auditing services, interest and financing charges incurred in connection with the Project, and the cost of other services to be provided by others to Owner pursuant to Exhibit B of this Agreement. 33.Work – The entire construction or the various separately identifiable parts thereof required to be provided under the Contract Documents. Work includes and is the result of performing or providing all labor, services, and documentation necessary to produce such construction, and furnishing, installing, and incorporating all materials and equipment into such construction, all as required by the Contract Documents. ARTICLE 8 – EXHIBITS AND SPECIAL PROVISIONS 8.01 Exhibits Included: A.Exhibit A, Engineer’s Services. B.Exhibit B, Owner’s Responsibilities. C.Exhibit C, Payments to Engineer for Services and Reimbursable Expenses. D.Exhibit D, Duties, Responsibilities and Limitations of Authority of Resident Project Representative. E.Exhibit E, Notice of Acceptability of Work. F.Exhibit F, Construction Cost Limit. NOT INCLUDED G.Exhibit G, Insurance. H.Exhibit H, Dispute Resolution. NOT INCLUDED I.Exhibit I, Limitations of Liability. J.Exhibit J, Special Provisions. K.Exhibit K, Amendment to Owner-Engineer Agreement. NOT INCLUDED 8.02 Total Agreement: A.This Agreement, (together with the exhibits identified above) constitutes the entire agreement between Owner and Engineer and supersedes all prior written or oral understandings. This Page 16 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. Agreement may only be amended, supplemented, modified, or canceled by a duly executed written instrument based on the format of Exhibit K to this Agreement. 8.03 Designated Representatives: A.With the execution of this Agreement, Engineer and Owner shall designate specific individuals to act as Engineer’s and Owner’s representatives with respect to the services to be performed or furnished by Engineer and responsibilities of Owner under this Agreement. Such an individual shall have authority to transmit instructions, receive information, and render decisions relative to the Project on behalf of the respective party whom the individual represents. 8.04 Engineer's Certifications: A.Engineer certifies that it has not engaged in corrupt, fraudulent, or coercive practices in competing for or in executing the Agreement. For the purposes of this Paragraph 8.04: 1."corrupt practice" means the offering, giving, receiving, or soliciting of any thing of value likely to influence the action of a public official in the selection process or in the Agreement execution; 2."fraudulent practice" means an intentional misrepresentation of facts made (a) to influence the selection process or the execution of the Agreement to the detriment of Owner, or (b) to deprive Owner of the benefits of free and open competition; 3."coercive practice" means harming or threatening to harm, directly or indirectly, persons or their property to influence their participation in the selection process or affect the execution of the Agreement. IN WITNESS WHEREOF, the parties hereto have executed this Agreement, the Effective Date of which is indicated on page 1. Owner: Engineer: City of South Bend, Indiana Board of Public Works Shive-Hattery Architecture + Engineering By: By: Title: Elizabeth A. Maradik, President Title: Kyle Copelin, R.A., Principal By: Title: Joseph R. Molnar, Vice President By: Title: Jordan V. Gathers, Member July 12, 2022 Page 17 EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. By: Title: Gary A. Gilot, Member By: Title: Murray Miller, Member Attest: Title: Theresa Heffner, Clerk Date: Date: May 27, 2022 Engineer License or Firm's Certificate No. AR11000101 State of: IN Address for giving notices: Address for giving notices: 227 West Jefferson Boulevard South Bend, Indiana 46601 321 S. Main Street South Bend, IN 46601 Designated Representative (Paragraph 8.03.A): Designated Representative (Paragraph 8.03.A): Kara M. Boyles, Ph.D., P.E. Kyle Copelin, R.A. Title: City Engineer Title: Principal Phone Number: (574) 235-5933 Phone Number: (574)307-9990 Facsimile Number: (574) 235-9171 Facsimile Number: (319)364-4251 E-Mail Address: kboyles@southbendin.gov E-Mail Address: KCopelin@shive-hattery.com Page 1 (Exhibit A – Engineer’s Services) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. This is EXHIBIT A, consisting of 8 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated May 27, 2022. See page 2 of Exhibit A. Project 217220187P Shive-Hattery | 321 S. Main Street | Suite 103 | South Bend, IN 46601 | 574.307.9990 | shive-hattery.com PROFESSIONAL SERVICES AGREEMENT ATTN: Chief Carl Buchanon South Bend Fire Department CLIENT: City of South Bend, IN 1222 South Michigan South Bend, IN 46601 PROJECT: South Bend Fire Station #8 PROJECT LOCATION: South Bend, IN DATE OF AGREEMENT: May 11, 2022 PROJECT DESCRIPTION It is our pleasure to present to you a proposal for initial design services for a new South Bend Fire Station #8 located at the corner of Twyckenham Dr and Altgeld St. This proposal includes programming, schematic building & site design, and cost estimation. SCOPE OF SERVICES Design Services Design services shall consist of two periods: Programming and Schematic Design. Each period will end with select deliverables in addition to a follow-up meeting. Programming •Review current planning documents with the City/Department •Conduct interviews with the Fire Department and station staff to identify current and future needs of the station o Working with you to develop and deliver an efficient and safe environment for your first responders is our highest goal. We will work with the fire department representatives to develop a comprehensive building and site program that defines your current and future needs. We expect to meet several times to develop this program with representatives from the South Bend Fire Department, the City of South Bend, and any other necessary stakeholders. Utilizing a programming matrix developed on past fire station projects, we can efficiently determine existing and future needs and use this in later cost estimating exercises. •Deliverable: Written Program of Requirements for the new station, including interior and exterior space requirements, and site requirements, inc orporating current NFPA standards Schematic Building & Site Design •Prepare a schematic design package o The schematic design package will be the result of collaboration between the City, Fire Department, and the Shive-Hattery team, and will include a conceptual site plan, floor plans, and elevations built upon programming and site selection criteria established in the programming phase. We will develop detailed floor plans, MEP system narratives, Page 2 of 7 Project 217220187P | May 11, 2022 and initial site layouts. We will review these plans with relevant stakeholders and revise the design as necessary in preparation for moving into future phases of the project. o We will develop a site model in computer aided design (CAD) software that displays site criteria from comprehensive site research (i.e., wetlands, parcel boundaries, contours, floodplain, environmental conditions/plumes, and easements). By performing this exercise the overall building and site program can be situated properly on the site. o We will conclude this phase with a presentation of the approved schematic design, construction costs, and anticipated project schedule to relevant stakeholders. •Prepare room data sheets for each space identified in the Space Program. o These data sheets will give a detailed description of the finishes, fixtures and fittings, and mechanical and electrical requirements that will be required for each room. These will help the design team engage with users of the spaces to ensure that they fully understand each room’s specific requirements and to ensure the design intent aligns with the needs of the City and Department. •Provide estimated total construction project cost estimate o Once a clear and concise schematic design package has been completed and approved, we will work with our consultants to develop a preliminary cost estimate to help you determine an overall project budget for moving the project forward •Deliverables: Schematic design site plan, floor plan, and elevations; Room data sheets; estimated total construction cost estimate. CLIENT RESPONSIBILITIES Shive-Hattery is not a municipal advisor as defined by the Dodd-Frank Act and as such does not offer municipal advisory services including advice regarding any municipal financial products or securities. Any advice or recommendations provided to the client is intended as architectural/engineering services and should not be interpreted as advice regarding municipal financial products or service s. The client understands they are responsible to retain the services of a registered municipal advisor for any advice it seeks regarding municipal financial products and securities. It will be your responsibility to provide the following: 1.Identify a Project Representative with full authority to act on behalf of the Client with respect to this project. The Client Project Representative shall render decisions in a timely manner in order to avoid delays of Shive-Hattery’s services. 2.Legal, accounting, and insurance counseling services or other consultants, including geotechnical, or vendors that may be necessary. The Client shall coordinate these services with those services provided by Shive-Hattery. 3.Provide to Shive-Hattery any available drawings, survey plats, testing data and reports related to the project, either hard copy or electronic media. Electronic media is preferred. 4.Unless specifically included in the Scope of Services to be provided by Shive-Hattery, the Client shall furnish tests, inspections, permits and reports required by law, regulation or code including but not limited to hazardous materials, structural, mechanical, chemical, air pollution and water pollution tests. 5.Provide Shive-Hattery personnel unlimited access to the site as required. SCHEDULE Working with the initial programming information gathered, we are prepared to begin immediately. •We will meet with you to develop a mutually agreed-upon schedule for the Scope of Services. Page 3 of 7 Project 217220187P | May 11, 2022 COMPENSATION The fees below represent the time and effort required to complete the scope of work outlined in this proposal. Description Fee Type Fee Estimated Expenses Total Programming Fixed Fee $15,806 Included $15,806 Schematic Design Package Fixed Fee $46,535 Included $46,535 TOTAL $62,341 Included $62,341 Fee Types: •Fixed Fee - We will provide the Scope of Services for the fee amounts listed above. Expenses: •Included - For Fixed Fee Type, expenses have been included in the Fee amount. For Hourly Fee Types, expenses will be reimbursed in accordance with our Reimbursable Expense Fee Schedule in effect at the time that the expense is incurred. The terms of this proposal are valid for 30 days from the date of this proposal. ADDITIONAL SERVICES Unless specifically stated in the Scope of Services, any resilient design related services including areas of resistance, reliability and redundancy (i.e. flood protection, storm/tornado shelter, emergency generators, utility backup, etc.) are not included in this proposal. The following are additional services you may require for your project. We can provide these services, but they are not part of this proposal at this time. •LEED Certification •Photo-realistic renderings OTHER TERMS STANDARD TERMS AND CONDITIONS Copyright © Shive-Hattery April 2022 PARTIES "S-H" or “Shive-Hattery” shall mean Shive-Hattery, Inc. or Shive-Hattery A/E Services, P.C. or Studio951 a Division of Shive- Hattery or EPOCH a Division of Shive-Hattery or Shive-Hattery New Jersey, Inc. or WSM, a Division of Shive-Hattery, Inc. and "CLIENT" shall mean the person or entity executing this Agreement with "S-H." LIMITATION OF LIABILITY AND WAIVER OF CERTAIN DAMAGES The CLIENT agrees, to the fullest extent of the law, to limit the liability of S-H, its officers, directors, shareholders, employees, agents, subconsultants, affiliated companies, and any of them, to the CLIENT and any person or entity claiming by or through the CLIENT, for any and all claims, damages, liabilities, losses, costs, and expenses including reasonable attorneys’ fees, experts’ fees, or any other legal costs , in any way related to the Project or Agreement from any cause(s) to an amount that shall not exceed the compensation received by S-H under the agreement or fifty thousand dollars ($50,000), whichever is greater. The parties intend that this limitation of liability apply to any and all liability or cause of action, claim, theory of recovery, or remedy however alleged or arising, including but not limited to negligence, errors or omissions, strict liability, breach of contract or warranty, express, implied or equitable indemnity and all other claims, which except for the limitation of liability above, the CLIENT waives. Page 4 of 7 Project 217220187P | May 11, 2022 CLIENT hereby releases S-H, its officers, directors, shareholders, employees, agents, subconsultants, affiliated companies, and any of them, and none shall be liable to the CLIENT for consequential, special, exemplary, punitive, indirect or incidental losses or damages, including but not limited to loss of use, loss of product, cost of capital, loss of goodwill, lost revenues or loss of profit, interruption of business, down time costs, loss of data, cost of cover, or governmental penalties or fines. INDEMNIFICATION Subject to the limitation of liability in this Agreement, S-H agrees to the fullest extent permitted by law, to indemnify and hold harmless the CLIENT, its officers, directors, shareholders, employees, contractors, subcontractors and consultants against all claims, damages, liabilities, losses or costs, including reasonable attorneys’ fees, experts’ fees, or other legal costs to the extent caused by S-H’s negligent performance of service under this Agreement and that of its officers, directors, shareholders, and employees. The CLIENT agrees to the fullest extent permitted by law, to indemnify and hold harmless S-H, its officers, directors, shareholders, employees, agents,, subconsultants, and affiliated companies against all damages, liabilities, losses, costs, and expenses including, reasonable attorneys’ fees, expert’s fees, and any other legal costs to the extent caused by the acts or omissions of the CLIENT, its employees, agents, contractors, subcontractors, consultants or anyone for whom the CLIENT is legally liable. HAZARDOUS MATERIALS - INDEMNIFICATION To the fullest extent permitted by law, CLIENT agrees to defend, indemnify, and hold S-H, its officers, directors, shareholders, employees, agents, consultants and affiliated companies, and any of them harmless from and against any and all claims, liabilities, losses, costs, or expenses including reasonable attorney’s fees, experts’ fees and any other legal costs (including without limitation damages to property, injuries or death to persons, fines, or penalties), arising out of, or resulting from the discharge, escape, release, or saturation of smoke, vapors, soot, fumes, acids, alkalies, toxic chemicals, liquids, gases, polychlorinated biphenyl, petroleum contaminants spores, biological toxins, or any other materials, irritants, contaminants, or pollutants in or into the atmosphere, or on, onto, upon, in, or into the surface or subsurface of soil, water, or watercourses, objects, or any tangible or intangible matter, whether sudden or not. STANDARD OF CARE Services provided by S-H under this Agreement will be performed in a manner consistent with that degree of care and skill ordinarily exercised by members of the same profession currently practicing under similar circumstances on projects of similar size, complexity, and geographic location as that of the Project. Nothing in this Agreement is intended to create, nor shall it be construed to create, a fiduciary duty owed by either party to the other party. BETTERMENT The CLIENT recognizes and expects that certain change orders may be required to be issued as the result in whole or part of imprecision, incompleteness, omissions, ambiguities, or inconsistencies in S-H’s drawings, specifications, and other design, bidding or construction documentation furnished by S-H or in other professional services performed or furnished by S-H under this Agreement (herein after in this Betterment section referred to as S-H Documentation). If a required item or component of the Project is omitted from S-H’s Documentation, the CLIENT is responsible for paying all costs required to add such item or component to the extent that such item or component would have been required and included in the original S-H Documentation. In no event will S-H be responsible for costs or expense that provides betterment or upgrades or enhances the value of the Project. RIGHT OF ENTRY The CLIENT shall provide for entry for the employees, agents and subcontractors of S-H and for all necessary equipment. While S-H shall take reasonable precautions to minimize any damage to property, it is understood by the CLIENT that in the normal course of the project some damages may occur, the cost of correction of which is not a part of this Agreement. PAYMENT Unless otherwise provided herein, invoices will be prepared in accordance with S -H's standard invoicing practices then in effect and will be submitted to CLIENT each month and at the completion of the work on the project. Invoices are due and payable upon receipt by the CLIENT. If the CLIENT does not make payment within thirty (30) days after the date the invoice was mailed to the CLIENT, then the amount(s) due S-H shall bear interest due from the date of mailing at the lesser interest rate of 1.5% per month compounded or the maximum interest rate allowed by law. In the event that S-H files or takes any action, or incurs any costs, for the collection of amounts due it from the client, S-H shall be entitled to recover its entire cost for attorney fees and other collection expenses related to the collection of amounts due it under this Agreement. Any failure to comply with this term shall be grounds for a default termination. TERMINATION Either party may terminate this Agreement for convenience or for default by providing written notice to the other party. If the termination is for default, the non-terminating party may cure the default before the effective date of the termination and the Page 5 of 7 Project 217220187P | May 11, 2022 termination for default will not be effective. The termination for convenience and for default, if the default is not cured, shall be effective seven (7) days after receipt of written notice by the non-terminating party. In the event that this Agreement is terminated for the convenience of either party or terminated by S-H for the default of the CLIENT, then S-H shall be paid for services performed to the termination effective date, including reimbursable expenses due, and termination expenses attributable to th e termination. In the event the CLIENT terminates the Agreement for the default of S-H and S-H does not cure the default, then S-H shall be paid for services performed to the termination notice date, including reimbursable expenses due, but shall not be paid for services performed after the termination notice date and shall not be paid termination expenses. Termination expenses shall include expenses reasonably incurred by S-H in connection with the termination of the Agreement or services, including, but not limited to, closing out Project records, termination of subconsultants and other persons or entities whose services were retained for the Project, and all other expenses directly resulting from the termination. INFORMATION PROVIDED BY OTHERS S-H shall indicate to the CLIENT the information needed for rendering of services hereunder. The CLIENT shall provide to S-H such information, including electronic media, as is available to the CLIENT and the CLIENT's consultants and contractors, and S- H shall be entitled to rely upon the accuracy and completeness thereof. The CLIENT recognizes that it is difficult for S-H to assure the accuracy, completeness and sufficiency of such client-furnished information, either because it is provided by others or because of errors or omissions which may have occurred in assembling the information the CLIENT is providing. Accordingly, the CLIENT agrees, to the fullest extent permitted by law, to indemnify and hold harmless S-H, its officers, directors, shareholders, employees, agents, subconsultants and affiliated companies, and any of them, from and against any and all claims, liabilities, losses, costs , expenses (including reasonable attorneys’ fees, experts’ fees, and any other legal costs) for injury or loss arising or allegedly arising from errors, omissions or inaccuracies in documents or other information provided by the CLIENT. UNDERGROUND UTILITIES Information for location of underground utilities may come from the CLIENT, third parties, and/or research performed by S-H or its subcontractors. S-H will use the standard of care defined in this Agreement in providing this service. The information that S-H must rely on from various utilities and other records may be inaccurate or incomplete. Therefore, the CLIENT agrees, to the fullest extent permitted by law, to indemnify and hold harmless S-H, its officers, directors, shareholders, employees agents, subconsultants, affiliated companies, and any of them for all claims, losses, costs and damages arising out of the location of underground utilities provided or any information related to underground utilities by S-H under this Agreement. CONTRACTOR MATTERS CLIENT agrees that S-H shall not be responsible for the acts or omissions of the CLIENT’s contractor, or subcontractors, their employees, agents, consultants, suppliers or arising from contractor’s or subcontractors’ work, their employees, agents, consultants, suppliers or other entities that are responsible for performing work that is not in conformance with the construction Contract Documents, if any, prepared by S-H under this Agreement. S-H shall not have responsibility for means, methods, techniques, sequences, and progress of construction of the contractor, subcontractors, agents, employees, agents, consultants, or other entities. In addition, CLIENT agrees that S-H is not responsible for safety at the project site and that safety during construction is for the CLIENT to address in the contract between the CLIENT and contractor. SHOP DRAWING REVIEW If, as part of this Agreement S-H reviews and approves Contractor submittals, such as shop drawings, product data, samples and other data, as required by S-H, these reviews and approvals shall be only for the limited purpose of checking for conformance with the design concept and the information expressed in the contract documents. This review shall not include review of the accuracy or completeness of details, such as quantities, dimensions, weights or gauges, fabrication processes, construction means or methods, coordination of the work with other trades or construction safety precautions, all of which are the sole responsibil ity of the Contractor. S-H's review shall be conducted with reasonable promptness while allowing sufficient time in S-H's judgment to permit adequate review. Review of a specific item shall not indicate that S -H has reviewed the entire assembly of which the item is a component. S-H shall not be responsible for any deviations from the contract documents not brought to the attention of S -H in writing by the Contractor. S-H shall not be required to review partial submissions or those for which submissions of correlated items have not been received. OPINIONS OF PROBABLE COST If, as part of this Agreement S-H is providing opinions of probable construction cost, the CLIENT understands that S-H has no control over costs or the price of labor, equipment or materials, or over the Contractor's method of pricing, and that S-H's opinions of probable construction costs are to be made on the basis of S-H's qualifications and experience. S-H makes no warranty, expressed or implied, as to the accuracy of such opinions as compared to bid or actual c osts. CONSTRUCTION OBSERVATION If, as part of this Agreement S-H is providing construction observation services, S-H shall visit the project at appropriate intervals during construction to become generally familiar with the progress and quality of the contractors' work and to determine if the work is proceeding in general accordance with the Contract Documents. Unless otherwise specified in the Agreement, the CLIENT has not retained S-H to make detailed inspections or to provide exhaustive or continuous project review and observation services. S- H does not guarantee the performance of, and shall have no responsibility for, the acts or omissions of any contractor, its subcontractors, employees, agents, consultants, suppliers or any other entities furnishing materials or performing any work on the Page 6 of 7 Project 217220187P | May 11, 2022 project. S-H shall advise the CLIENT if S-H observes that the contractor is not performing in general conformance of Contract Documents. CLIENT shall determine if work of contractor should be stopped to resolve any problems. OTHER SERVICES The CLIENT may direct S-H to provide other services including, but not limited to, any additional services identified in S -H's proposal. If S-H agrees to provide these services, then the schedule shall be reasonably adjusted to allow S-H to provide these services. Compensation for such services shall be at S-H's Standard Hourly Fee Schedule in effect at the time the work is performed unless there is a written Amendment to Agreement that contains an alternative compensation provision. OWNERSHIP & REUSE OF INSTRUMENTS OF SERVICE All reports, plans, specifications, field data and notes and other documents, including all documents on electronic media, prepared by S-H as instruments of service shall remain the property of S-H. The CLIENT shall not reuse or make any modifications to the plans and specifications without the prior written authorization of S-H. The CLIENT agrees, to the fullest extent permitted by law, to defend, indemnify and hold harmless S-H its officers, directors, shareholders, employees, agents, subconsultants and affiliated companies, and any of them from any and all claims, losses, costs or damages of any nature whatsoever arising out of, result ing from or in any way related to any unauthorized reuse or modifications of the construction documents by the CLIENT or any person or entity that acquires or obtains the plans and specifications from or through the CLIENT without the written authorization of S-H. DISPUTE RESOLUTION If a dispute arises between S-H and CLIENT, the executives of the parties having authority to resolve the dispute shall meet within thirty (30) days of the notification of the dispute to resolve the dispute. If the dispute is not resolved within such thirty (30) day time period, CLIENT and S-H agree to submit to non-binding mediation prior to commencement of any litigation and that non-binding mediation is a precondition to any litigation. Any costs incurred directly for a mediator, shall be shared equally between t he parties involved in the mediation. EXCUSABLE EVENTS S-H shall not be responsible or liable to CLIENT or CLIENT’s contractors, consultants, or other agents for any of the following events or circumstances, or the resulting delay in S-H’s services, additional costs and expenses in S-H’s performance of its services, or other effects in S-H’s services, stemming in whole or part from such events and circumstances (collectively, “Excusable Events” or, singularly, an “Excusable Event”): a change in law, building code or applicable standards; actions or inactions by a governmental authority; the presence or encounter of hazardous or toxic materials on the Project; war (declare d or undeclared) or other armed conflict; terrorism; sabotage; vandalism; riot or other civil disturbance; blockad e or embargos; explosion; abnormal weather; unanticipated or unknown site conditions; epidemic or pandemic (including but not limited to COVID-19), delays or other effects arising from government-mandated or government-recommended quarantines, closure of business, access, or travel; strike or labor dispute, lockout, work slowdown or stoppage; accident; act of God; failure of any governmental or other regulatory authority to act in a timely manner; acts or omissions by CLIENT or by any CLIENT’s contractors, consultants or agents of any level on the project (including, without limitation, failure of the CLIENT to furnish timely information or approve or disapprove of S-H's services or work product promptly, delays in the work caused by CLIENT, CLIENT’s suspension, breach or default of this Agreement, or delays caused by faulty performance by the CLIENT or by CLIENT’s contractors, consultants, or agents of any level); or any delays or events outside the reasonable control of S-H. When an Excusable Event occurs, the CLIENT agrees S-H is not responsible for any actual or claimed damages incurred by CLIENT or CLIENT’s contractors, consultants, or agents, S-H shall not be deemed to be in default of this Agreement, and S-H shall be entitled to a change order to equitably increase and extend S-H’s time for performance of its services, as well as equitably increase the contract sum to compensate S-H for its increased labor, expenses, and other costs to perform its services, due to the Excusable Event. ASSIGNMENT Neither party to this Agreement shall transfer, sublet or assign any rights under or interest in this Agreement (including but not limited to monies that are due or monies that may be due) without the prior written consent of the other party. SEVERABILITY, SURVIVAL AND WAIVER Any provision of this Agreement later held to be unenforceable for any reason shall be deemed void, and all remaining provisions shall continue in full force and effect. All obligations arising prior to the termination of this Agreement and all provisions of this Agreement allocating responsibility or liability between the CLIENT and S-H shall survive the completion of the services hereunder and the termination of this Agreement. The failure of a party to insist upon strict compliance of any term hereof shall not constitute a waiver by that party of its rights to insist upon strict compliance at a subsequent date. GOVERNING LAW This Agreement shall be governed pursuant to the laws in the state of the locale of the S-H office address written in this Agreement. EQUAL EMPLOYMENT OPPORTUNITY It is the policy of S-H to provide equal employment opportunities for all. S-H enforces the following acts and amendments as Page 7 of 7 Project 217220187P | May 11, 2022 presented by Federal government or State governments: Title VII of the Civil Rights Act of 1965, Age Discrimination in Employment ACT (ADEA), Americans With Disabilities Act (ADA), Iowa Civil Rights Act of 1965, and Illinois Human Rights Act [ 775ILCS 5]. S-H will not discriminate against any employee or applicant because of race, creed, color, religion, sex, national origin, gender identity, sexual orientation, marital status, ancestry, veteran status, or physical or mental handicap, unless related to performance of the job with or without accommodation. COMPLETE AGREEMENT This Agreement constitutes the entire and integrated agreement between the CLIENT and S-H and supersedes all prior negotiations, representations and agreements, whether oral or written. In the event the CLIENT issues a Purchase Order of whi ch this Agreement becomes a part, or the CLIENT and S-H otherwise execute or enter into a contract into which this Agreement is incorporated, the parties expressly agree that, to the extent the terms of this Agreement conflict with or are otherwise inconsistent with such Purchase Order, or any other contract, this Agreement shall supersede and override the terms of the aforementioned documents, and this Agreement shall solely govern in those regards. ACCEPTANCE Wet signatures, digital signatures, electronic signatures or acceptance communicated by mail or e-mail from one party to another, are deemed acceptable for binding the parties to the Agreement. The CLIENT representative accepting this Agreement warrants that he or she is authorized to enter into this Agreement on behalf of the CLIENT. AGREEMENT This proposal shall become the Agreement for Services when accepted by both parties. Wet signatures, digital signatures, electronic signatures or acceptance communicated by mail or e -mail from one party to another, are deemed acceptable for binding the parties to the Agreement . The Client representative signing this Agreement warrants that he or she is authorized to enter into this Agreement on behalf of the Client. To return a hardcopy of this proposal to us, please return a signed copy to us in the enclosed envelope. Thank you for considering this proposal. We look forward to working with you. If you have any questions concerning this proposal, please contact us. Sincerely, SHIVE-HATTERY, INC. Brian Kane, Project Manager bkane@shive-hattery.com AGREEMENT ACCEPTED AND SERVICES AUTHORIZED TO PROCEED CLIENT: City of South Bend, IN BY: TITLE: (signature) PRINTED NAME: DATE ACCEPTED: Page 1 (Exhibit B – Owner's Responsibilities) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. This is EXHIBIT B, consisting of 3 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated May 27, 2022. Owner’s Responsibilities Article 2 of the Agreement is supplemented to include the following agreement of the parties. B2.01 In addition to other responsibilities of Owner as set forth in this Agreement, Owner shall at its expense: A.Provide Engineer with all criteria and full information as to Owner’s requirements for the Project, including design objectives and constraints, space, capacity and performance requirements, flexibility, and expandability, and any budgetary limitations; and furnish copies of all design and construction standards which Owner will require to be included in the Drawings and Specifications; and furnish copies of Owner’s standard forms, conditions, and related documents for Engineer to include in the Bidding Documents, when applicable. B.Furnish to Engineer any other available information pertinent to the Project including reports and data relative to previous designs, or investigation at or adjacent to the Site. C.Following Engineer’s assessment of initially-available Project information and data and upon Engineer’s request, furnish or otherwise make available such additional Project related information and data as is reasonably required to enable Engineer to complete its Basic and Additional Services. Such additional information or data would generally include the following: 1.Property descriptions. 2.Zoning, deed, and other land use restrictions. 3.Property, boundary, easement, right-of-way, and other special surveys or data, including establishing relevant reference points. 4.Explorations and tests of subsurface conditions at or contiguous to the Site, drawings of physical conditions relating to existing surface or subsurface structures at the Site, or hydrographic surveys, with appropriate professional interpretation thereof. 5.Environmental assessments, audits, investigations, and impact statements, and other relevant environmental or cultural studies as to the Project, the Site, and adjacent areas. 6.Data or consultations as required for the Project but not otherwise identified in the Agreement or the Exhibits thereto. D.Give prompt written notice to Engineer whenever Owner observes or otherwise becomes aware of the presence at the Site of any Constituent of Concern, or of any other development that affects the scope or time of performance of Engineer’s services, or any defect or nonconformance in Engineer’s services, the Work, or in the performance of any Contractor. Page 2 (Exhibit B – Owner's Responsibilities) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. E.Authorize Engineer to provide Additional Services as set forth in Part 2 of Exhibit A of the Agreement as required. F.Arrange for safe access to and make all provisions for Engineer to enter upon public and private property as required for Engineer to perform services under the Agreement. G.Examine all alternate solutions, studies, reports, sketches, Drawings, Specifications, proposals, and other documents presented by Engineer (including obtaining advice of an attorney, insurance counselor, and other advisors or consultants as Owner deems appropriate with respect to such examination) and render in writing timely decisions pertaining thereto. H.Provide reviews, approvals, and permits from all governmental authorities having jurisdiction to approve all phases of the Project designed or specified by Engineer and such reviews, approvals, and consents from others as may be necessary for completion of each phase of the Project. I.Recognizing and acknowledging that Engineer's services and expertise do not include the following services, provide, as required for the Project: 1.Accounting, bond and financial advisory, independent cost estimating, and insurance counseling services. 2.Legal services with regard to issues pertaining to the Project as Owner requires, Contractor raises, or Engineer reasonably requests. 3.Such auditing services as Owner requires to ascertain how or for what purpose Contractor has used the moneys paid. J.Place and pay for advertisement for Bids in appropriate publications. K.Advise Engineer of the identity and scope of services of any independent consultants employed by Owner to perform or furnish services in regard to the Project, including, but not limited to, cost estimating, project peer review, value engineering, and constructibility review. L.Furnish to Engineer data as to Owner’s anticipated costs for services to be provided by others (including, but not limited to, accounting, bond and financial, independent cost estimating, insurance counseling, and legal advice) for Owner so that Engineer may assist Owner in collating the various cost categories which comprise Total Project Costs. M.If Owner designates a construction manager or an individual or entity other than, or in addition to, Engineer to represent Owner at the Site, define and set forth as an attachment to this Exhibit B the duties, responsibilities, and limitations of authority of such other party and the relation thereof to the duties, responsibilities, and authority of Engineer. N.If more than one prime contract is to be awarded for the Work designed or specified by Engineer, designate a person or entity to have authority and responsibility for coordinating the activities among the various prime Contractors, and define and set forth the duties, responsibilities, and limitations of authority of such individual or entity and the relation thereof to the duties, Page 3 (Exhibit B – Owner's Responsibilities) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. responsibilities, and authority of Engineer as an attachment to this Exhibit B that is to be mutually agreed upon and made a part of this Agreement before such services begin. O.Attend the pre-bid conference, bid opening, pre-construction conferences, construction progress and other job related meetings, and Substantial Completion and final payment visits to the Project. P.Provide the services of an independent testing laboratory to perform all inspections, tests, and approvals of samples, materials, and equipment required by the Contract Documents, or to evaluate the performance of materials, equipment, and facilities of Owner, prior to their incorporation into the Work with appropriate professional interpretation thereof. Q.Provide Engineer with the findings and reports generated by the entities providing services to Owner pursuant to this paragraph. R.Inform Engineer in writing of any specific requirements of safety or security programs that are applicable to Engineer, as a visitor to the Site. S.Perform or provide the following additional services: [Here list any such additional services]. Page 1 Exhibit C –Compensation Packet BC-1: Basic Services (other than RPR) – Lump Sum Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. SUGGESTED FORMAT (for use with E-500, 2008 Edition) This is EXHIBIT C, consisting of 2 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated May 27, 2022. Payments to Engineer for Services and Reimbursable Expenses COMPENSATION PACKET BC-1: Basic Services – Lump Sum Article 2 of the Agreement is supplemented to include the following agreement of the parties: ARTICLE 2 – OWNER’S RESPONSIBILITIES C2.01 Compensation for Basic Services (other than Resident Project Representative) – Lump Sum Method of Payment A.Owner shall pay Engineer for Basic Services set forth in Exhibit A, except for services of Engineer’s Resident Project Representative, if any, as follows: 1.A Lump Sum amount of $ 62,341 based on the following estimated distribution of compensation: a.Study and Report Phase $ 15,806 b.Preliminary Design Phase $ 46,535 c.Final Design Phase $ -- d.Bidding and Negotiating Phase $ -- e.Construction Phase $ -- f.Post-Construction Phase $ -- 2.Engineer may alter the distribution of compensation between individual phases noted herein to be consistent with services actually rendered, but shall not exceed the total Lump Sum amount unless approved in writing by the Owner. 3.The Lump Sum includes compensation for Engineer’s services and services of Engineer’s Consultants, if any. Appropriate amounts have been incorporated in the Lump Sum to account for labor, overhead, profit, and Reimbursable Expenses. 4.The portion of the Lump Sum amount billed for Engineer’s services will be based upon Engineer’s estimate of the percentage of the total services actually completed during the billing period. Page 2 Exhibit C –Compensation Packet BC-1: Basic Services (other than RPR) – Lump Sum Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. B.Period of Service: The compensation amount stipulated in Compensation Packet BC-1 is conditioned on a period of service not exceeding 2 months. If such period of service is extended, the compensation amount for Engineer's services shall be appropriately adjusted. Page 1 Exhibit C – Compensation Packet AS-3: Additional Services – Salary Costs Times a Factor Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. COMPENSATION PACKET AS-1: Additional Services – Standard Hourly Rates Article 2 of the Agreement is supplmented to include the following agreement of the parties: C2.05 Compensation for Additional Services – Standard Hourly Rates Method of Payment A.Owner shall pay Engineer for Additional Services, if any, as follows: 1.General: For services of Engineer’s personnel engaged directly on the Project pursuant to Paragraph A2.01 or A2.02 of Exhibit A, except for services as a consultant or witness under Paragraph A2.01.A.20, (which if needed shall be separately negotiated based on the nature of the required consultation or testimony) an amount equal to the cumulative hours charged to the Project by each class of Engineer’s personnel times Standard Hourly Rates for each applicable billing class for all Additional Services performed on the Project, plus related Reimbursable Expenses and Engineer’s Consultant’s charges, if any. B.Compensation For Reimbursable Expenses: 1.For those Reimbursable Expenses that are not accounted for in the compensation for Basic Services under Paragraph C2.01 and are directly related to the provision of Additional Services, Owner shall pay Engineer at the rates set forth in Appendix 1 to this Exhibit C. 2.Reimbursable Expenses include the following categories: transportation and subsistence incidental thereto; providing and maintaining field office facilities including furnishings and utilities; toll telephone calls and mobile phone charges; reproduction of reports, Drawings, Specifications, Bidding Documents, and similar Project-related items in addition to those required under Exhibit A. In addition, if authorized in advance by Owner, Reimbursable Expenses will also include expenses incurred for the use of highly specialized equipment. 3.The amounts payable to Engineer for Reimbursable Expenses, if any, will be the Additional Services-related internal expenses actually incurred or allocated by Engineer, plus all invoiced external Reimbursable Expenses allocable to such Additional Services, the latter multiplied by a factor of 0.10 . 4.The Reimbursable Expenses Schedule will be adjusted annually (as of January 1 ) to reflect equitable changes in the compensation payable to Engineer. C.Other Provisions Concerning Payment For Additional Services: 1.Whenever Engineer is entitled to compensation for the charges of Engineer’s Consultants, those charges shall be the amounts billed by Engineer’s Consultants to Engineer times a factor of 0.10 . Page 2 Exhibit C – Compensation Packet AS-3: Additional Services – Salary Costs Times a Factor Method of Payment EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. 2.Factors: The external Reimbursable Expenses and Engineer’s Consultant’s Factors include Engineer’s overhead and profit associated with Engineer’s responsibility for the administration of such services and costs. 3.To the extent necessary to verify Engineer’s charges and upon Owner’s timely request, Engineer shall make copies of such records available to Owner at cost. Page 1 Exhibit C – Appendix 1: Reimbursable Expenses Schedule EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. This is Appendix 1 to EXHIBIT C, consisting of 1 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated May 27, 2022. Reimbursable Expenses Schedule Current agreements for engineering services stipulate that the Reimbursable Expenses are subject to review and adjustment per Exhibit C. Reimbursable expenses for services performed on the date of the Agreement are: Reproducible Copies (Paper) $0.30 /sq. ft. Page 1 (Exhibit D - Resident Project Representative) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. This is Appendix 2 to EXHIBIT C, consisting of 1 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated May 27, 2022. Standard Hourly Rates Schedule A.Standard Hourly Rates: 1.Standard Hourly Rates are set forth in this Appendix 2 to this Exhibit C and include salaries and wages paid to personnel in each billing class plus the cost of customary and statutory benefits, general and administrative overhead, non-project operating costs, and operating margin or profit. 2.The Standard Hourly Rates apply only as specified in Article C2. B.Schedule: PROFESSIONAL STAFF: TECHNICAL STAFF: Grade 1 $ 96.00 Grade 1 $ 67.00 Grade 2 $115.00 Grade 2 $ 83.00 Grade 3 $128.00 Grade 3 $ 94.00 Grade 4 $143.00 Grade 4 $101.00 Grade 5 $159.00 Grade 5 $114.00 Grade 6 $172.00 Grade 6 $130.00 Grade 7 $187.00 Grade 7 $146.00 Grade 8 $205.00 Grade 9 $223.00 ADMIN STAFF: $ 66.00 Page 1 (Exhibit F – Construction Cost Limit) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. This is EXHIBIT E, consisting of 2 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated May 27, 2022. NOTICE OF ACCEPTABILITY OF WORK PROJECT: OWNER: CONTRACTOR: OWNER’S CONSTRUCTION CONTRACT IDENTIFICATION: EFFECTIVE DATE OF THE CONSTRUCTION CONTRACT: ENGINEER: NOTICE DATE: To: ___________________ Owner And To: ___________________ Contractor From: ___________________ Engineer The Engineer hereby gives notice to the above Owner and Contractor that the completed Work furnished and performed by Contractor under the above Contract is acceptable, expressly subject to the provisions of the related Contract Documents, the Agreement between Owner and Engineer for Professional Services dated , , and the terms and conditions set forth in this Notice. By: Title: Dated: CONDITIONS OF NOTICE OF ACCEPTABILITY OF WORK Page 2 (Exhibit F – Construction Cost Limit) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. The Notice of Acceptability of Work (“Notice”) is expressly made subject to the following terms and conditions to which all those who receive said Notice and rely thereon agree: 1.This Notice is given with the skill and care ordinarily used by members of the engineering profession practicing under similar conditions at the same time and in the same locality. 2.This Notice reflects and is an expression of the professional judgment of Engineer. 3.This Notice is given as to the best of Engineer’s knowledge, information, and belief as of the Notice Date. 4.This Notice is based entirely on and expressly limited by the scope of services Engineer has been employed by Owner to perform or furnish during construction of the Project (including observation of the Contractor’s work) under Engineer’s Agreement with Owner and under the Construction Contract referred to in this Notice, and applies only to facts that are within Engineer’s knowledge or could reasonably have been ascertained by Engineer as a result of carrying out the responsibilities specifically assigned to Engineer under such Agreement and Construction Contract. 5.This Notice is not a guarantee or warranty of Contractor’s performance under the Construction Contract referred to in this Notice, nor an assumption of responsibility for any failure of Contractor to furnish and perform the Work thereunder in accordance with the Contract Documents. Page 1 (Exhibit G - Insurance) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. This is EXHIBIT G, consisting of 3 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated May 27, 2022. Insurance Paragraph 6.04 of the Agreement is supplemented to include the following agreement of the parties. G6.04 Insurance A.The limits of liability for the insurance required by Paragraph 6.04.A and 6.04.B of the Agreement are as follows: 1.By Engineer: a.See page 3 of Exhibit G. 2.By Owner: a.The City of South Bend is a municipal corporation organized under the laws of the State of Indiana, and is self-insured under provisions of Indiana statutes and local ordinance. Specifically, the City of South Bend maintains blanket insurance coverage over real and personal property, and is covered by a non-reverting insurance premium and liability reserve fund created by the City of South Bend, Ordinance #6657-79, pursuant to Indiana Code 34-13-3-4, as amended from time to time. Under said statute, the City’s liability is limited to: 1)Seven hundred thousand dollars ($700,000) for a cause of action that accrues on or after January 1, 2008; and 2)Five million dollars ($5,000,000) for injury to or death of all persons in that occurrence,; and 3)A governmental entity or an employee of a governmental entity acting within the scope of employment is not liable for punitive damages. B.Additional Insureds: 1.The following persons or entities are to be listed on Owner’s general liability policies of insurance as additional insureds, and on any applicable property insurance policy as loss payees, as provided in Paragraph 6.04.B: Page 2 (Exhibit G - Insurance) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. a. Engineer b. Engineer’s Consultant c. Engineer’s Consultant 2.During the term of this Agreement the Engineer shall notify Owner of any other Consultant to be listed as an additional insured on Owner’s general liability and property policies of insurance. 3.The Owner shall be listed on Engineer’s general liability policy as provided in Paragraph 6.04.A. SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. INSURER(S) AFFORDING COVERAGE INSURER F : INSURER E : INSURER D : INSURER C : INSURER B : INSURER A : NAIC # NAME: CONTACT (A/C, No): FAX E-MAIL ADDRESS: PRODUCER (A/C, No, Ext): PHONE INSURED REVISION NUMBER:CERTIFICATE NUMBER:COVERAGES IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. OTHER: (Per accident) (Ea accident) $ $ N / A SUBR WVD ADDL INSD THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. $ $ $ $PROPERTY DAMAGE BODILY INJURY (Per accident) BODILY INJURY (Per person) COMBINED SINGLE LIMIT AUTOS ONLY AUTOSAUTOS ONLY NON-OWNED SCHEDULEDOWNED ANY AUTO AUTOMOBILE LIABILITY Y / N WORKERS COMPENSATION AND EMPLOYERS' LIABILITY OFFICER/MEMBER EXCLUDED? (Mandatory in NH) DESCRIPTION OF OPERATIONS below If yes, describe under ANY PROPRIETOR/PARTNER/EXECUTIVE $ $ $ E.L. DISEASE - POLICY LIMIT E.L. DISEASE - EA EMPLOYEE E.L. EACH ACCIDENT ER OTH- STATUTE PER LIMITS(MM/DD/YYYY) POLICY EXP (MM/DD/YYYY) POLICY EFF POLICY NUMBERTYPE OF INSURANCELTR INSR DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) EXCESS LIAB UMBRELLA LIAB $EACH OCCURRENCE $AGGREGATE $ OCCUR CLAIMS-MADE DED RETENTION $ $PRODUCTS - COMP/OP AGG $GENERAL AGGREGATE $PERSONAL & ADV INJURY $MED EXP (Any one person) $EACH OCCURRENCE DAMAGE TO RENTED $PREMISES (Ea occurrence) COMMERCIAL GENERAL LIABILITY CLAIMS-MADE OCCUR GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PRO- JECT LOC CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) CANCELLATION AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. CERTIFICATE HOLDER The ACORD name and logo are registered marks of ACORD HIRED AUTOS ONLY 319-896-7670 X X 10,000,000 10/01/21 BAP020393006 C Aggregate Per Claim WC020392806 10/01/21 10/01/22 X 10,000 msunnes@holmesmurphy.com 1,000,000 X 37885 27855 25674 27855 63357468 63357468 10,000 09/28/2021 X 1,000,000 10/01/21 To Whom it May Concern *For Informational Purposes Only* X X 1,000,000 1,000,000 GLO020392906 XL SPECIALTY INS CO Zurich American Insurance Company TRAVELERS PROP CAS CO OF AMER Zurich American Insurance Company of IL 10/01/22 10,000,000 300,000 Cedar Rapids, IA 52401 X N (Claims-Made Policy) South Bend, IN 46601 Professional Liability 10/01/21 D X Shive-Hattery, Inc. 10,000,000 5,000,000 A 321 S. Main Street, Suite 103 2,000,000 10/01/22 MSunnescr B 201 First Street SE, Suite 700 DPR9983713 10/01/22 ZUP6S170317 1,000,000 2,000,000 1,000,000 1-800-300-0325 X A Holmes Murphy & Assoc - CR 10/01/21 10/01/22 X Misty Sunnes Page 1 (Exhibit J - Special Provisions) EJCDC E-500 Agreement Between Owner and Engineer for Professional Services. Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. This is EXHIBIT I, consisting of 1 pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated May 27, 2022. Limitations of Liability Paragraph 6.10 of the Agreement is supplemented to include the following agreement of the parties: A. Limitation of Engineer’s Liability 1.Engineer’s Liability Limited to Amount of Insurance Proceeds: Engineer shall procure and maintain insurance as required by and set forth in Exhibit G to this Agreement. Notwithstanding any other provision of this Agreement, and to the fullest extent permitted by law, the total liability, in the aggregate, of Engineer and Engineer’s officers, directors, members, partners, agents, employees, and Consultants to Owner and anyone claiming by, through, or under Owner for any and all claims, losses, costs, or damages whatsoever arising out of, resulting from, or in any way related to the Project or the Agreement from any cause or causes, including but not limited to the negligence, professional errors or omissions, strict liability, breach of contract, indemnity obligations, or warranty express or implied, of Engineer or Engineer’s officers, directors, members, partners, agents, employees, or Consultantss (hereafter “Owner’s Claims”), shall not exceed the total insurance proceeds paid on behalf of or to Engineer by Engineer’s insurers in settlement or satisfaction of Owner’s Claims under the terms and conditions of Engineer’s insurance policies applicable thereto (excluding fees, costs and expenses of investigation, claims adjustment, defense, and appeal). If no such insurance coverage is provided with respect to Owner’s Claims, then the total liability, in the aggregate, of Engineer and Engineer’s officers, directors, members, partners, agents, employees, and Consultants to Owner and anyone claiming by, through, or under Owner for any and all such uninsured Owner’s Claims shall not exceed $_____________ B.Indemnification by Owner: To the fullest extent permitted by law, Owner shall indemnify and hold harmless Engineer and its officers, directors, members, partners, agents, employees, and Consultants from and against any and all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals, and all court, arbitration, or other dispute resolution costs) arising out of or relating to the Project, provided that any such claim, cost, loss, or damage is attributable to bodily injury, sickness, disease, or death or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom, but only to the extent caused by any negligent act or omission of Owner or Owner’s officers, directors, members, partners, agents, employees, consultants, or others retained by or under contract to the Owner with respect to this Agreement or to the Project. BOARD OF PUBLIC WORKS AGENDA ITEM REVIEW REQUEST FORM Date 06/30/2022 Name Zach Hurst Department DPW BPW Date 07/12/2022 Phone Extension 3057 Review and Approval Required Prior to Submittal to Board Diversity Compliance and Inclusion Officer Officer Name BPW Attorney Attorney Name Clara McDaniels, via DFO Dept. Attorney Attorney Name Purchasing Check the Appropriate Item Type – Required for All Submissions Professional Services Agreement Contract Proposal Open Market Contract Amendment/Addendum Special Purchase, QPA Bid Opening Bid Award Req. to Advertise Title Sheet Quote Opening Quote Award Reject Bids/Quotes Proposal Opening C/O & PCA No. PCA Chg. Order, No. Traffic Control Resolution Other: Ease./Encroach Required Information Company or Vendor Name Shive Hattery New Vendor Yes If Yes, Approved by Purchasing No MBE/WBE Contractor MBE WBE Completed E-Verify Form Attached Yes No Project Name Fire Station 8 Replacement Project Number 122-034 Funding Source South Side DA TIF Account No. PR-00017945 Amount $62,341.00 Terms of Contract Fixed Fee for Programming and Schematic Design Purpose/Description PSA to develop site plan and floor plan for new Fire Station 8 For Change Orders Only Amount of Increase Decrease $ ($ ) Previous Amount $ Current Percent of Change: Increase Decrease % ( %) New Amount $ Total Percent of Change: Increase Decrease % ( %) Time Extension Amount: New Completion Date: