|
WARRANTY:
<br />MANUFACTURERS' LIMITED WARRANTY ON ALL EQUIPMENT, PARTS AND MATERIALS.
<br />A. LABOR AND MATERIALS: Horton Ambulance shall furnish the Ambulance listed as specified, with Me price and delivery quoted herein, are
<br />based on materials which were in our inventory and in the inventory of our suppliers at the time m this proposal and are subject to prior sale.
<br />Delivery quotes are contingent on fimely confirmation him Customer Any variations to material listed will result in a cost change.
<br />Change Order Fees may apply
<br />B. ARBITRATION: If any controversy or dispute arises under, out of, or in relation to any "a provisions hereof which cannot be settled by
<br />Me parties within 15 days after the same shall arise, such controversy or dispute shall be submitted for arbitration in the State of Ohio in
<br />accordance with Me Mies Of Me American Ar omphi n Association Sn arblh'ator(s) in a=oO anee W sneh Mies shall
<br />determine any dispute or controversy submitted to arbitration in accordance with Me provisions of Me section.
<br />The arohnitions) may award any relief which he or she shall deem proper in Me circumstances, without regard to Me relief which
<br />would otherwise be available to any party hereto in a coon M law or equity including, without limitation, an award of money damages, specific
<br />performance, injunctive relief and/or declaratory relief. The aware and findings dfMe arbitrators shall be condushm and binding upon all Me
<br />parries hereto, whether or not all pates hereto participate in the arbitration proceeding, and judgment upon Me award may be entered in any
<br />court of competent jurisdiction upon Me application of any party.
<br />Any party may in@ate an arbitration proceeding hereunder, all costs Of which (inducting filing fees, fees payable to impostors, court
<br />reporters' fees, transcript costs and counsel fees) shall be recovered by the prevailing party. No party hereto shall commence any arbitration
<br />proceeding hereunder other than in good faith, or take any action other than in good faith which requires another party hereto to commence
<br />such arbitration hearing and, in Me event any party is determined in arbitration to have so acted other Man in good faith, he or it shall bear all
<br />casts of Me such proceeding.
<br />C. REPRESENTATION OF SOLVENCY: Buyer represents Mat buyer is solvent and has assets suficient to meet all M its finanaal obligations,
<br />and that it is current an all offs financial obligations. Buyer fuller represents that it can and will meet all its financial obligations to seller on
<br />time. Buyer understands seller relies on this promise and that any breach is material and substamial and to the essence of the contract.
<br />D. FORCE MAJEURE Seller shall not be responsible for delay, nondelivery, failure to complete installation or construction, or default in
<br />shipment or other performance, in whale or in part if occasioned by strike, war, not, or revolutions, or for any delay in transportation due to
<br />demands or embargoes of the United States government or any other government, or nondelivery or delays through fire, foods, dmugms,
<br />accidents, insurrections, lockouts, breakdown of machinery, commandeering of vessels carrying goads, or for lass or damage in transit, or
<br />detention of or delay in vessels resulting directly or indirectly from ads of God, perils of the sea, stoppage d labor, shortage of tamers, or
<br />refusal of any necessary license of government restrams considered as'Yorce majeues" or any other unavoidable cause other than sellers
<br />own negligence. In no case shall seller be responsible after delivery d goods in good order or conditioning to Me center or carriers "a point
<br />of shipment
<br />E. CUSTOM ORDERS: Buyer understands Mat a custom -ordered vehicle is specific to Buyers needs. Any deposit received for a custom order
<br />is non-refundable once Engineering has begun, material has been purchased or the vehicle begins production.
<br />YOU MAY CONSIDER THE PRICE QUOTED FIRM FOR WRITTEN ACCEPTANCE WITHIN 30 DAYS OF THE DATE OF OUR PROPOSAL.
<br />Thank you for your interest in having Horton Ambulance provide you with our quotation for this
<br />purchase. Ifyou have any questions or comments regarding this sales agreement please contact us.
<br />Sincerely,
<br />Robert Burgh
<br />Horton Ambulance
<br />ACCEPTANCE OF PROPOSAL:
<br />I have read, understand and agree to Me terms, conditions and specifcations described herein and
<br />euthome Renegade Specialty Vehicles to go forward with this order.
<br />By:
<br />Signature of Customer
<br />Date
<br />
|