|
WARRANTY:
<br />MANUFACTURERS' LIMITED WARRANTY ON ALL EQUIPMENT, PARTS AND MATERIALS.
<br />TERMS AND CONDITIONS:
<br />A. LABOR AND MATERIALS: Horton Ambulance shall fumish the Ambulance listed as specified, with the price and delivery quoted herein, are
<br />based on materials which were In our inventory and in the inventory o€ouf suppliers at the time of this proposal and are subject to prior sale.
<br />Delivery quotes are contingent on timely confirmation from Customer. Any variations to material listed will result in it cost change.
<br />Change Order Fees may apply
<br />B. ARBITRATION: If any controversy or dispute arises under, out of, or in relation to any of the provisions hereof which cannot be settled by
<br />the parties within 15 days after the same shall arise, such controversy or dispute shall be submitted for arbitration in the State of Ohio in
<br />accordance with the rules of the American Arbitration Association. Such arbitrator(s) in accordance with such rules shall
<br />determine any dispute or controversy submitted to arbitration in accordance with the provisions of the secfion.
<br />The arbilrator(s) may award any relief which he or she shall deem proper in the circumstances, without regard to the relief which
<br />would otherwise be available to any party hereto in a court of law or equity including, without limitation, an award of money damages, specific
<br />performance, injunctive relief andlor dedarstory relief. The award and findings of the arbitrators shall be conclusive and binding upon all the
<br />parties hereto, whether or not all parties hereto participate in the arbitration proceeding, and judgment upon the award may be entered In any
<br />court of competent jurisdiction upon the application of any party.
<br />Any party may initiate an arbitration proceeding hereunder, all costs of which (including filing fees, fees payable to arbitrators, court
<br />reporters' fees, transcript costs and counsel fees) shall be recovered by the prevailing party. No party herato shalt commence any arbitration
<br />proceeding hereunder other than in good faith, or take any action other than in good faith which requires another party hereto to commence
<br />such arbitration hearing and, in the event any party is determined in arbitration to have so acted other than in good faith, he or it shall bear ail
<br />costs of the such proceeding,
<br />C. REPRESENTATION OF SOLVENCY: Buyer represents that buyer is solvent and has assets sufficient to meet all of its financial obligations,
<br />and that it is cement on oil of ils financial obligations. Buyer further represents that it can and will meet all its financial obligations to seller on
<br />time. Buyer understands seller relies on this promise and that any breach is material and substantial and to the essence of the contract.
<br />D. FORCE MAJEURE: Seller shall not be responsible for delay, nendeiiveiy, failure to complete installation or construction, or default in
<br />shipment or other performance, in whole or in pan if occasioned by strike, war, riot, or revolutions, or for any delay in transportation due to
<br />demands or embargoes of the United States government or any other government, or nondelivery ordelays through fire, floods, droughts,
<br />accidents, insurrections, lockouts, breakdown of machinery, commandeering of vessels carrying goods, or for loss or damage in transit, or
<br />detention of or delay In vessels resulting directly or indirectly from acts of God, perils of the sea, stoppage of labor, shortage of carriers, or
<br />refusal of any necessary license of government restrictions considered as "force majeure," or any other unavoidable cause other than sellers
<br />own negligence. in no case shall seller be responsible after delivery of goods in good order or conditioning to the carrier or carders at the point
<br />of shipment.
<br />E. CUSTOM ORDERS: Buyer understands that a custom -ordered vehicle is specific to Buyers needs. Any deposit received for a custom order
<br />is non-refundable once Engineering has begun, material has been purchased or the vehicle begins production.
<br />YOU MAY CONSIDER THE PRICE QUOTED FIRM FOR WRITTEN ACCEPTANCE WITHIN 30 DAYS OF THE DATE OF OUR PROPOSAL.
<br />Thank you for your interest in having Horton Ambulance provide you with our quotation for this
<br />purchase. If you have any questions or comments regarding this sales agreement please contact us,
<br />Sincerely,
<br />Robert Burgh
<br />Horton Ambulance
<br />ACCEPTANCE OF PROPOSAL'
<br />I have read, understand and agree to the terms, conditions and specifications described herein and
<br />authorize Renegade Specialty Vehicles to go forward with this order.
<br />By:
<br />Signature of Customer
<br />Date
<br />
|