Loading...
HomeMy WebLinkAboutConsulting Contract - Shrewsberry & Assoc - Review and Installation of School Zone Flashing Beacons within City of SB1316 COUNTY -CITY BUILDING 227 W.JEFFERSON BOULEVARD SOUTH BEND. INDIANA 46601 -1 830 CITY OF SOUTHBEND BOARD OF PUBLICWORKS April 9, 2019 Jill Palmer Shrewsberry & Associates, LLC 7321 Shadeland Station, Suite 160 Indianapolis, IN 46256 RE: Consulting Contract Dear Ms. Palmer: PHONE 574/235-9251 FAX 574/235-9171 The Board of Public Works, at its meeting held on April 9, 2019, approved the above referenced contract regarding engineering design for the review and installation of school zone flashing beacons within the City of South Bend in the amount not to exceed $79,372, Enclosed please find the original of the contract for your signature. Please sign and return the original agreement to our office and retain a copy for your records. If you have any further questions regarding this matter, please call this office at (574) 235- 9251. Sincerely, Linda M. Martin, Clerk Enclosure GARY A. GILOT GENEVIEVE E. MILLER ELIZABETH A. MARADIK LAURA L. O'SULLIVAN THERESE J. DORAU Version 6-8-2017 LPA - CONSULTING CONTRACT This Contract ("this Contract") is made and entered into effective as of I, I` qJ. , 20_0 ("Effective Date") by and between tl�e Cit of South Bend hdiara, acting by and through its proper officials ("LOCAL PUBLIC AGENCY" or "LPA"), and Shrewsb�erry aft Associates LLC ("the CONSULTANT"), a corporation/limited liability company organized under the laws of the State of Indiana. Des. No.: 1801240 Project Description: School zone flashing beacon RECITALS WHEREAS, the LPA has entered into an agreement to utilize federal monies with the Indiana Department of Transportation ("INDOT") for a transportation or transportation enhancement project ("the Project"), which Project Coordination Contract is herein attached as Attachment 1 and incorporated as reference; and WHEREAS, the LPA wishes to hire the CONSULTANT to provide services toward the Project completion more fully described in Appendix "A" attached hereto ("Services"); WHEREAS, the CONSULTANT has extensive experience, knowledge and expertise relating to these Services; and WHEREAS, the CONSULTANT has expressed a willingness to furnish the Services in connection therewith NOW, THEREFORE, in consideration of the following mutual covenants, the parties hereto mutually covenant and agree as follows: The "Recitals" above are hereby made an integral part and specifically incorporated into this Contract. SECTION I SERVICES BY CONSULTANT. The CONSULTANT will provide the Services and deliverables described in Appendix "A" which is herein attached to and made an integral part of this Contract. SECTION II INFORMATION AND SERVICES TO BE FURNISHED BY THE LPA. The information and services to be furnished by the LPA are set out in Appendix "B" which is herein attached to and made an integral part of this Contract. SECTION III TERM. The term of this Contract shall be from the date of the last signature affixed to this Contract to the completion of the construction contract which is estimated to be 9/1/22. A schedule for completion of the Services and deliverables is set forth in Appendix "C" which is herein attached to and made an integral part of this Contract. SECTION IV COMPENSATION. The LPA shall pay the CONSULTANT for the Services performed under this Contract as set forth in Appendix "D" which is herein attached to and made an integral part of this Contract. The maximum amount payable under this Contract shall not exceed $ 79�0. SECTION V NOTICE TO PROCEED AND SCHEDULE. The CONSULTANT shall begin the work to be performed under this Contract only upon receipt of the written notice to proceed from the LPA, and shall deliver the work to the LPA in accordance with the schedule contained in Appendix "C" which is herein attached to and made an integral part of this Contract. Version 6-8-2017 SECTION VI GENERAL PROVISIONS 1. Access to Records. The CONSULTANT and any SUB -CONSULTANTS shall maintain all books, documents, papers, correspondence, accounting records and other evidence pertaining to the cost incurred under this Contract, and shall make such materials available at their respective offices at all reasonable times during the period of this Contract and for five (5) years from the date of final payment under the terms of this Contract, for inspection or audit by the LPA, INDOT and/or the Federal Highway Administration ("FHWA") or its authorized representative, and copies thereof shall be furnished free of charge, if requested by the LPA, INDOT, and/or FHWA. The CONSULTANT agrees that, upon request by any agency participating in federally -assisted programs with whom the CONSULTANT has contracted or seeks to contract, the CONSULTANT may release or make available to the agency any working papers from an audit performed by the LPA, INDOT and/or FHWA of the CONSULTANT and its SUB -CONSULTANTS in connection with this Contract, including any books, documents, papers, accounting records and other documentation which support or form the basis for the audit conclusions and judgments. Assignment; Successors. A. The CONSULTANT binds its successors and assignees to all the terms and conditions of this Contract. The CONSULTANT shall not assign or subcontract the whole or any part of this Contract without the LPA's prior written consent, except that the CONSULTANT may assign its right to receive payments to such third parties as the CONSULTANT may desire without the prior written consent of the LPA, provided that the CONSULTANT gives written notice (including evidence of such assignment) to the LPA thirty (30) days in advance of any payment so assigned. The assignment shall cover all unpaid amounts under this Contract and shall not be made to more than one party. B, Any substitution of SUB -CONSULTANTS must first be approved and receive written authorization from the LPA. Any substitution or termination of a Disadvantaged Business Enterprise ("DBE") SUB -CONSULTANT must first be approved and receive written authorization from the LPA and INDOT's Economic Opportunity Division Director. 3. Audit. The CONSULTANT acknowledges that it may be required to submit to an audit of funds paid through this Contract. Any such audit shall be conducted in accordance with 48 CFR part 31 and audit guidelines specified by the State and/or in accordance with audit requirements specified elsewhere in this Contract. 4. Authority to Elrod Consultant. The CONSULTANT warrants that it has the necessary authority to enter into this Contract. The signatory for the CONSULTANT represents that he/she has been duly authorized to execute this Contract on behalf of the CONSULTANT and has obtained all necessary or applicable approval to make this Contract fully binding upon the CONSULTANT when his/her signature is affixed hereto. 5. Certification for Federal -Aid Contracts Lobbying Activities. A. The CONSULTANT certifies, by signing and submitting this Contract, to the best of its knowledge and belief after diligent inquiry, and other than as disclosed in writing to the LPA prior to or contemporaneously with the execution and delivery of this Contract by the CONSULTANT, the CONSULTANT has complied with Section 1352, Title 31, U.S. Code, and specifically, that: No federal appropriated funds have been paid, or will be paid, by or on behalf of the CONSULTANT to any person for influencing or attempting to influence an officer or employee of any federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the awarding of any federal contracts, the making of any federal grant, the making of any federal loan, the 2 Version 6-8-2017 entering into of any cooperative agreement, and the extension, continuation, renewal, amendment, or modification of any federal contract, grant, loan, or cooperative agreement. ii. If any funds other than federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with this federal Contract, grant, loan, or cooperative agreement, the undersigned shall complete and submit Standard Form-LLL, "Disclosure Form to Report Lobbying," in accordance with its instructions. B„ The CONSULTANT also agrees by signing this Contract that it shall require that the language of this certification be included in all lower tier subcontracts, which exceed $100,000, and that all such sub -recipients shall certify and disclose accordingly. Any person who fails to sign or file this required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each failure. 6. Changes in '"i'llork. The CONSULTANT shall not commence any additional work or change the scope of the work until authorized in writing by the LPA. The CONSULTANT shall make no claim for additional compensation or time in the absence of a prior written approval and amendment executed by all signatories hereto. This Contract may be amended, supplemented or modified only by a written document executed in the same manner as this Contract. The CONSULTANT acknowledges that no claim for additional compensation or time may be made by implication, oral agreements, actions, inaction, or course of conduct. Conn Iiance with Laws. A. The CONSULTANT shall comply with all applicable federal, state and local laws, rules, regulations and ordinances, and all provisions required thereby to be included herein are hereby incorporated by reference. If the CONSULTANT violates such rules, laws, regulations and ordinances, the CONSULTANT shall assume full responsibility for such violations and shall bear any and all costs attributable to the original performance of any correction of such acts. The enactment of any state or federal statute, or the promulgation of regulations thereunder, after execution of this Contract, shall be reviewed by the LPA and the CONSULTANT to determine whether formal modifications are required to the provisions of this Contract. B. The CONSULTANT represents to the LPA that, to the best of the CONSULTANT'S knowledge and belief after diligent inquiry and other than as disclosed in writing to the LPA prior to or contemporaneously with the execution and delivery of this Contract by the CONSULTANT: State of Indiana Actions. The CONSULTANT has no current or outstanding criminal, civil, or enforcement actions initiated by the State of Indiana pending, and agrees that it will immediately notify the LPA of any such actions. During the term of such actions, CONSULTANT agrees that the LPA may delay, withhold, or deny work under any supplement or amendment, change order or other contractual device issued pursuant to this Contract. ii. Professional Licensing Standards. The CONSULTANT, its employees and SUBCONSULTANTS have complied with and shall continue to comply with all applicable licensing standards, certification standards, accrediting standards and any other laws, rules or regulations governing services to be provided by the CONSULTANT pursuant to this Contract. Version 6-8-2017 iii. Work Specific Standards. The CONSULTANT and its SUB -CONSULTANTS, if any, have obtained, will obtain and/or will maintain all required permits, licenses, registrations and approvals, as well as comply with all health, safety, and environmental statutes, rules, or regulations in the performance of work activities for the LPA. iv. Secretary of State Registration. If the CONSULTANT is an entity described in IC Title 23, it is properly registered and owes no outstanding reports with the Indiana Secretary of State. Debarment and Suspension of CONSULTANT. Neither the CONSULTANT nor its principals are presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from entering into this Contract by any federal agency or by any department, agency or political subdivision of the State and will immediately notify the LPA of any such actions. The term "principal" for purposes of this Contract means an officer, director, owner, partner, key employee, or other person with primary management or supervisory responsibilities, or a person who has a critical influence on or substantive control over the operations of the CONSULTANT or who has managerial or supervisory responsibilities for the Services. v. Debarment and Suspension of any SUB -CONSULTANTS. The CONSULTANT's SUB - CONSULTANTS are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from entering into this Contract by any federal agency or by any department, agency or political subdivision of the State. The CONSULTANT shall be solely responsible for any recoupment, penalties or costs that might arise from the use of a suspended or debarred SUBCONSULTANT. The CONSULTANT shall immediately notify the LPA and INDOT if any SUB -CONSULTANT becomes debarred or suspended, and shall, at the LPA's request, take all steps required by the LPA to terminate its contractual relationship with the SUB -CONSULTANT for work to be performed under this Contract. C. Violations. In addition to any other remedies at law or in equity, upon CONSULTANT'S violation of any of Section 7(A) through 7(B), the LPA may, at its sole discretion, do any one or more of the following: terminate this Contract; or delay, withhold, or deny work under any supplement or amendment, change order or other contractual device issued pursuant to this Contract. D. Disputes. If a dispute exists as to the CONSULTANT's liability or guilt in any action initiated by the LPA, and the LPA decides to delay, withhold, or deny work to the CONSULTANT, the CONSULTANT may request that it be allowed to continue, or receive work, without delay. The CONSULTANT must submit, in writing, a request for review to the LPA. A determination by the LPA under this Section 7.1) shall be final and binding on the parties and not subject to administrative review. Any payments the LPA may delay, withhold, deny, or apply under this section shall not be subject to penalty or interest under IC 5-17-5. 8. Conditi2n of Payment. The CONSULTANT must perform all Services under this Contract to the LPA's reasonable satisfaction, as determined at the discretion of the LPA and in accordance with all applicable federal, state, local laws, ordinances, rules, and regulations. The LPA will not pay for work not performed to the LPA's reasonable satisfaction, inconsistent with this Contract or performed in violation of federal, state, or local law (collectively, "deficiencies") until all deficiencies are remedied in a timely manner. Version 6-8-2017 9. Confidentiality of LPA Information. A. The CONSULTANT understands and agrees that data, materials, and information disclosed to the CONSULTANT may contain confidential and protected information. Therefore, the CONSULTANT covenants that data, material, and information gathered, based upon or disclosed to the CONSULTANT for the purpose of this Contract, will not be disclosed to others or discussed with third parties without the LPA's prior written consent. B„ The parties acknowledge that the Services to be performed by the CONSULTANT for the LPA under this Contract may require or allow access to data, materials, and information containing Social Security numbers and maintained by the LPA in its computer system or other records. In addition to the covenant made above in this section and pursuant to 10 IAC 5-3-1(4), the CONSULTANT and the LPA agree to comply with the provisions of IC 4-1-10 and IC 4-1-11. If any Social Security number(s) is/are disclosed by the CONSULTANT, the CONSULTANT agrees to pay the cost of the notice of disclosure of a breach of the security of the system in addition to any other claims and expenses for which it is liable under the terms of this Contract. 10. 'Delays ,and Extensions. The CONSULTANT agrees that no charges or claim for damages shall be made by it for any minor delays from any cause whatsoever during the progress of any portion of the Services specified in this Contract. Such delays, if any, shall be compensated for by an extension of time for such period as may be determined by the LPA subject to the CONSULTANT's approval, it being understood, however, that permitting the CONSULTANT to proceed to complete any services, or any part of them after the date to which the time of completion may have been extended, shall in no way operate as a waiver on the part of the LPA of any of its rights herein. In the event of substantial delays or extensions, or change of any kind, not caused by the CONSULTANT, which causes a material change in scope, character or complexity of work the CONSULTANT is to perform under this Contract, the LPA at its sole discretion shall determine any adjustments in compensation and in the schedule for completion of the Services. CONSULTANT must notify the LPA in writing of a material change in the work immediately after the CONSULTANT first recognizes the material change. 11. 1 BE Re uirements. A. Notice is hereby given to the CONSULTANT and any SUB -CONSULTANT, and both agree, that failure to carry out the requirements set forth in 49 CFR Sec. 26.13(b) shall constitute a breach of this Contract and, after notification and failure to promptly cure such breach, may result in termination of this Contract or such remedy as INDOT deems appropriate. The referenced section requires the following assurance to be included in all subsequent contracts between the CONSULTANT and any SUB -CONSULTANT: The CONSULTANT, sub recipient or SUB -CONSULTANT shall not discriminate on the basis of race, color, national origin, or sex in the performance of this Contract. The CONSULTANT shall carry out applicable requirements of 49 CFR Part 26 in the award and administration of DOT -assisted contracts. Failure by the CONSULTANT to carry out these requirements is a material breach of this Contract, which may result in the termination of this Contract or such other remedy, as INDOT, as the recipient, deems appropriate. B. The CONSULTANT shall make good faith efforts to achieve the DBE percentage goal that may be included as part of this Contract with the approved DBE SUB -CONSULTANTS identified on its Affirmative Action Certification submitted with its Letter of Interest, or with approved amendments. Any changes to a DBE firm listed in the Affirmative Action Certification must be requested in writing and receive prior approval by the LPA and INDOT's Economic Opportunity Division Director. After this Contract is completed and if a DBE SUB -CONSULTANT has performed services thereon, the CONSULTANT must complete, and return, a Disadvantaged Business Enterprise Utilization Affidavit ("DBE-3 Form") to INDOT's Economic Opportunity Version 6-8-2017 Division Director. The DBE-3 Form requires certification by the CONSULTANT AND DBE SUB -CONSULTANT that the committed contract amounts have been paid and received. 12. Non -Discrimination. A. Pursuant to I.C. 22-9-1-10, the Civil Rights Act of 1964, and the Americans with Disabilities Act, the CONSULTANT shall not discriminate against any employee or applicant for employment, to be employed in the performance of work under this Contract, with respect to hire, tenure, terms, conditions or privileges of employment or any matter directly or indirectly related to employment, because of race, color, religion, sex, disability, national origin, ancestry or status as a veteran. Breach of this covenant may be regarded as a material breach of this Contract. Acceptance of this Contract also signifies compliance with applicable federal laws, regulations, and executive orders prohibiting discrimination in the provision of services based on race, color, national origin, age, sex, disability or status as a veteran. B The CONSULTANT understands that the LPA is a recipient of federal funds. Pursuant to that understanding, the CONSULTANT agrees that if the CONSULTANT employs fifty (50) or more employees and does at least $50,000.00 worth of business with the State and is not exempt, the CONSULTANT will comply with the affirmative action reporting requirements of 41 CFR 60-1.7. The CONSULTANT shall comply with Section 202 of executive order 11246, as amended, 41 CFR 60-250, and 41 CFR 60-741, as amended, which are incorporated herein by specific reference. Breach of this covenant may be regarded as a material breach of Contract. It is the policy of INDOT to assure full compliance with Title VI of the Civil Rights Act of 1964, the Americans with Disabilities Act and Section 504 of the Vocational Rehabilitation Act and related statutes and regulations in all programs and activities. Title VI and related statutes require that no person in the United States shall on the grounds of race, color or national origin be excluded from participation in, be denied the benefits of, or be subjected to discrimination under any program or activity receiving Federal financial assistance. (INDOT's Title VI enforcement shall include the following additional grounds: sex, ancestry, age, income status, religion and disability.) C, The CONSULTANT shall not discriminate in its selection and retention of contractors, including without limitation, those services retained for, or incidental to, construction, planning, research, engineering, property management, and fee contracts and other commitments with persons for services and expenses incidental to the acquisitions of right-of-way. D. The CONSULTANT shall not modify the Project in such a manner as to require, on the basis of race, color or national origin, the relocation of any persons. (INDOT's Title VI enforcement will include the following additional grounds; sex, ancestry, age, income status, religion and disability). E. The CONSULTANT shall not modify the Project in such a manner as to deny reasonable access to and use thereof to any persons on the basis of race, color or national origin. (INDOT's Title VI enforcement will include the following additional grounds; sex, ancestry, age, income status, religion and disability.) F. The CONSULTANT shall neither allow discrimination by contractors in their selection and retention of subcontractors, leasors and/or material suppliers, nor allow discrimination by their subcontractors in their selection of subcontractors, leasors or material suppliers, who participate in construction, right-of-way clearance and related projects. Version 6-8-2017 G. The CONSULTANT shall take appropriate actions to correct any deficiency determined by itself and/or the Federal Highway Administration ("FHWA") within a reasonable time period, not to exceed ninety (90) days, in order to implement Title VI compliance in accordance with INDOT's assurances and guidelines. H. During the performance of this Contract, the CONSULTANT, for itself, its assignees and successors in interest (hereinafter referred to as the "CONSULTANT") agrees as follows: (1) Compliance with Regulations: The CONSULTANT shall comply with the Regulation relative to nondiscrimination in Federally -assisted programs of the Department of Transportation (hereinafter, "DOT") Title 49, Code of Federal Regulations, Part 21, as they may be amended from time to time, (hereinafter referred to as the Regulations), which are herein incorporated by reference and made a part of this Contract. (2) Nondiscrimination: The CONSULTANT, with regard to the work performed by it during the Contract, shall not discriminate on the grounds of race, color, or national origin in the selection and retention of subcontractors, including procurements of materials and leases of equipment. The CONSULTANT shall not participate either directly or indirectly in the discrimination prohibited by section 21.5 of the Regulations, including employment practices when the contract covers a program set forth in Appendix B of the Regulations. (3) Solicitations for SUBCONSULTANTS, Including Procurements of Materials and Equipment: In all solicitations either by competitive bidding or negotiation made by the CONSULTANT for work to be performed under a subcontract, including procurements of materials or leases of equipment, each potential SUBCONSULTANT or supplier shall be notified by the CONSULTANT of the CONSULTANT'S obligations under this Contract and the Regulations relative to nondiscrimination on the grounds of race, color, or national origin. (4) Information and Reports: The CONSULTANT shall provide all information and reports required by the Regulations or directives issued pursuant thereto, and shall permit access to its books, records, accounts, other sources of information, and its facilities as may be determined by the LPA or INDOT to be pertinent to ascertain compliance with such Regulations, orders and instructions. Where any information required of a CONSULTANT is in the exclusive possession of another who fails or refuses to furnish this information the CONSULTANT shall so certify to the LPA, or INDOT as appropriate, and shall set forth what efforts it has made to obtain the information. (5) Sanctions for Noncompliance: In the event of the CONSULTANT'S noncompliance with the nondiscrimination provisions of this contract, the LPA shall impose such contract sanctions as it or INDOT may detennine to be appropriate, including, but not limited to: (a) withholding of payments to the CONSULTANT under the Contract until the CONSULTANT complies, and/or (b) cancellation, termination or suspension of the Contract, in whole or in part. (6) Incorporation of Provisions: The CONSULTANT shall include the provisions of paragraphs (1) through (6) in every subcontract, including procurements of materials and leases of equipment, unless exempt by the Regulations, or directives issued pursuant thereto. 7 Version 6-8-2017 The CONSULTANT shall take such action with respect to any SUBCONSULTANT procurement as the LPA or INDOT may direct as a means of enforcing such provisions including sanctions for noncompliance: Provided, however, that, in the event a CONSULTANT becomes involved in, or is threatened with, litigation with a SUBCONSULTANT or supplier as a result of such direction, the CONSULTANT may request the LPA to enter into such litigation to protect the interests of the LPA, and, in addition, the CONSULTANT may request the United States to enter into such litigation to protect the interests of the United States. 13. Dire. A. Should any disputes arise with respect to this Contract, the CONSULTANT and the LPA agree to act promptly and in good faith to resolve such disputes in accordance with this Section 13. Time is of the essence in the resolution of disputes. B. The CONSULTANT agrees that the existence of a dispute notwithstanding, it will continue without delay to carry out all of its responsibilities under this Contract that are not affected by the dispute. Should the CONSULTANT fail to continue to perform its responsibilities regarding all non -disputed work, without delay, any additional costs (including reasonable attorneys' fees and expenses) incurred by the LPA or the CONSULTANT as a result of such failure to proceed shall be borne by the CONSULTANT. C. If a party to this Contract is not satisfied with the progress toward resolving a dispute, the party must notify the other party of this dissatisfaction in writing. Upon written notice, the parties have ten (10) business days, unless the parties mutually agree in writing to extend this period, following the written notification to resolve the dispute. If the dispute is not resolved within ten (10) business days, a dissatisfied party may submit the dispute in writing to initiate negotiations to resolve the dispute. The LPA may withhold payments on disputed items pending resolution of the dispute. 14. Dru -F"ree Workplace Certification. A. The CONSULTANT hereby covenants and agrees to make a good faith effort to provide and maintain a drug -free workplace, and that it will give written notice to the LPA within ten (10) days after receiving actual notice that an employee of the CONSULTANT in the State of Indiana has been convicted of a criminal drug violation occurring in the CONSULTANT's workplace. False certification or violation of the certification may result in sanctions including, but not limited to, suspension of Contract payments, termination of this Contract and/or debarment of contracting opportunities with the LPA. B. The CONSULTANT certifies and agrees that it will provide a drug -free workplace by: Publishing and providing to all of its employees a statement notifying their employees that the unlawful manufacture, distribution, dispensing, possession or use of a controlled substance is prohibited in the CONSULTANT's workplace and specifying the actions that will be taken against employees for violations of such prohibition; ii. Establishing a drug -free awareness program to inform its employees of (1) the dangers of drug abuse in the workplace; (2) the CONSULTANT's policy of maintaining a drug -free workplace; (3) any available drug counseling, rehabilitation, and employee assistance programs; and (4) the penalties that may be imposed upon an employee for drug abuse violations occurring in the workplace; 8 Version 6-8-2017 iii„ Notifying all employees in the statement required by subparagraph 14.B.i above that as a condition of continued employment, the employee will (1) abide by the terms of the statement; and (2) notify the CONSULTANT of any criminal drug statute conviction for a violation occurring in the workplace no later than five (5) days after such conviction; iv. Notifying in writing the LPA within ten (10) days after receiving notice from an employee under subdivision 14.B.iii(2) above, or otherwise receiving actual notice of such conviction; V. Within thirty (30) days after receiving notice under subdivision 14.B.iii(2) above of a conviction, imposing the following sanctions or remedial measures on any employee who is convicted of drug abuse violations occurring in the workplace: (1) take appropriate personnel action against the employee, up to and including termination; or (2) require such employee to satisfactorily participate in a drug abuse assistance or rehabilitation program approved for such purposes by a Federal, State or local health, law enforcement, or other appropriate agency; and vi. Making a good faith effort to maintain a drug -free workplace through the implementation of subparagraphs 14.B.i. through 14.B.v. above. 15. E.rn to ment Eligibility Verification. The CONSULTANT affirms under the penalties of perjury that he/she/it does not knowingly employ an unauthorized alien. The CONSULTANT shall enroll in and verify the work eligibility status of all his/her/its newly hired employees through the E-Verify program as defined in IC 22-5-1.7-3. The CONSULTANT is not required to participate should the E-Verify program cease to exist. Additionally, the CONSULTANT is not required to participate if the CONSULTANT is self-employed and does not employ any employees. The CONSULTANT shall not knowingly employ or contract with an unauthorized alien. The CONSULTANT shall not retain an employee or contract with a person that the CONSULTANT subsequently learns is an unauthorized alien. The CONSULTANT shall require his/her/its subcontractors, who perform work under this Contract, to certify to the CONSULTANT that the SUB -CONSULTANT does not knowingly employ or contract with an unauthorized alien and that the SUB -CONSULTANT has enrolled and is participating in the E- Verify program. The CONSULTANT agrees to maintain this certification throughout the duration of the term of a contract with a SUB -CONSULTANT,. The LPA may terminate for default if the CONSULTANT fails to cure a breach of this provision no later than thirty (30) days after being notified by the LPA. 16. force Ca'eure. In the event that either party is unable to perform any of its obligations under this Contract or to enjoy any of its benefits because of fire, natural disaster, acts of God, acts of war, terrorism, civil disorders, decrees of governmental bodies, strikes, lockouts, labor or supply disruptions or similar causes beyond the reasonable control of the affected party (hereinafter referred to as a Force Majeure Event), the party who has been so affected shall immediately give written notice to the other party of the occurrence of the Force Majeure Event (with a description in reasonable detail of the circumstances causing such Event) and shall do everything reasonably possible to resume performance. Upon receipt of such written notice, all obligations under this Contract shall be immediately suspended for as long as such Force Majeure Event continues and provided that the affected party continues to use commercially reasonable efforts to recommence performance whenever and to whatever extent possible without delay. If the period of nonperformance exceeds thirty (30) days from the receipt of written notice of the Force Majeure Event, the party whose ability to perform has not been so affected may, by giving written notice, terminate this Contract. 9 Version 6-8-2017 17. Governing Laws. This Contract shall be construed in accordance with and governed by the laws of the State of Indiana and the suit, if any, must be brought in the State of Indiana. The CONSULTANT consents to the jurisdiction of and to venue in any court of competent jurisdiction in the State of Indiana. 18. Liability. If the CONSULTANT or any of its SUB -CONSULTANTS fail to comply with any federal requirement which results in the LPA's repayment of federal funds to MOT the CONSULTANT shall be responsible to the LPA, for repayment of such costs to the extent such costs are caused by the CONSULTANT and/or its SUB -CONSULTANTS. 19. Indemnification,. The CONSULTANT agrees to indemnify the LPA, and their agents, officials, and employees, and to hold each of them harmless, from claims and suits including court costs, attorney's fees, and other expenses caused by any negligent act, error or omission of, or by any recklessness or willful misconduct by, the CONSULTANT and/or its SUB -CONSULTANTS, if any, under this Contract, provided that if the CONSULTANT is a "contractor" within the meaning of I.C. 8-3-2-12.5, this indemnity obligation shall be limited by and interpreted in accordance with I.C. 8-23-2-12-5. The LPA shall not provide such indemnification to the CONSULTANT. 20. lnde Indent Contractor. Both parties hereto, in the performance of this Contract, shall act in an individual capacity and not as agents, employees, partners, joint ventures or associates of one another. The employees or agents of one party shall not be deemed or construed to be the employees or agents of the other party for any purposes whatsoever. Neither party will assume liability for any injury (including death) to any persons, or damage to any property, arising out of the acts or omissions of the agents or employees of the other party. The CONSULTANT shall be responsible for providing all necessary unemployment and workers' compensation insurance for its employees. 21. Insurance - Liability for Damages. A. The CONSULTANT shall be responsible for the accuracy of the Services performed under this Contract and shall promptly make necessary revisions or corrections resulting from its negligence, errors or omissions without any additional compensation from the LPA. Acceptance of the Services by the LPA shall not relieve the CONSULTANT of responsibility for subsequent correction of its negligent act, error or omission or for clarification of ambiguities. The CONSULTANT shall have no liability for the errors or deficiencies in designs, drawings, specifications or other services furnished to the CONSULTANT by the LPA on which the Consultant has reasonably relied, provided that the foregoing shall not relieve the CONSULTANT from any liability from the CONSULTANT'S failure to fulfill its obligations under this Contract, to exercise its professional responsibilities to the LPA, or to notify the LPA of any errors or deficiencies which the CONSULTANT knew or should have known existed. B. During construction or any phase of work performed by others based on Services provided by the CONSULTANT, the CONSULTANT shall confer with the LPA when necessary for the purpose of interpreting the information, and/or to correct any negligent act, error or omission. The CONSULTANT shall prepare any plans or data needed to correct the negligent act, error or omission without additional compensation, even though final payment may have been received by the CONSULTANT. The CONSULTANT shall give immediate attention to these changes for a minimum of delay to the project. C. The CONSULTANT shall be responsible for damages including but not limited to direct and indirect damages incurred by the LPA as a result of any negligent act, error or omission of the CONSULTANT, and for the LPA's losses or costs to repair or remedy construction. Acceptance of the Services by the LPA shall not relieve the CONSULTANT of responsibility for subsequent correction. 10 Version 6-8-2017 D. The CONSULTANT shall be required to maintain in full force and effect, insurance as described below from the date of the first authorization to proceed until the LPA's acceptance of the work product. The CONSULTANT shall list both the LPA and INDOT as insureds on any policies. The CONSULTANT must obtain insurance written by insurance companies authorized to transact business in the State of Indiana and licensed by the Department of Insurance as either admitted or non -admitted insurers. E. The LPA, its officers and employees assume no responsibility for the adequacy of limits and coverage in the event of any claims against the CONSULTANT, its officers, employees, sub - consultants or any agent of any of them, and the obligations of indemnification in Section 19 herein shall survive the exhaustion of limits of coverage and discontinuance of coverage beyond the term specified, to the fullest extent of the law. F„ The CONSULTANT shall furnish a certificate of insurance and all endorsements to the LPA prior to the commencement of this Contract. Any deductible or self -insured retention amount or other similar obligation under the insurance policies shall be the sole obligation of the CONSULTANT. Failure to provide insurance as required in this Contract is a material breach of Contract entitling the LPA to immediately terminate this Contract. I. Professional Liability Insurance The CONSULTANT must obtain and carry professional liability insurance as follows: For INDOT Prequalification Work Types 1.1, 12.2-12.6 the CONSULTANTS shall provide not less than $250,000.00 professional liability insurance per claim and $250.000.00 aggregate for all claims for negligent performance. For Work Types 2.2, 3.1, 3.2, 4.1, 4.2, 5.5 , 5.8 , 5.11, 6.1, 7.1, 8.1, 8.2 , 9.1, 9.2 , 10.1 — 10.4 , 11.1, 13.1, 14.1 — 14.5 , the CONSULTANTS shall carry professional liability insurance in an amount not less than $1,000,000.00 per claim and $1,000,000.00 aggregate for all claims for negligent performance. The CONSULTANT shall maintain the coverage for a period ending two (2) years after substantial completion of construction. II. Commercial General Liability Insurance The CONSULTANT must obtain and carry Commercial / General liability insurance as follows: For INDOT Prequalification Work Types 2.1, 6.1, 7.1, 8.1, 8.2, 9.1, 9.2, 10.1 - 10.4, 11.1, 13.1, 14.1 - 14.5, the CONSULTANT shall carry $1,000,000.00 per occurrence, $2,000,000.00 general aggregate. Coverage shall be on an occurrence form, and include contractual liability. The policy shall be amended to include the following extensions of coverage: Exclusions relating to the use of explosives, collapse, and underground damage to property shall be removed. The policy shall provide thirty (30) days notice of cancellation to LPA. The CONSULTANT shall name the LPA as an additional insured, III. Automobile Liability The CONSULTANT shall obtain automobile liability insurance covering all owned, leased, borrowed, rented, or non -owned autos used by employees or others on behalf of the CONSULTANT for the conduct of the CONSULTANT's business, for an amount not less than $1,000,000.00 Combined Single Limit for Bodily Injury and Property Damage. The term "automobile" shall include private passenger autos, trucks, and similar type vehicles licensed for use on public highways. The policy shall be amended to include the following extensions of coverage: 11 Version 6-8-2017 1. Contractual Liability coverage shall be included. 2. The policy shall provide thirty (30) days notice of cancellation to the LPA. 3. The CONSULTANT shall name the LPA as an additional insured. IV. Watercraft Liability (When Applicable) When necessary to use watercraft for the performance of the CONSULTANT's Services under the terms of this Contract, either by the CONSULTANT, or any SUB -CONSULTANT, the CONSULTANT or SUB -CONSULTANT operating the watercraft shall carry watercraft liability insurance in the amount of $1,000,000 Combined Single Limit for Bodily Injury and Property Damage, including Protection & Indemnity where applicable. Coverage shall apply to owned, non - owned, and hired watercraft. 2. If the maritime laws apply to any work to be performed by the CONSULTANT under the terms of the agreement, the following coverage shall be provided: a. United States Longshoremen & Harbor workers Maritime Coverage - Jones Act 3. The policy shall provide thirty (30) days notice of cancellation to the LPA. 4. The CONSULTANT or SUB -CONSULTANT shall name the LPA as an additional insured. V. Aircraft Liability (When Applicable) When necessary to use aircraft for the performance of the CONSULTANT's Services under the terms of this Contract, either by the CONSULTANT or SUB - CONSULTANT, the CONSULTANT or SUB -CONSULTANT operating the aircraft shall carry aircraft liability insurance in the amount of $5,000,000 Combined Single Limit for Bodily Injury and Property Damage, including Passenger Liability. Coverage shall apply to owned, non -owned and hired aircraft. 2. The policy shall provide thirty (30) days notice of cancellation to the LPA. The CONSULTANT or SUB -CONSULTANT shall name the LPA as an additional insured. 22. Merger and Modification. This Contract constitutes the entire agreement between the parties. No understandings, agreements or representations, oral or written, not specified within this Contract will be valid provisions of this Contact. This Contract may not be modified, supplemented or amended, in any manner, except by written agreement signed by all necessary parties. 23. Notice to Parties: Any notice, request, consent or communication (collectively a "Notice") under this Agreement shall be effective only if it is in writing and (a) personally delivered; (b) sent by certified or registered mail, return receipt requested, postage prepaid; or (c) sent by a nationally recognized overnight delivery service, with delivery confirmed and costs of delivery being prepaid, addressed as follows: 12 Version 6-8-2017 Notices to the LPA shall be sent to: Dr, Cerra Boyles Ph.D. P.'F., City Engineer gineer 227 "West Jefferson Boulevard Suite 1316 South (lend IN 46601 Notices to the CONSULTANT shall be sent to: Jill Palmer, PE 7321 Shadeland Station Suite 160 Indianapolis, 1'N 46256, or to such other address or addresses as shall be furnished in writing by any party to the other party. Unless the sending party has actual knowledge that a Notice was not received by the intended recipient, a Notice shall be deemed to have been given as of the date (i) when personally delivered; (ii) three (3) days after the date deposited with the United States mail properly addressed; or (iii) the next day when delivered during business hours to overnight delivery service, properly addressed and prior to such delivery service's cut off time for next day delivery. The parties acknowledge that notices delivered by facsimile or by email shall not be effective. 24. Order of Precedence-, Incor aeration by Reference. Any inconsistency or ambiguity in this Contract shall be resolved by giving precedence in the following order: (1) This Contract and attachments, (2) RFP document, (3) the CONSULTANT's response to the RFP document, and (4) attachments prepared by the CONSULTANT.- All of the foregoing are incorporated fully by reference. 25. Ownershi of Documents and Materials. All documents, records, programs, data, film, tape, articles, memoranda, and other materials not developed or licensed by the CONSULTANT prior to execution of this Contract, but specifically developed under this Contract shall be considered "work for hire" and the CONSULTANT assigns and transfers any ownership claim to the LPA and all such materials ("Work Product) will be the property of the LPA. The CONSULTANT agrees to execute and deliver such assignments or other documents as may be requested by the LPA. Use of these materials, other than related to contract performance by the CONSULTANT, without the LPA's prior written consent, is prohibited. During the performance of this Contract, the CONSULTANT shall be responsible for any loss of or damage to any of the Work Product developed for or supplied by INDOT and used to develop or assist in the Services provided herein while any such Work Product is in the possession or control of the CONSULTANT. Any loss or damage thereto shall be restored at the CONSULTANT's expense. The CONSULTANT shall provide the LPA full, immediate, and unrestricted access to the Work Product during the term of this Contract. The CONSULTANT represents, to the best of its knowledge and belief after diligent inquiry and other than as disclosed in writing prior to or contemporaneously with the execution of this Contract by the CONSULTANT, that the Work Product does not infringe upon or misappropriate the intellectual property or other rights of any third party. The CONSULTANT shall not be liable for the use of its deliverables described in Appendix "A" on other projects without the express written consent of the CONSULTANT or as provided in Appendix "A". The LPA acknowledges that it has no claims to any copyrights not transferred to INDOT under this paragraph. 26. Payments. All payments shall be made in arrears and in conformance with the LPA's fiscal policies and procedures. 27. Penalties Interest and Attorne 's Fees. The LPA will in good faith perform its required obligations hereunder, and does not agree to pay any penalties, liquidated damages, interest, or attorney's fees, except as required by Indiana law in part, IC 5-17-5,1. C. 34-54-8, and I. C. 34-13-1. 13 Version 6-8-2017 28. Pollution Control Re uirements. If this Contract is for $100,000 or more, the CONSULTANT: Stipulates that any facility to be utilized in performance under or to benefit from this Contract is not listed on the Environmental Protection Agency (EPA) List of Violating Facilities issued pursuant to the requirements of the Clean Air Act, as amended, and the Federal Water Pollution Control Act, as amended; Agrees to comply with all of the requirements of section 114 of the Clean Air Act and section 308 of the Federal Water Pollution Control Act, and all regulations and guidelines issued thereunder; and ii„ Stipulates that, as a condition of federal aid pursuant to this Contract, it shall notify INDOT and the Federal Highway Administration of the receipt of any knowledge indicating that a facility to be utilized in performance under or to benefit from this Contract is under consideration to be listed on the EPA Listing of Violating Facilities. 29. "Severability. The invalidity of any section, subsection, clause or provision of this Contract shall not affect the validity of the remaining sections, subsections, clauses or provisions of this Contract. 30. Status of Claims. The CONSULTANT shall give prompt written notice to the LPA any claims made for damages against the CONSULTANT resulting from Services performed under this Contract and shall be responsible for keeping the LPA currently advised as to the status of such claims. The CONSULTANT shall send notice of claims related to work under this Contract to: Dr. Kara Boyles, Ph.D., P.E. C, ity Fri xineer 227 West Jefferson Boulevard Suite 1316 South Bend IN 46691 31. Sub -consultant Acknowledgement. The CONSULTANT agrees and represents and warrants to the LPA, that the CONSULTANT will obtain signed Sub -consultant Acknowledgement forms, from all SUB -CONSULTANTS providing Services under this Contract or to be compensated for Services through this Contract. The CONSULTANT agrees to provide signed originals of the Sub -consultant Acknowledgement form(s) to the LPA for approval prior to performance of the Services by any SUB - CONSULTANT. 32. Substantial Performance. This Contract shall be deemed to be substantially performed only when fully performed according to its terms and conditions and any modification or Amendment thereof. 33. Taxes. The LPA will not be responsible for any taxes levied on the CONSULTANT as a result of this Contract. 34. Termination for Convenience. A, The LPA may terminate, in whole or in part, whenever, for any reason, when the LPA determines that such termination is in its best interests. Termination or partial termination of Services shall be effected by delivery to the CONSULTANT of a Termination Notice at least fifteen (15) days prior to the termination effective date, specifying the extent to which performance of Services under such termination becomes effective. The CONSULTANT shall be compensated for Services properly rendered prior to the effective date of termination. The LPA will not be liable for Services performed after the effective date of termination. B„ If the LPA terminates or partially terminates this Contract for any reason regardless of whether it is for convenience or for default, then and in such event, all data, reports, drawings, plans, sketches, sections and models, all specifications, estimates, measurements and data pertaining to the project, prepared under the terms or in fulfillment of this Contract, shall be delivered within ten (10) days to the LPA. In the event of the failure by the CONSULTANT to make such delivery 14 Version 6-8-2017 upon demand, the CONSULTANT shall pay to the LPA any damage (including costs and reasonable attorneys' fees and expenses) it may sustain by reason thereof. 15 Version 6-8-2017 35. Termination for Default. A. With the provision of twenty (20) days written notice to the CONSULTANT, the LPA may terminate this Contract in whole or in part if (i) the CONSULTANT fails to: I. Correct or cure any breach of this Contract within such time, provided that if such cure is not reasonably achievable in such time, the CONSULTANT shall have up to ninety (90) days from such notice to effect such cure if the CONSULTANT promptly commences and diligently pursues such cure as soon as practicable; 2. Deliver the supplies or perform the Services within the time specified in this Contract or any amendment or extension; 3. Make progress so as to endanger performance of this Contract; or 4. Perform any of the other provisions of this Contract to be performed by the CONSULTANT; or (ii) if any representation or warranty of the CONSULTANT is untrue or inaccurate in any material respect at the time made or deemed to be made. B. If the LPA terminates this Contract in whole or in part, it may acquire, under the terms and in the manner the LPA considers appropriate, supplies or services similar to those terminated, and the CONSULTANT will be liable to the LPA for any excess costs for those supplies or services. However, the CONSULTANT shall continue the work not terminated. C. The LPA shall pay the contract price for completed supplies delivered and Services accepted. The CONSULTANT and the LPA shall agree on the amount of payment for manufactured materials delivered and accepted and for the protection and preservation of the property. Failure to agree will be a dispute under the Disputes clause (see Section 13). The LPA may withhold from the agreed upon price for Services any sum the LPA determine necessary to protect the LPA against loss because of outstanding liens or claims of former lien holders. D. The rights and remedies of the LPA in this clause are in addition to any other rights and remedies provided by law or equity or under this Contract. E. Default by the LIMA. If the CONSULTANT believes the LPA is in default of this Contract, it shall provide written notice immediately to the LPA describing such default. If the LPA fails to take steps to correct or cure any material breach of this Contract within sixty (60) days after receipt of such written notice, the CONSULTANT may cancel and terminate this Contract and institute the appropriate measures to collect monies due up to and including the date of termination, including reasonable attorney fees and expenses, provided that if such cure is not reasonably achievable in such time, the LPA shall have up to one hundred twenty (120) days from such notice to effect such cure if the LPA promptly commences and diligently pursues such cure as soon as practicable. The CONSULTANT shall be compensated for Services properly rendered prior to the effective date of such termination. The CONSULTANT agrees that it has no right of termination for non -material breaches by the LPA. 16 Version 6-8-2017 36. Waiver of Rights . No rights conferred on either party under this Contract shall be deemed waived, and no breach of this Contract excused, unless such waiver or excuse is approved in writing and signed by the party claimed to have waived such right. Neither the LPA's review, approval or acceptance of, nor payment for, the Services required under this Contract shall be construed to operate as a waiver of any rights under this Contract or of any cause of action arising out of the performance of this Contract, and the CONSULTANT shall be and remain liable to the LPA in accordance with applicable law for all damages to the LPA caused by the CONSULTANT's negligent performance of any of the Services furnished under this Contract. 37.. Work Standards/Conflicts of Interest. The CONSULTANT shall understand and utilize all relevant INDOT standards including, but not limited to, the most current version of the Indiana Department of Transportation Design Manual, where applicable, and other appropriate materials and shall perform all Services in accordance with the standards of care, skill and diligence required in Appendix "A" or, if not set forth therein, ordinarily exercised by competent professionals doing work of a similar nature. 38. No Third -Party Beneficiaries. This Agreement is solely for the benefit of the parties hereto. Other than the indemnity rights under this Contract, nothing contained in this Agreement is intended or shall be construed to confer upon any person or entity (other than the parties hereto) any rights, benefits or remedies of any kind or character whatsoever. 39, No Investment in Iran. As required by IC 5-22-16.5, the CONSULTANT certifies that the CONSULTANT is not engaged in investment activities in Iran. Providing false certification may result in the consequences listed in IC 5-22-16.5-14, including termination of this Contract and denial of future state contracts, as well as an imposition of a civil penalty. 40. A si nment of Antitrust Claims. The CONSULTANT assigns to the State all right, title and interest in and to any claims the CONSULTANT now has, or may acquire, under state or federal antitrust laws relating to the products or services which are the subject of this Contract. [Remainder of Page Intentionally Left Blank] 17 Version 6-8-2017 Non -Collusion. The undersigned attests, subject to the penalties for perjury, that he/she is the CONSULTANT, or that he/she is the properly authorized representative, agent, member or officer of the CONSULTANT, that he/she has not, nor has any other member, employee, representative, agent or officer of the CONSULTANT, directly or indirectly, to the best of his/her knowledge, entered into or offered to enter into any combination, collusion or agreement to receive or pay, and that he/she has not received or paid, any sum of money or other consideration for the execution of this Contract other than that which appears upon the face of this Contract. Furthermore, if the undersigned has knowledge that a state officer, employee, or special state appointee, as those terms are defined in IC §4-2-6-1, has a financial interest in the Contract, the Party attests to compliance with the disclosure requirements in IC §4-2-6-10.5. In Witness Whereof, the CONSULTANT and the LPA have, through duly authorized representatives, entered into this Contract. The parties having read and understand the forgoing terms of this Contract do by their respective signatures dated below hereby agree to the terms thereof. CONSULTANT Signature (Print or type name and title) LOCAL PUBLIC AGENCY Gary A. Gilo , President, Board of Public Works Genevieve E. Miller, Member, Board of Public Works Laura O'Sullivan, Member, Board of Public Works Elizabeth A. Maradik, Member, Board of Public Works Attest: Therese J. Dor au, Membep,-Ifloard ofPublic— Works Signature (Print or type name and title) inch M. Martin, Cferk 18 Version 6-8-2017 APPENDIX "A" SERVICES TO BE FURNISHED BY CONSULTANT: In fulfillment of this Contract, the CONSULTANT shall comply with the requirements of the appropriate regulations and requirements of the Indiana Department of Transportation and Federal Highway Administration. The CONSULTANT shall be responsible for performing the following activities: Understanding The purpose of this project is to replace school speed zone sign assemblies with flashing beacon sign assemblies at approximately 39 schools within the City of South Bend. The project calls for replacing signage within school zones and determining the appropriate placement and use of signage enhanced with flashing beacons. This contract covers preliminary engineering activities, which include design and preparation of contract documents for letting. The project will be let through the INDOT LPA process in accordance with HSIP funding requirements. LPA staff will be responsible for seeking changes to ordinances, if required. The LPA will be responsible for programming flashing time once the assemblies are installed. Scope of Services — School Flashers Design Determine the appropriate use of flashing beacons 1. Review the posted speed limits on roads near the selected schools, both the school zone speed limit and the off -hours "regular" speed limit. 2. Review the LPA's school zone speed limit ordinance for a definition of a "school zone" and applicability of the reduced speed limit. 3. In conjunction with the LPA, determine which of the schools and which frontages should have a school zone speed reduction with flashing beacons installed. Gather existing data 1. Obtain GIS layers, as available, to assist in generating base maps for the design plans. 2. Use online mapping tools supplemented with on -site field checks to determine the approximate locations of existing school zone signage. Prepare plan sheets Create base maps for each school area using GIS mapping. Plot the approximate locations of existing school zone signage (not to scale). 19 Version 6-8-2017 3. Indicate with symbols and descriptions the locations of flashing beacon assemblies to be installed. Static signs (those without flashing beacons) are not included in the project scope. 4. Develop a typical installation detail representative of each type of assembly to be installed, showing the sign type(s), height of sign, offset of sign from edge of pavement, flashing beacon, and other components. Environmental Document 1. Details of the environmental scope of services are attached. 2. This project is expected to qualify for Programmatic Categorical Exclusion (PCE) plus bat worksheet and limited red flag investigations at each school. Prepare contract documents 1. Prepare title sheet, index sheet, maintenance of traffic notes, and typical installation details. 2. Prepare map sheets indicating sign locations and summary tables indicating materials to be installed or removed. 3. Prepare quantities, cost estimates, provisions, and other documentation as required for INDOT LPA submittal. 4. Include specifications for components to allow remote programming and monitoring, if the LPA decides to include that equipment. Include a specification that requires the contractor/vendor/manufacturer to provide adequate solar energy collection and storage for each flasher location. Include a specification that all flasher units are to be from the same manufacturer. 5. Utility coordination will be performed in accordance with INDOT requirements. No utility relocations are expected for this project. Instead, the design will be adjusted around existing utilities. Submittals 1. Stage 3 to LPA for review 2. Stage 3 to INDOT 3. Final Tracings to INDOT with copy to LPA 4. Electronic CAD and other files distributed to LPA Meetings 1. Scope of Work meeting with INDOT 2. One design meeting, to be held early in the design process Construction Phase Services — Construction Engineering Objective: the objective of this task is to facilitate a competitive bid process for the project, clarify design intent during construction, and continue utility coordination services during construction. 1. Review plans and bid documents as advertised by INDOT and notify INDOT of inconsistencies from submitted documents which require correction. 20 Version 6-8-2017 2. Respond to bidder questions. 3. Issue addenda to interpret, clarify, or expand the plans and bid documents that are not directly related to an error or omission by Shrewsberry. 4. Attend pre -construction meeting. 5. Respond to contractor questions during construction to clarify design intent. 6. Review shop drawings, if applicable. 7. Perform utility coordination services during construction. Exclusions: Construction inspection services. Attendance at construction progress meetings. 21 Version 6-8-2017 APPENDIX "B" INFORMATION AND SERVICES TO BE FURNISHED BY THE LPA: The LPA shall furnish the CONSULTANT with the following: (TO BE DETERMINED -MAY INCLUDE THE FOLLOWING) 1. Criteria for design and details for signs, signals, lighting, highway and structures such as grades, curves, sight distances, clearances, design loading, etc. 2. Standard Specifications and standard drawings applicable to the project 3. All written views pertinent to the location and environmental studies that are received by INDOT 4. Provide access to enter upon public and private lands as required for the CONSULTANT to perform work under this Contract Version 6-8-2017 APPENDIX "C" SCHEDULE: No work under this Contract shall be performed by the CONSULTANT until the CONSULTANT receives a written notice to proceed from the LPA. All work by the CONSULTANT under this Contract shall be completed and delivered to the LPA for review and approval within the approximate time periods shown in the following submission schedule: Schedule based on a 12/8/21 letting date: A. Requested data provided to Shrewsberry by 11/1/20. B. Stage 3 to LPA for review by 5/1 /21. C. Stage 3 to INDOT by 7/16/21. D. Environmental Document approval by 9/29/21. E. Final Tracings to INDOT by 8/30/21. F. Letting on 12/8/21. G. Preconstruction meeting to be determined by INDOT. 23 Version 6-8-2017 Fee APPENDIX "D" A. Preliminary Engineering B. Environmental C. Construction Engineering D. Total Breakdown of fees is attached. 24 LUMP SUM LUMP SUM T&M NTE $50,068.00 $19,304.00 $10,000.00 $79,372.00 South Bend School Flashers Fee Justification Des. Number: 1801240 312512019 Inal shrewsherrg Task i Eng. 4 147.93 Eng. 2 101.99 Des. l 7151 0 Mileage Total Determine appropriate use of flashing beacons 1. Review speed limits 2 $ 295.86 2. Review ordinances 1 $ 147.93 3. Determine which schools/frontages get speed flashers Gather existing data 4 $ 591.72 1. Obtain GIS layers 1 $ 101.99 2. Determine approximate locations of existing school zone signage 24 52 $420.00 $ 9,273.80 Prepare plan sheets 1. Create base maps using GIS 8 60 $ 5,315.92 2. Plot existing school signage 4 40 $ 4,671.32 3. Indicate the locations of flashing beacons to be installed 12 40 $ 5,854.76 4. Develop a typical installation detail Prepare contract documents 1. Prepare general sheets 2 2 2 8 $ 353.98 $ 895.86 2. Prepare map sheets and summary tables 4 8 8 $ 2,007.64 3. Prepare quantities and estimates 4. Prepare specifications 4 16 20 4 $ 2,631.52 $ 2,774.84 5. Utility coordination 1 8 $ 963.85 Submittals Stage 3 Final Tracings 40 20 16 20 $ 7,549.04 $ 4,998.40 Meetings Design meeting 6 6 $140.00 $ 1,639.52 Scope of Work meeting Subtotals 6 106 209 78 $140.00 $700.00 1 $ 50,067.95 Preliminary Engineering Total - Lump Sum $ 69,371.95 Construction Phase Services - Construction Engineering - Time and Materials Not To Exceed $ 10,000.00 SCOPE OF SERVICES UPDATED MARCH 18, 2019 The City of South Bend proposes to proceed with the School Zone Flashing Beacon and Sign Upgrades Project, Des. 1801240. Shrewsberry and Associates will enter into a sub contract with Green 3, LLC who has been charged in complying with the National Environmental Policy Act (NEPA) and all related federal, state, and local laws in accordance with the most current INDOT regulations. Client Contact: Jill Palmer, PE; 4pylr7 ert shewuw.com. Shrewsberry and Associates 7321 Shadeland Station, Suite 160 Indianapolis, IN 46256 Project Vocation; The project is located In South Bend, St. Joseph County, Indiana. Project f cope Based on project information received on February 15, 2019 and February 25, 2019, this project involves the upgrade of existing signage that will Include the installation of school zone flashing beacons at and near 39 schools in South Bend. Assumptions for Green 3, LLC"s Scope of Services: PCE • All work will occur within existing right-of-way. • The project will fall under the criteria for a Programmatic Categorical Exclusion (PCE) environmental document. • No onsite project meetings will be required; all coordination and communication will be via email and phone. • Limited Red Flag Investigations (RFIs) only will be required; for the purposes of this proposal, it is assumed that up to 30 RFIs will be required. Due to the number of environmental sites of concern surrounding the schools, research of the Indiana Department of Environmental Management (IDEM) Virtual File Cabinet will be necessary to meet the requirements of the Indiana Department of Transportation Site Assessment and Management (INDOT SAM) for RFIs. • No waterway permits will be required. • No impacts to Section 4(f) resources will occur. • No tree removal will be required, and therefore the project will result in a No Effect or Not Likely to Adversely Affect (without minimization/avoidance measures) to endangered species, including bats. Section 106 Review - MPPA, Category B • Based on current project information, this project will fall under the Minor Projects Programmatic Agreement (MPPA), Category A. Since all work will be upgrades to existing signs in previously Green 3, LLC 1104 Prospect Street Indianapolis, IN 46203 317.634.4110 disturbed soils, Category A of the MPPA will apply. Archaeology • Because it is assumed that all work will occur within the existing and disturbed right-of-way of roadways, no archaeological studies will be required. n ironrnentalll bse ations Concerns; • Multiple environmental sites of concern exist in and around the schools listed in this project. • Due to the proposed work of upgrading signs occurring in existing right-of-way (under MPPA, Category A), there should be no impact to the dozens of above -ground resources within the project area listed in the State Historic Architectural and Archaeological Research Database (SHAARD) that are listed In the National Register of Historic Places (NRHP) as well rated Notable and Outstanding. Green 3. LLC Level of "fork and Deliverables: • PCE document with up to 30 limited RFIs • Section 106/MPPA, Cat A Sup leernentall Clause: This scope of services DOES NOT include the following: l . Any special studies such as 4(f) evaluations, noise/air analyses, waters of the U.S. reporting, permitting coordination/execution, hazardous materials testing, etc. 2. Any changes in scope, such as right-of-way acquisition, or impacts to resources not currently known that would require a full CE document 3. Any preparation of documentation under the MPPA Category B, a historic properties report, 800.11 documentation (full Section 106 review), memorandum of agreement (MOA), or any additional work requested/required by Indiana State Historic Preservation Office (SHPO) or INDOT Cultural Resources Office. 4. Any archaeological records review, fieldwork, and write-up of the results are found to be required after the acceptance of this proposal. If, upon consultation with all local, state, and federal agencies regarding the project, additional studies are requested or the project scope/area changes, then additional fees will be required to meet the additional scope of services. The fee for this work will be $19,304.00 to be billed as lump sum based on percent complete. The task and hourly breakdown of this fee is attached. Thank you, and we look forward to working with you! Kind Regards, Erin Mulryan, MPA ['resident Green 3, LLC 1104 Prospect Street Indianapolis, IN 46203 317.634.4110 Name of Project: South Bend School Zone Flashing Beacons, Des No. 1801240 Job Type: Programmatic Categorical Exclusion (PCE) Contact Information: Shrewsberry & Associates, LLC @ r ®, , 3 Green 3, LLC ATTN: Jill Palmer Historic Fountain Square 7321 Shadeland Station, Suite 160 1 104 Prospect Street Indianapolis, IN 46256 Indianapolis IN 46203 updated March 18, 2019 Fee Justification CE Task Description Principal,/"tP Wetland Ecologist Totals I I, I I IYlrl 111 + I I r la����ammart"auN�wx�I�I�iil�u��wmti�Mt�w��wrJai�rsrm���rwJr�ii�iiiiaaraiuuuiuiir�iiauril�rauuuuurrw�io�>'>' �a� aieri.�rr �,�rairr UU���a»�w�umUiuiarl�l�yrraJrriu,r� �rr�»riania I+rlmu�rtr r i J r I I, I J r f� 1 I r ;���rr�rQtu>dt<sn��r�u m>>mw ua mot. rowtt��n���u>r�aml�uv�ttta�„���U�rrtr�rtrUrJLu�u�iUiiu9im�uii9udJ4u�rrir»sravttul�nlr����ra�urlirrir�rJar��wlNJ�r�JJ�rwt,�Jri>r:rrrKrr�r�mm�uuIiuI �iIuittitIon Project Coordination & Contract Administration 4.0 4.0 8.0 PCE Map(s) & Exhibit Development 1.0 20.0 21.0 U.S. Fish&Wildlife (USFWS) Range -wide Programmatic Consultation for Endangered Bat Species- Compliance Documentation 1.0 6.0 7.0 Coordination with INDOT Site Assessment & Management and Limited Red Flag Investigations (assumes limited investigations for 39 schools) 4.0 120.0 124.0 PCE Form Development 2.0 24.0 26.0 INDOT PCE Submittal Coordination 1.0 14.0 1550 Final Commitments Summary Form Prep & Submission 1.0 10.0 1 1.0 Section 106 MPPA Category A Verification 4.0 0.0 4.0 Hour Totals 18.0 198.0 216.0 Rates $130.00 $85.00 Total Feefor CE $2,340.00 $16,830.00 $19,170.00 Expenses: Printing, postage $20.00 Mileage ($0.38/mix 300 mi roundtrip, one field day) $1 14.00 /%,.Nd`N.ntld✓//lArh'i17✓Nr'.1lPdQIGiDI!Wh1V�ly1Nn//,4,�11YI1!'///,.dYW`AIIII. 1d011YUJ11111%1PU'JYlIIJh'J11G)d111YY11Y111'rllNlll(VNIYrII)////////Y!!l/lfJ�'.Y4DYJAU////lIdIIIIIIIIIIIIAIM'XC9s�(dl/LJlilll{7l178JYitlI4f,L!%7M%6(l/dd�(VNlftlflld/,11111UJllfll/////17fP11iW,VJI/UEJIEI't/I7mN177YG11911,,,�16iVilt/1�11!!/f/IUN!/NIlJ✓////fllm(IGII„✓/11fPYAIdJIlNdfNfPU11N17(Y/ftlllBdf1,Y7(,//!//„t/Il�I(If,NYIfiIYIYIN(UYA'r/I ;,%11 dli(6% Yir i'( 9'I "ti" 1. Ud/ldlti rM,'....�VAfIIUU;tNId Jill lidffbll� TOTAL Proposed Fee For CE &Sec 106 $ 19,304.00 RFP Scoring Tabulation Sheet Version 8/3/18 - LPA RFP Scoring Tabulation for: Flashing School Beacons for 39 Schools Item Title: Non -Complex R adway Design Des. No.: 1801240 Member I I Member 2 I Member 3 Weighted Consultants (list consultants below and enter Alicia Roger Nawrot Scott Kreeger Scores Ranking each Members score under their name) Czarnecki Total Shrewsberry & Associates 70 105 85 260 1 VS Engineering 65.2 85.2 50.2 200.6 2 A&F Engineering Co 30 50 30 110 3 The Troyer Group 29.6 34.6 29.6 j 93.8 4 Employee in Responsible Charge Signature: " Title:, Date: '. RFP Selection Rating for Ciy of South Bend Des. No. 1801240 (City, County, Town) or (Local Public Agency) Services Description: Flas ing School Beacons for 39 Schools Consultant Name: Evaluation Criteria to be Rated by Scorers Category Scoring Criteria Scale Score Weight Weighted Score (Past Performance evaluation score averages from historical performance data. Quality score for similar work from performance database. 6 Perrormance Schedule score from performance database. 7 3� Responsiveness score from performance database. 1 Capacity of Evaluation of the team's personnel and equipment to perform the project on time. Team to do Availability of more than adequate capacity that results in added value. Adequate to I 20 Work capacity meet the schedule. 0 V Insufficient available ca acr to meet the schedule. . 1 Technical Expertise: Unique Resources that yield a relevant added value or efficiency to the deliverable. Team's Demonstrated outstanding expertise and resources identified 2 Demonstrated for required services for value added benefit. j 15 Qualifications Demonstrated high level of expertise and resources identified 1 1 is for required services for value added benefit. Expertise and resources at appropriate level. 0 Insufficient expertise and/or resources. -3 Predicted ability to manage the project, based on: experience in size, complexity, type, subs, documentation skills. Project Demonstrated outstanding experience in similar type and complexity. 2 Manager Demonstrated high level of experience in similar type and complexity. 1 /. 20 Experience in similar type and complexity shown in resume, 0 Experience in different type or lower complexity. -1 l/1l Insufficient cx ience. -3 Project Understanding and Innovation that provides cost and/or time savings. Approach to J High level of understanding and viable innovative ideas proposed. 2 Project High levelof the project. oc 1 15 understanding _ andi, of the project. 0 Weighted Sub -Total:) r It is the responsibility of scorers to make every effort to identify the firm most capable of producing the highest deliverables in a timely and cost effective manner without regard to personal preference. I certify that 1 do not have any conflicts of interest associated with this consultant as defined in 49CFR1 18.36. I have thoroughly reviewed the letter of interest for this consultant and certify that the above scores represent my best judgment of this firm's abilities. Signature: AhN,,1 Print Name: �✓ t, �✓�la Title: tC �d) I"�. Dater, . .. �. _.. �. a-. (Form Rev, 4-7-16) RFP Selection Rating for City of South Bend Des. No. 1801240 (City, County, Town) or (Local Public Agency) Services Description: Flashing School Beacons for 39 Schools Consultant Name: Evaluation Criteria to be Rated by Scorers Category Scoring Criteria Performance evaluation score averages from historical performance data. Past Quality score for similar work from performance database. Performance Schedule score from performance database. Res onsiveness score from performance database. Capacityof :valuation of the team's personnel and equipment to perform the project on time. Team to do Availability of more than adequate capacity that results in added value. Adequate capacity to meet the schedule. Work insufficient available capacity to meet the schedule. Technical Expertise: Unique Resources that yield a relevant added value or efficiency to the deliverable. Team's Demonstrated outstanding expertise and resources identified Demonstrated for required services for value added benefit. Qualifications Demonstrated high level of expertise and resources identified for required services for value added benefit. Expertise and resources at appropriate level. Insufficient ex ertise and/or resources. Predicted ability to manage the project, based on: experience in size, complexity, type, subs, documentation skills. Project Demonstrated outstanding experience in similar type and complexity. Manager Demonstrated high level of experience in similar type and complexity. Experience in similar type and complexity shown in resume. Experience in different type or lower complexity. Insufficient experience. Project Understanding and Innovation that provides cost and/or time savings. Approach to High level of understanding and viable innovative ideas proposed. Project High level of understanding of the project. Basic understanding of the project. Lack of Droiect understandine. Scale Score Weight Weighted Score —0i 6 1 _i' . Ga 2 1 0 -3 20 n 15 ,5 20 G 15 15 Weighted Sub -Total: It is the responsibility of scorers to make every effort to identify the firm most capable of producing the highest deliverables in a timely and cost effective manner without regard to personal preference. I certify that I do not have any conflicts of interest associated with this consultant as defined in 49CFR1 18.36. L ON I have thoroughly reviewed the letter of interest for this consultant and certify that the above scores represent my best judgment of this firm's abilities. Signature: A,�t, Title; (Form Rev. 4-7-16) Print Name: kc,a Date: RFP Selection Raking for Ciq of South Bend Des. No. 1801240 (City, County, Town) or (Local Public Agency) Services Description: Flashin School Beacons for 39 Schools Consultant Name: 'S i p r I 1' Evaluation Criteria to be Rated by Scorers Category B �'Y Scoring Criteria g Scale Score Weighted Weight Score Performance evaluation score averages from historical performance data. Past Quality score for similar work from performance database. 6 Performance Schedule score from perlinmunce database. 3 It4-s onsiveness score from wrl'onnance database. ,>, 1 Capacity of Evaluation of the team's personnel and equipment to perform the project on time. Team to do Availability of more than adequate capacity that results in added value. Adequate 1 20 Work capacity to meet the schedule. 0 Insufficient available EVIcity to meet the schedule. -1 Technical Expertise: Unique Resources that yield a relevant added value or efficiency to the deliverable. Team's Demonstrated outstanding expertise and resources identified 2 Demonstrated l f i for required services or value added benefit, Demonstrated high level identified � 15 3 Qualifications of expertise and resources I for required services for value added benefit, Expertise and resources at appropriate level. 0 Insufficient ex isc and/or resources. -3 Predicted ability to manage the project, based on: experience in size, complexity, type, subs, documentation skills. Project Demonstrated outstanding experience in similar type and complexity. 2 Manager Demonstrated high level of cx13cricnce in Similar type and Complexity. 1 I 20 hxpericnec in similar ty;v and complexity shown in resume. 0 Experience in different type or lower complexity. -1 Insufficient ex erience. -3 Project Understanding and Innovation that provides cost and/or time savings - Approach to High level of understanding and viable innovative ideas proposed. 2 Project High level of understanding of the project. 1 I 15 I S Basic understanding of the project. 0 Lack of ppject undcrstandin . -3 Weighted Sub-Totah �j 5 It is the responsibility of scorers to make every effort to identify the firm most capable of producing the highest deliverables in a timely and cost effective manner without regard to personal preference. I certify that I do not have any conflicts of interest associated with this consultant as defined in 49CFRI 18.36. I have thoroughly reviewed the letter of interest for this consultant and certify that the above scores represent my best judgment or this firm's abilities_ Signature: Title: ` t" l (Form Rev. 4-7-16) Print Name: Date: tV.. . . RFP Selection Rating for City of South Bend Des. No. 1801240 (City, County, Town) or (Local Public Agency) Services Description: Flushing School Beacons for 39 Schools Consultant Name: Evaluation Criteria to be Rated by Scorers Category Scoring Criteria Scale Score Weight Weighted Score Performance evaluation score averages from historical performance data. Past Quality score for similar work from performance database. 6 Performance Schedule score from performance database, j Res onsiveness score from Eerformance database. U l Capacity of Evaluation of the team's personnel and equipment to perform the project on time. Team to do Availability of more than adequate capacity that results in added value. Adequate 1 20 � Work capacity to meet the schedule. 0 Insufficient available ca aci to meet the schedule. -1 Technical Expertise: Unique Resources that yield a relevant added value or efficiency to the deliverable. Teant's Demonstrated outstanding expertise and resources identified 2 Demonstrated for required services for value added benefit. 15 ` Qualifications Demonstrated high level of expertise and resources identified I I I for required services for value added benefit.' Expertise and resources at appropriate Icvel.' 0 Insufficient expertise and/or resources. -3 Predicted ability to manage the project, based on: experience in size, complexity, type, subs, documentation skills. Project Demonstrated outstanding experience in similar type and complexity. 2 Manager Demonstrated high level of experience in similar type and complexity. 1 20 j Experience in similar type and complexity shown in resume. 0 Experience in different type or lower complexity. -1 Insufficient experience. -3 Project Understanding and Innovation that provides cost and/or time savings. Approach to High level of understanding and viable innovative ideas proposed. 2 Project High level of understanding of the project, 1 1 15 15 Basic understanding of the project. 0 Lack of ro'ect understanding.,-3 Weighted Sub -Total: It is the responsibility of scorers to make every effort to identify the firm most capable of producing the highest deliverables in a timely and cost effective manner without regard to personal preference. I certify that I do not have any conflicts of interest associated with this consultant as defined in 49CFRI 18.36. I have thoroughly reviewed the letter of interest for this consultant and certify that the above scores represent my best judgment of this firm's abilities. Signature: .;��°'� Title: fe (Form Rev. 4-7-16) Print Name: Alicla Date: ,. RFP Selection Rating for Ci of South Bend Des. No. 1801240 (City, County, Town) or (Local Public Agency) Services Description: Flashing School Beacons for 39 Schools Consultant Name: /J Evaluation Criteria to be Rated by Scorers Category Scoring Criteria Scale Score Weight Weighted Score Performance evaluation score averages from historical performance data. 6 Past Quality score for similar work from performance database. Performance Schedule score from performance database. ¢3 Responsiveness score from Performance database. 1 Capacity of Evaluation of the team's personnel and equipment to perform the project on time. Team to do Availability of more than adequate capacity that results in added value. Adequate capacity to meet the schedule. 1 0 20 0 Work Insufficient available capacity to meet the schedule. -1 Technical Expertise: Unique Resources that yield a relevant added value or efficiency to the deliverable. Teams Demonstrated outstanding expertise and resources identified 2 Demonstrated for required services for value added benefit. 15 Qualifications Demonstrated high level of expertise and resources identified 1 / for required services for value added benefit. Expertise and resources at appropriate level. 0 Insufficient ex ertise and/or resources. -3 Predicted ability to manage the project, based on: experience in size, complexity, type, subs, documentation skills. Project Demonstrated outstanding experience in similar type and complexity. 2 1Vlaoager Demonstrated high level of experience in similar type and complexity. 1 % 20 ! �LJ p Experience in similar type and complexity shown in resume. 0 Experience in different type or lower complexity. -1 Insufficient experience. -3 Project Understanding and Innovation that provides cost and/or time savings. Approach to ApprM High level of understanding and viable innovative ideas proposed. High level of understanding of the project. 2 1 15Proj / Basic understanding of the project. 1 0 Lack of oroiect understanding. 1 -3 Weighted Sub 'total: 5� It is the responsibility of scorers to make every effort to identify the firm most capable of producing the highest deliverables in a timely and cost effective manner without regard to personal preference. I certify that I do not have any conflicts of interest associated with this consultant as defined in 49CFRI 18.36. I have thoroughly revic e lie!—pflirucrcsl�', tlti:rconsultant and certify that the above scores represent my best judgment of this firm's abilities. Signature; ,� Print Name: Title: r; Date:Z- a.................,, ,..._ _ (Form Rev. 4-7-16) RFP Selection satin for City of South Bend Des. No. 1801240 (City, County, Town) or (Local Public Agency) Services Description: Flashing School Beacons for 39 Schools Consultant Name: 8 coep Evaluation Criteria to be Rated by Scorers Category Scoring Criteria Scale Score Weight Weighted Score Performance evaluation score averages from historical performance data. Past Quality score for similar work from performance database. —0./ 6 +- Performance Schedule score from performance database. 3 p ,.,,Responsiveness score from performance database. (, 1 0.210 Zo Capacity of Evaluation of the team's personnel and equipment to perform the project on time. Team to do Availability of more than adequate capacity that results in added value. 1 20 Adequate capacity to meet the schedule. 0 / Work 240 Insufficient available Maci!y to meet the schedule. -1 Technical Expertise: Unique Resources that yield a relevant added value or efficiency to the deliverable. Team's Demonstrated outstanding expertise and resources identified Uemonfor required services for value added benefit. d 2 15 attons Demonstrated high level of expertise and resources identified Qualifications 1 for required services for value added benefit. Expertise and resources at appropriate level. 0 Insufficient ex isc and/or resources. -3 Predicted ability to manage the project, based on: experience in size, complexity, type, subs, documentation skills. Project Demonstrated outstanding experience in similar type and complexity. 2 Manager Demonstrated high level of experience in similar type and complexity. 1 20 Experience in similar type and complexity shown in resume. 0 Experience in different type or lower complexity. -I Insufficient experience, -3 Project Understanding and Innovation that provides cost and/or time savings. Approach to High level of understanding and viable innovative ideas proposed, 2 High level of understanding of the project. Project 1 ` 15 Basic understanding of the project. 0 / Lack of project understanding. -3 Weighted Sub -Total: J 1� 4- It is the responsibility of scorers to make every effort to identify the firm most capable of producing the highest deliverables in a timely and cost effective manner without regard to personal preference. I certify that I do not have any conflicts of interest associated with this consultant as defined in 49CFRI 18.36. 1 have thoroughly reviewyk0ela1wof interestfiy this consultant and certify that the above scores represent my best judgment of this firm's abilities. Signature: Title: (Form Rev. 4-7-16) Print Name:�t�G Date: RFP Selection Rating for City of South Bend Des. No (City, County, Town) or (Local Public Agency) 1801240 Services Description: Flashing School Beacons for 39 Schools Consultant Name: rj l Pl6r&gI % Evaluation Criteria to be Rated by Scorers Category Scoring Criteria Scale Score Weight Weighted Score Performance evaluation score averages from historical performance data. Past Quality score for similar work from performance database. 6 Performance Schedule score from performance database. 3 U Res onsiveness score from performance database. 1 Capacity of Evaluation of the team's personnel and equipment to perform the project on time. Team to do Availability of more than adequate capacity that results in added value. Adequate to 1 20 Work capacity meet the schedule. 0 Insufficient available capacity to meet the schedule. -1 Technical Expertise: Unique Resources that yield a relevant added value or efficiency to the deliverable. Taam's Demonstrated outstanding expertise and resources identified 2 Demonstrated for required services for value added benefit. Demonstrated high level identified 15 Qualifications of expertise and resources 1 for required services for value added benefit. Expertise and resources at appropriate level. 0 lnsufficienl expertise and/or resources. -3 Predicted ability to manage the project, based on: experience in size, complexity, type, subs, documentation skills. Project Demonstrated outstanding experience in similar type and complexity. 2 Manager Demonstrated high level of experience in similar type and complexity. 1 / 20 Z C7 Experience in similar type and complexity shown in resume. 0 Experience in different type or lower complexity. -1 Insufficient experience. -3 Project Understanding and Innovation that provides cost and/or time savings. Approach to High level of understanding and viable innovative ideas proposed. 2 Project High level of understanding of the project. 1 J 1 is Basic understanding of the project. 0 Lack of ro'ect understandin 3 Weighted Sub -Total: It is the responsibility of scorers to make every effort to identify the firm most capable of producing the highest deliverables in a timely and cost effective manner without regard to personal preference. I certify that I do not have any conflicts of interest associated with this consultant as defined in 49CFR118.36. I have thoroughly rcv°ictvc lz5'intc:rc/stfMis consultant and certify that the above scores represent my best judgment of this firm's abilities. Signature: Print Name:...... %� u Title: Date: (Form Rev. 4-7-16) RFP Selection Ration for City of South Bend Des. No. 1801240 (City, County, Town) or (Local Public Agency) Services Description: Flashing School Beacons for 39 Schools Consultant Name: Evaluation Criteria to be Rated by Scorers Category Scoring Criteria Scale Score Weight Weighted Score Performance evaluation score averages from historical performance data. Past Quality score for similar work from performance database. U 6 Performance Schedule score from performance database, or 3 b Responsiveness score from i2erformance database. 1 �} Capacity of Evaluation of the team's personnel and equipment to perform the project on time. Team to do Availability of more than adequate capacity that results in added value. 1 20 Z Work Adequate capacity to meet the schedule. 0 Insufficient available ca acity to meet the schedule. -1 Technical Expertise: Unique Resources that yield a relevant added value or efficiency to the deliverable. Team's Demonstrated outstanding expertise and resources identified 2 Demonstrated for required services for value added benefit. Demonstrated high level identified 15 Qualifications of expertise and resources 1 for required services for value added benefit. Expertise and resources at appropriate level. 0 Insufficient ex ertise and/or resources. -3 Predicted ability to manage the project, based on: experience in size, complexity, type, subs, documentation skills. Project Demonstrated outstanding experience in similar type and complexity. 2 Manager Demonstrated high level of experience in similar type and complexity. 1 lJ 20 Experience in similar type and complexity shown in resume. 0 Experience in different type or lower complexity. -1 Insufficient experience. -3 Project Understanding and Innovation that provides cost and/or time savings. Approach to High level of understanding and viable innovative ideas proposed. High level of understanding of the project. 2 1 15 Project Basic understanding of the project. 0 Lack of pLoject understanding. -3 Weighted Sub -Total:: /D `v It is the responsibility of scorers to make every effort to identify the firm most capable of producing the highest deliverables in a timely and cost effective manner without regard to personal preference. I certify that I do not have I have thoroughly rev" "We Signature: Title: (Form Rev. 4-7-16) ith this consultant as defined in 49CFRI 19.36. ant and certify that the above scores represent my best judgment of this firm's abilities. Print Name: . Date: RFP Selection Rating for City of South Bend Des. No. 1801240 (City, County, Town) or (Local Public Agency) Services Description: Flashing School Beacons for 39 Schools Consultant Name: LP x,00 r;roc Evaluation Criteria to be Rated by Scorers Category Scoring Criteria Performance evaluation score averages from historical performance data. Past Quality score for similar work from performance database. Performance Schedule score from performance database. Responsiveness score from Berformance database. Scale Score Weight 6 p 3 Weighted Score 0 ] Capacity of Evaluation of the team's personnel and equipment to perform the project on time. Team to do Availability of more than adequate capacity that results in added value. 1 20 Work Adequate capacity to meet the schedule. 0 Insufficient available capacity to meet the schedule. -1 Technical Expertise: Unique Resources that yield a relevant added value or efficiency to the deliverable. Team's Demonstrated outstanding expertise and resources identified 2 for required services for value added benefit. Demonstrated 15 Qualifications Demonstrated high level of expertise and resources identified I M for required services for value added benefit. Expertise and resources at appropriate level. 0 Insufficient ex ertise and/or resources. -3 Predicted ability to manage the project, based on: experience in size, complexity, type, subs, documentation skills. Project Demonstrated outstanding experience in similar type and complexity. 2 U Manager Dcmonstrated high level of experience in similar type and complexity. 1 U 20 Experience in similar type and complexity shown in resume, 0 Experience in different type or lower complexity. - I Insufficient experience. -3 Project Understanding and Innovation that provides cost and/or time savings. Approach to High level of understanding and viable innovative ideas proposed. 2 Project High level of understanding of the project. 1 ( 15 15 Basic understanding of the project. 0 Lack of pr2ject understanding.,-3 Weighted Sub -Total: ,U It is the responsibility of scorers to make every effort to identify the firm most capable of producing the highest deliverables in a timely and cost effective manner without regard to personal preference. 1 certify that I do not have any conflicts of interest associated with this consultant as defined in 49CFRI 18.36. have thoroughly reviewed the letter of interest for this consultant and certify that the above scores represent my best judgment of this firm's abilities. Signature: -_ Print [dame: Title:�� Date: a ylr� j (Form Rev. 4-7-16) RFP Selection Rating for City of South Bend Des. No. 1801240 (City, County, Town) or (Local Public Agency) Services Consultant Description: Flashing School Beacons for 39 Schools Name: - Evaluation Criteria to be Rated by Scorers Category Scoring Criteria Scale Score Weight Weighted Score Performance evaluation score averages from historical performance data. Pest Quality score for similar work from performance database. - 6 Performance Schedule score from performance database. 0 3 Res naiveness score from perforrnance database. 1 O"OL 1 0. Capacity of Evaluation of the team's personnel and equipment to perform the project on time. Team to do Availability of more than adequate capacity that results in added value. l 20 i Work Adequate capacity to meet the schedule. 0 t Insufficient available ca aci to meet the schedule. -1 Technical Expertise: Unique Resources that yield a relevant added value or efficiency to the deliverable. Team's Demonstrated outstanding expertise and resources identified 2 'Demonstrated for required services for value added benefit. `` 15 Qualifications Demonstrated high level of expertise and resources identified 1 1 I for required services for value added benefit. Expertise and resources at appropriate level. 0 Insufficient expertise and/or resources. -3 Predicted ability to manage the project, based on: experience in size, complexity, type, subs, documentation skills. Project Demonstrated outstanding experience in similar type and complexity. 2 Manager Demonstrated high level of experience in similar type and complexity. 1 20 O Experience in similar type and complexity shown in resume. 0 O Experience in different type or lower complexity. ', -1 Insufficient experience, -3 Project Understanding and Innovation that provides cost and/or time savings. Approach to High level of understanding and viable innovative ideas proposed. 2 Project High level of understanding of the project. 1 i 15 5 Basic understanding of the project. 0 Lack of pro ect understandin . -3 Weighted Sub -Total: r1� It is the responsibility of scorers to make every effort to identify the firm most capable of producing the highest deliverables in a timely and cost effective manner without regard to personal preference. I certify that I do not have any conflicts of interest associated with this consultant as defined in 49CFRI 18.36. I have thoroughly reviewed the letter of interest for this consultant and certify that the above scores represent my best judgment of this firm's abilities. Signature: X11�11 Print Name: e arlr ,ra * ,,,,,,,, ,,,,,, Tile: ._�e Date: l `t I (Form Rev. 4-7-16) RFP Selection Rating for City of South Bend Des. No. 1801240 (City, County, Town) or (Local Public Agency) Services Description: Flashing School Beacons for 39 Schools Consultant Name: Evaluation Criteria to be Rated by Scorers Category Scoring Criteria Performance evaluation score averages from historical performance data. Past Quality score for similar work from performance database. Performance Schedule score from performance database. Res onsiveness score from performance database. Capacity of Evaluation of the team's personnel and equipment to perform the project on time. Team to do Availability of more than adequate capacity that results in added value. Work Adequate capacity to meet the schedule. Insufficient available capacity to meet the schedule. Technical Expertise: Unique Resources that yield a relevant added value or efficiency to the deliverable. Team's Demonstrated outstanding expertise and resources identified Demonstrated for required services for value added benefit. QusilQeatiotts Demonstrated high level of expertise and resources identified for required services for value added benefit. Expertise and resources at appropriate level. Insufficient expertise and/or resources. Predicted ability to manage the project, based on: experience in size, complexity, type, subs, documentation skills. Project Demonstrated outstanding experience in similar type and complexity. Manager Demonstrated high level of experience in similar type and complexity. Experience in similar type and complexity shown in resume. Experience in different type or lower complexity. Insufficient experience. Scale Score Weight Weighted Score 6 LO 3 p 0 -1 `^ V 20 2 1 I 15 I � 0 -3 Project Understanding and Innovation that provides cost and/or time savings. Approach to High level of understanding and viable innovative ideas proposed. 2 High level of understanding of the project. I Project Basic understanding of the project. 0 Lack of project understanding. -3 I 20 a (7 15 S Weighted Sub -Total: JU-o1 It is the responsibility of scorers to make every effort to identify the firm most capable of producing the highest deliverables in a timely and cost effective manner without regard to personal preference. i certify that I do not have any conflicts of interest associated with this consultant as defined in 49CFRI 18.36. I have thoroughly reviewed the letter of interest for this consultant and certify that the above scores represent my best judgment of this firm's abilities. Signature: - e Print Name: + e t. Title: j+.c ivw�.r° Date: a,/L l I I 'l (Form Rev. 4-7-16) RFP Selection Ratin for Ciy of South Bend Des. No. 1801240 (City, County, Town) or (Local Public Agency) Services Description: Flashing School Beacons for 39 Schools Consultant Name: Evaluation Criteria to be Rated by Scorers Category 'Scoring Criteria Scale Score Weight Weighted Score Performance evaluation score averages from historical performance data. Past Quality score for similar work from performance database. 6 Performance Schedule score from performance database. 3 Responsiveness score from performance database. i l7 Capacity of Evaluation of the team's personnel and equipment to perform the project on time. Team to do Availability of more than adequate capacity that results in added value. ➢ 20 Adequate capacity to meet the schedule. Work r, 0) V Insufficient available ca acity to meet the schedule. -1 Technical Expertise: Unique Resources that yield a relevant added value or efficiency to the deliverable. Team's Demonstrated outstanding expertise and resources identified 2 Demonstrated for required services for value added benefit. Demonstrated high level of expertise and resources identified 15 Qualifications I for required services for value added benefit. Expertise and resources at appropriate level. 0 Insufficient ex ertise and/or resources. -3 Predicted ability to manage the project, based on: experience in size, complexity, type, subs, documentation skills. Project Demonstrated outstanding experience in similar type and complexity. Demonstrated high level in 2 20 (� of experience similar type and complexity. Manager 1 a Experience in similar type and complexity shown in resume, 0 Experience in different type or lower complexity. -1 Insufficient experience. -3 Project Understanding and Innovation that provides cost and/or time savings. Approach to High level of understanding and viable innovative ideas proposed. High level 2 `. $ of understanding of the project. Project 1 15 Basic understanding of the project. 0 I..ack of gro ect undvrstandin . -3 Weighted Sub -Total: Q G; It is the responsibility of scorers to make every effort to identify the firm most capable of producing the highest deliverables in a timely and cost effective manner without regard to personal preference. I certify that I do not have any conflicts of interest associated with this consultant as defined in 49CFRI 18.36. I have thoroughly reviewed the letter of interest for this consultant and certify that the above scores represent my best judgment of this firm's abilities. Signature: ;et? Title: �• (Form Rev. 4-7-16) PrintName: Date: �1.1 ( .. ,.m.... ..... .... „, BOARD OF PUBLIC WORKS AGENDA ITEM REVIEW REQUEST FORM Date April 12019 .__............. ....... Department Public Name Scott Kreeger Works ......... BPW Date Aril 912019 Phone Extension 9245 Mm M RNuired Prior to Submittal to Board BPW Attorney Attorney Name Clara McDanlels Dept. Attorney Attorney Name Purchasing ® Michael. Schmidt Check the Appro rat Item `l" o �- Re u ❑ Professional Services Agreement Z Contract Open Market Contract ❑ Amendment/Addendum Bid Opening ❑ Bid Award Quote Opening F� Quote Award Proposal Opening C/O & PCA No. El Chg. Order, No. ❑ Traffic Control 7 Other: Pronosal Award Company or Vendor Name New Vendor MBE/WBE Contractor Project Name Project Number Funding Source Account No. Amount Terms of Contract Purpose/Description (I or All Submissions ❑ Proposal Special Purchase, QPA ❑ Req. to Advertise ❑ Reject Bids/Quotes 0 PCA Resolution Ease./Encroach ❑ Title Sheet .Slirewsberry & Associates, LLC ..... _ _ Yes If Yes, Approved by Purchasing No MBE Completed E-Verify Form Attached F]Yes WBE [:] No School Zone Flashing Beacon Assemblies 117-075 R _._.__ _._..................... ..... ....... Professional Services / Other Professional Services 412-0602-431.31-06 $79,372.00 .M.... - ............. Hourly NTE Engineering design for the review and installation of school zone flashing beacons within the City of South Bend. For, 4-0g C3idexs Amount of ❑ Increase _......_.$ ....... ......... _._...__. -_._._ ❑ Decrease ($ ) Previous Amount $ _ Increase ................._... ................ % Current Percent of Change: Decrease New Amount $ ............. . ... _.......... Increase uuu_ % �.._........ Total Percent of Change: Decrease ......... .... %._.. Time Extension Amount: _........_ New Completion Date: