2. 721 Forest Avenue_COA 2026-0106 PACKET

Home Browse Search

leaptodigital.com 2.30.3 ADDITIOAL TERMS & CODITIOS Contractor’s Responsibility: Mad City shall perform all work in a professional manner and in keeping with industry standards. Mad City is not responsible for any damage resulting from structural or other defects in the property at which the installation is carried out. Mad City shall not be responsible for remedying structural defects. Buyer acknowledges Mad City’s products do not correct or cure structural problems. Mad City is not responsible for (a) any damages arising in whole or in part from strikes, fires, accidents, floods, governmental actions, or any other causes beyond the control of Mad City; (b) any consequential damages including, without limitation, lost profits or reduction in the value of Buyer’s property, arising from Mad City’s delay in performing under this Agreement or due to its breach of this Agreement; and (c) unintentional damage to window treatments, landscaping, driveways, sidewalks, gas lines, electrical wiring, plumbing, telephone installations, collateral or incidental damage to interior walls and personal property, it being understood that Buyer is responsible at Buyer’s cost for all preparations, protection, and/or moving of such items prior to Mad City’s commencement of work. If applicable, Mad City shall not be responsible for the reinstallation or reconnection of any security or alarm system or security or alarm sensors, and any reconnection fees, surcharges, or any other associated costs are the responsibility of Buyer. The reinstallation of security alarm hardware is the responsibility of Buyer. Any interior trim installed by Mad City will be unfinished, and Mad City is not responsible for any staining or painting needed as a result of the work performed. Contractor Warranties: Any written warranties for the products installed will be provided to Buyer(s) at time of full payment. The sales representative has copies of the warranties for the products being offered for sale, which Buyer(s) may inspect at any time during the sales presentation. Mad City shall provide any manufacturer warranties upon full payment of Purchase Price. Mad City warrants its workmanship as described on the warranty to be provided to Buyer(s). Buyer(s) understands they should read Mad City’s written warranty for complete details of the warranty coverage available for complete review before Buyer(s) signs this Agreement. Buyer(s) understands that warranties will not be effective or enforced while a balance due remains outstanding on this Agreement. Buyer’s Punch List Rights: Within three (3) days following Substantial Completion of the work, Buyer(s) may request a “walk-through” inspection with Mad City to determine whether the project has been constructed in a good and workmanlike condition and in accordance with this Agreement. “Substantial Completion” is defined as the job being materially completed, functional as intended, and a final inspection having been obtained. If either Mad City or Buyer(s) determines that any items have not been completed in accordance with this Agreement or are not completed in a good and workmanlike manner, Buyer(s) and Mad City shall prepare a list (the “Punch List”) of such incomplete or deficient items (the “Punch List Items”). Buyer(s) may retain a maximum of ten percent (10%) of the balance due under this Agreement upon Substantial Completion (hereinafter referred to as “Retainage”). Once Mad City has completed work on the Punch List Items, Buyer(s) shall make immediate payment to Mad City of the Retainage. Additional work requested by Buyer(s), unless covered by Mad City’s labor warranty, will require the parties to execute a Change Order to the current Agreement. Buyer’s Representations and Responsibilities: Buyer(s) will provide reasonable access to the property and the area on which the work is to be performed, including access to electrical outlets and access to deliver and/or remove materials and debris as may be required by Mad City. Buyer(s) will be responsible for the preparation, moving, and reinstalling of electrical or telephone wiring, satellite dishes, water lines, power lines, plumbing, and moving of shrubs and plants as required for performance by Mad City under this Agreement. Buyer(s) represents to Mad City that all of the existing surfaces are suitable to receive the materials identified in the scope of work. Buyer warrants to have disclosed to Mad City all conditions about the premises that may reasonably be relevant to Mad City’s work, including but not limited to all hazards and unsafe conditions. Buyer warrants having liability insurance in force on Buyer’s property. Choice of Law, Venue, and Attorney’s Fees: This Agreement shall be governed by the laws of the State in which it is executed, and venue for all actions related to this Agreement shall rest exclusively in the County where Buyer’s property is without regard to any conflict of laws, and the parties hereto specifically consent as such. Should either party employ an attorney to institute litigation or arbitration to enforce any of the provisions hereof, to protect its interest in any matter arising out of or related to this Agreement, the prevailing party shall be entitled to recover from the other party all of its reasonable attorney’s fees and costs/expenses incurred therein, including costs/expenses incurred at mediation, administrative, appellate or bankruptcy proceedings. Late Cancellation, Late Payment/Default: If Buyer(s) attempts to cancel this Agreement at any time after midnight of the third business day after the date of the Agreement, as more fully described on the Notice of Right to Cancel form, and Mad City accepts such late cancellation, then Buyer(s) agrees to pay Mad City a cancellation fee equal to 10% of the Agreement’s purchase price, or the maximum amount permissible by law otherwise, to offset Mad City’s incurred labor, administrative, and material costs, including any restocking expenses, because Mad City is unable to accurately measure its damages for the cancellation of the Agreement. By executing this Agreement, Buyer(s) and Mad City agree that the liquidated damages amount is not a penalty. If Buyer(s) is in default of this Agreement, Buyer(s) agrees to pay Mad City its reasonable attorney’s fees and other legal expenses incurred as part of its collection efforts. Buyer(s) agrees to pay interest at the rate of 1 1/2 % per month unless otherwise required by law, on the balance of any and all unpaid amounts including, without limitation, after the entry of a final judgment on any collection matter. Payments received shall be applied first to interest on all outstanding invoices and then to the principal amount of the oldest outstanding invoices. Delay/Unknown Conditions: Mad City will not be responsible for delays that are due to events beyond its control, such as Acts of God, labor strikes, bad weather, permitting delays, or material shortages. If Mad City determines within 30 days of entering into this Agreement that the Agreement cannot be performed as intended due, for example, to incorrect pricing or unforeseen structural defects to the Buyer’s property, then Mad City may cancel this Agreement and return all monies paid by the Buyer. Mad City and the Buyer(s) have determined that a definite completion date is not of the essence to this Agreement. READ & ACCEPTED Page 3 of 23