Laserfiche WebLink
DocuSign Envelope ID: E657424D-142C-4DDA-85F'9-31 D697BE41370 <br />15. Providing Construction Phase services beyond the original date for completion and <br />readiness for final payment of Contractor. <br />lb. Providing assistance in responding to the presence of any Constituent of Concern at the <br />Site, in compliance with current Laws and Regulations. <br />17. Preparing Record Drawings showing appropriate record information based on Project <br />annotated record documents received from Contractor, and furnishing such Record <br />Drawings to Owner. <br />18. Preparation of operation and maintenance manuals. <br />19. Preparing to serve or serving as a consultant or witness for Owner in any litigation, <br />arbitration, or other dispute resolution process related to the Project. <br />20. Providing more extensive services required to enable Engineer to issue notices or <br />certifications requested by Owner. <br />21. Assistance in connection with the adjusting of Project equipment and systems. <br />22. Assistance to Owner in training Owner's staff to operate and maintain Project equipment <br />and systems. <br />23. Assistance to Owner in developing procedures for (a) control of the operation and <br />maintenance of Project equipment and systems, and (b) related record -keeping. <br />24. Overtime work requiring higher than regular rates. <br />25. Other services performed or furnished by Engineer not otherwise provided for in this <br />Agreement. <br />A. Engineer shall advise Oy,%er- in ad-N,anee thi4 Engineer is will im.-nediately eeffiffienee ie pei <br />8r•.• <br />r-equested by Owner-.' <br />equal"of stibst4ute materials er- equipmefll other- than "ef equal" i4e ' af ter- the awaf d e <br />7 —aluatian and <br />............. <br />Page k l <br />(Exhibit A — Engineer's Services) <br />EJCDC E-500 Agreement Between Owner and Engineer for Professional Services <br />Copyright © 2008 National Society of Professional Engineers for EJCDC. All rights reserved. <br />