Loading...
HomeMy WebLinkAboutProfessional Services Agreement - Maclovio Cantu IV - Traffic Calming Artwork at Riverside Drive and Hudson Avenue1316 Cotwvy-Ck ry BOILDING 227 W. Jl--'Fr-,RSON 1301JLFiVARD Sot ji,Ii BEND. INDIANA 4 6601-1830 CITY OF SOUTuj BEND PETS BUTTICAFG, MAYOR BOARD OF PUBLIC' WORKS April 24,2018 Maclovio Cantu IV 125 W. Marion Street, Apt 311 South Bend, rN 46601 RE: Professional Services Agreement Dear Mr. Cantu: PHONiv 574/235-9251 FAX 574/ 235-9171 The Board of Public Works, at its meeting held on April 24, 2018, approved the above referenced agreement regarding traffic calming artwork at Riverside Drive and Hudson Ave, in the amount of $650. Enclosed please find a copy of the agreement for your records. If you have any further questions regarding this matter, please call this office at (574) 235- 9251. Sincerely, Linda M. Martin, Clerk Enclosure c : Jitin Kain, Public Works SE J. DORAIJ GARY A. GjLo-r SUZANNA M. FRITZBERG ELIZABEni A. MARADIK JAMEs A. MUELLER T[ ]ERE AGREEMENT FOR SERVICES This Agreement For Services (this "Agreement") is entered into on April 24, 2018 (the "Effective Date"), by and between the City of South Bend, acting by and through its Board of Public Works (the "City"), and Maclovio Cantu IV, a professional artist with an office address at 125 W. Marion St., Apt 311, South Bend, IN 46601 (the "Provider") (each a "Party" and collectively the "Parties"). For and in consideration of the mutual covenants and promises contained herein, the Parties agree as follows: 1. Services. The Contractor will provide to the City the services (the "Services") set forth in the Contractor's proposal attached hereto as Exhibit A (the "Proposal"), which Proposal is incorporated herein. In the event of any conflict between the terms of this Agreement and the terms of the Proposal, the terms of this Agreement will prevail. The Contractor will execute its obligations under this Agreement in accordance with the prevailing professional standard of care for projects of similar design and complexity. 2. Compensation. In exchange for the Contractor's satisfactory performance of the Services, and subject to the terms and conditions of this Agreement, the City will pay the Contractor the fee stated in the Proposal (the "Contract Amount") in accordance with the project budget stated in the Proposal. The City will pay the Contract Amount in installments upon invoicing by the Contractor as set forth in the Proposal (each a "Contract Installment"). The City will not be required to pay any Contract Installment if the City is not satisfied with the Contractor's performance under this Agreement or any default or breach of this Agreement by the Contractor exists, as the City may determine in its sole discretion. The sum of all Contract Installments will not exceed the Contract Amount, and the Contractor will not incur or seek reimbursement for any expenses in excess of the Contract Amount. 3. Term; Termination. Unless earlier terminated in accordance with its terms, this Agreement will commence on the Effective Date and end upon the Contractor's satisfaction of all its obligations hereunder and the City's final payment therefor. Notwithstanding the foregoing, effective immediately upon delivery of a written termination notice to the Contractor, the City may terminate this Agreement, in whole or in part, for any reason, if the City determines that such termination is in the best interest of the City. In addition, in accordance with Ind. Code 6-1.1-18, payments are subject to appropriation by the City. If the City makes a written determination that funds are not appropriated or are otherwise unavailable to support the continuation of this Agreement, it shall be cancelled. A determination by the City that funds are not appropriated or are otherwise unavailable to support the continuation of performance shall be final and conclusive. The City will not be required to pay any Contract Installment or be otherwise liable for any cost associated with the Contractor's performance of any Services after the effective date of termination. 4. Remedies for Breach of Contract. Failure to complete the Services in accordance with this Agreement will be considered a material breach. In the event of such breach, the City may suspend all payments to the Contractor and may pursue any and all remedies available at law or in equity. The Contractor shall repay to the City any portion of the Contract Amount expended for matters not within the scope of the Services. 5. Point of Contact. The City employee identified in Section 9 below will serve as the City's principal point of contact for purposes of this Agreement, 6. Relationshit�. The Contractor shall at all times be an independent contractor for the performance of the Services rather than an employee of the City, and no act or omission to act by the Contractor shall in any way bind or obligate the City. This Agreement is strictly for the benefit of the Parties and not for any third party or person. This Agreement was negotiated by the Parties at arm's length and each of the parties hereto has reviewed the Agreement after the opportunity to consult with independent legal counsel. Neither party shall maintain that the language in the Agreement shall be construed against any signatory hereto. The City and the Contractor hereby renounce the existence of any form of agency relationship, joint venture, or partnership between the Contractor and the City and agree that nothing contained herein or in any document executed in connection herewith shall be construed as creating any such relationship between the City and the Contractor. 7. Indemnification of City. The Contractor hereby agrees to defend, indemnify, and hold harmless the City, its officials, employees, and agents from any and all claims of any nature which arise from the performance by the Contractor under this Agreement and from all costs and attorney fees in connection therewith, excepting for claims arising out of the negligence of the City, its officials, directors, employees, and agents. The obligations of the Contractor under this section shall survive the termination of this Agreement. 8. Assignment. The Contractor shall not assign or subcontract the whole or any part of this Agreement or its obligations hereunder without the prior written consent of the City. 9. Notices. Any notice required or permitted to be delivered hereunder shall be deemed to be delivered, whether or not actually received, when deposited in the United States Postal Service, postage prepaid, registered or certified mail, return receipt requested, addressed to the City or the Contractor, as the case may be, at the address set forth below. Contractor: Cam: Maclovio Cantu IV City of South Bend 125 W. Marion St., Apt 311 227 W. Jefferson Boulevard, Suite 1400 N. South Bend, IN 46601 South Bend, IN 46601 Attn: Jitin Kain, Public Works 10. Equal Opportunity, Non -Discrimination; Compliance. The Contractor shall comply with all applicable laws and regulations in its hiring and employment practices and policies for any activity covered by this Agreement. The Contractor shall comply with all state, federal, and municipal laws, regulations, and standards applicable to its activities pursuant to this Agreement including, but not limited to, the requirements imposed by Ind. Code 22-9-1-10 (non- discrimination), the provisions of Ind. Code 5-22-16.5 (disqualification for dealings with the government of Iran), and the provisions of Ind. Code 22-5-1.7 (requiring E-Verify for new 2 employees and prohibiting employment of unauthorized aliens). Each of the foregoing provisions is incorporated herein as if set forth in full, and the Contractor certifies that it is in compliance with each such provision and shall remain in compliance through the term of this Agreement. 11. Contractor's Affidavit. The Contractor agrees, as a condition precedent to the effectiveness of this Agreement, that its authorized representative will execute and submit to the City and any other appropriate bodies an affidavit in the form attached hereto as Exhibit B. 12. Drug -Free Workplace. The Contractor hereby agrees to make a good faith effort to provide and maintain a drug -free workplace. The Contractor will give written notice to the City within ten (10) days after receiving actual notice that the Contractor or an employee of the Contractor within the State of Indiana has been convicted of criminal drug violation occurring in the workplace. 13. Entire Agreement; Amendment; A licable Law. This Agreement sets forth the entire agreement and understanding between the parties as to the subject matter hereof, and merges and supersedes all prior discussions, agreements, and understanding of any and every nature between them. This Agreement may be amended only by separate writing, signed by authorized representatives of both the Contractor and the City. This Agreement will be construed and interpreted according to the laws of the State of Indiana, and any dispute arising out of this Agreement or otherwise concerning the Contractor's rendering of the Services will be resolved in the courts located in St. Joseph County, Indiana, unless the Parties mutually agree to a different method of dispute resolution. 14. Severability. All provisions of this Agreement shall be considered as separate terms and conditions, and in the event any one shall be held illegal, invalid or unenforceable, all the other provisions hereof shall remain in full force and effect as if the illegal, invalid, or unenforceable provision were not a part hereof, unless the provision held illegal, invalid or unenforceable is a material provision of this Agreement, in which case the Contractor and the City agree to amend this Agreement with replacement provisions containing mutually acceptable terms and conditions. 15. Force Mgure. The Contractor shall not be responsible for any failure or delay in the performance of any obligation hereunder, if such failure or delay is due to a cause beyond the Contractor's reasonable control, including, but not limited to acts of God, flood, fire, volcano, war, third -party suppliers, labor disputes or governmental acts. [Signature page follows.] IN WITNESS WHEREOF, the Parties hereto have caused this Agreement for Services to be effective as of the Effective Date stated above. 4 4411 as re Nadc,(116, Printed Name and Title Street Address P.O. Box Ory, State Zip 1�;4 13 V Telephone Fax CITY OF SOUTH BEND, INDIANA BOARD OF PUBLIC WORKS, Gary Gilot, President James Mueller, Member j I uk- Elizabeth Maradik, Member Therese Dorau, 146mber Suzarma Fritzberg, Member ATTEST: "Linda Martin, Cler'k 0 EXHIBIT A Proposal [See attached.] 24703599,2 EXHIBIT B Contractor's Affidavit [See attached.] 242W589.2 4/11 /201 S 125. W Marion St. Apt. 311 South Bend, IN. 46601 Proposal of Services: Provided painting services for the Placemaking street mural project. These services include designing and painting the artwork at the intersection of Riverside Drive and Hudson Ave. The professional fee for this work will be $650.00 Paint and painting supplies will be provided by the City at their own expense. Maclovio Cantu IV Date Name BOARD OF PUBLIC WORKS AGENDA ITEM REVIEW REQUEST FORM 4/18118 Jitin Kain Department Public Works BPW Date 4/24/18 Phone Extension 5835 ❑ Professional Services ❑ Bid Opening ❑ Quote Opening ❑ Chg Order No. ❑ Ease./Encroach. F.I Other: ❑ Amendment ❑ Bid Award ❑ Quote Award ❑ C/O &PCA No ❑ Traffic Control ❑ Req. to Advertise ❑ PCA ❑ Resolution F l Claim ❑ Title Sheet Company or Vendor Name Maclovio Cantu IV ®Yes ❑ If Yes, Approved by Purchasing New Vendor ❑ No MBEIWBE Contractor ` ❑MBE Completed E Verify Form ❑Yes ❑ WBE Attached No ❑ Project Name Riverside & Hudson Placemaking Project Number Funding Source Account No. Amount $650 Terms of Contract Purpose/Description The services include designing and painting artwork at the intersection of Riverside Drive and Hudson Ave. This is part of a placemaking initiative being implemented to calm traffic at the intersection. °, . for Change Orders On[ Amount of ❑ Increase $ ❑ Decrease $ Previous Amount $ Current Percent of Change: % New Amount $ Total Percent of Change: % Time Extension: Dispersal. After Approval Copy Original ❑ ❑ ❑ ❑ ❑ ❑