|
AIA Document A2 01- -- 2017
<br />General Conditions of the Contract for Construction
<br />fourteen days of the Contractor's request, the Contractor may immediately stop the Work and, in that event, shall notify the
<br />Owner that the Work has stopped. However, if the request is made because a change in the Work materially changes the
<br />Contract Sum under (3) above, the Contractor may immediately stop only that portion of the Work affected by the change
<br />until reasonable evidence is provided. If the Work is stopped under this Section 2.2.2, the Contract Time shall be extended
<br />appropriately and the Contract Sum shall be increased by the amount of the Contractor's reasonable costs of shutdown, delay
<br />and start-up, plus interest as provided in the Contract Documents.
<br />§ 2.2.3 After the Owner furnishes evidence of financial arrangements under this Section 2.2, the Owner shall not materially
<br />vary such financial arrangements without prior notice to the Contractor.
<br />§ 2.2.4 Where the Owner has designated information furnished under this Section 2.2 as "confidential," the Contractor shall
<br />keep the information confidential and shall not disclose it to any other person. However, the Contractor may disclose
<br />"confidential" information, after seven (7) days' notice to the Owner, where disclosure is required by law, including a
<br />subpoena or other form of compulsory legal process issued by a court or governmental entity, or by court or arbitrator(s)
<br />order. The Contractor may also disclose "confidential" information to its employees, consultants, sureties, Subcontractors and
<br />their employees, Sub -subcontractors, and others who need to know the content of such information solely and exclusively for
<br />the Project and who agree to maintain the confidentiality of such information.
<br />§ 2.3 Information and Services Required of the Owner
<br />§ 2.3.1 Except for permits and fees that are the responsibility of the Contractor under the Contract Documents, including those
<br />required under Section 3.7.1, the Owner shall secure and pay for necessary approvals, easements, assessments and charges
<br />required for construction, use or occupancy of permanent structures or for permanent changes in existing facilities.
<br />§ 2.3.2 The Owner shall retain an architect lawfully licensed to practice architecture, or an entity lawfully practicing
<br />architecture, in the jurisdiction where the Project is located. That person or entity is identified as the Architect in the
<br />Agreement and is referred to throughout the Contract Documents as if singular in number.
<br />§ 2.3.3 If the employment of the Architect terminates, the Owner shall employ a successor to whom the Contractor has no
<br />reasonable objection and whose status under the Contract Documents shall be that of the Architect.
<br />§ 2.3.4 The Owner shall furnish surveys describing physical characteristics, legal limitations and utility locations for the site
<br />of the Project, and a legal description of the site. The Contractor shall be entitled to rely on the accuracy of information
<br />furnished by the Owner but shall exercise proper precautions relating to the safe performance of the Work.
<br />§ 2.3.5 The Owner shall furnish information or services required of the Owner by the Contract Documents with reasonable
<br />promptness. The Owner shall also furnish any other information or services under the Owner's control and relevant to the
<br />Contractor's performance of the Work with reasonable promptness after receiving the Contractor's written request for such
<br />information or services.
<br />§ 2.3.6 Unless otherwise provided in the Contract Documents, the Owner shall furnish to the Contractor one copy of the
<br />Contract Documents for purposes of making reproductions pursuant to Section 1.5.2.
<br />§ 2.4 Owner's Right to Stop the Work
<br />If the Contractor fails to correct Work that is not in accordance with the requirements of the Contract Documents as required
<br />by Section 12.2 or repeatedly fails to carry out Work in accordance with the Contract Documents, the Owner may issue a
<br />written order to the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated;
<br />however, the right of the Owner to stop the Work shall not give rise to a duty on the part of the Owner to exercise this right
<br />for the benefit of the Contractor or any other person or entity, except to the extent required by Section 6.1.3.
<br />AIA Document A201" - 2017. Copyright _ 1911, 1915, 1919, 1925, 1937, 1951, 1958, 1961, 1963, 1966, 1970, 1976, 1987, 1997, 2007 1
<br />and 2017 by The American Institute of Architects. A11 rights reserved. WARNING: This AIA° Document is protected by U.S. Copyright
<br />Law and International Treaties. Unauthorized reproduction or distribution of this AIA° Document, or any portion of it, may result
<br />n severe civil
<br />and criminal
<br />nal penalties, and will be prosecuted to the m extent possible under the law. This draft was
<br />produced by AIA software at 09:02:25 on 05/10/2017 under Order No. 1496524162 which expires on 03/09/2015, and is not for resale.
<br />User Notes:
<br />(389ADA17)
<br />
|